Loading...
HomeMy WebLinkAboutBuilding Permit #132 - 171 KARA DRIVE 8/18/2006 I 1 TOWN OF NORTH ANDOVER NORTH APPLICATION FOR PLAN EXAMINATION 6�'�'p Permit NO: // Date ReceivedArED *?o e SSA Date Issued: I -6 CHus���y IMPORTANT: Applicant must complete all items on this page LOCATION V k f Knot PROPERTY OWNER C\-\f-0, gn& V�e c'(, SL f I 1 uc t-, Print MAP NO.: PARCEL: ZONING DISTRICT: TYPE AND USE OF BUILDING HISTORIC DISTRICT YES ❑ TYPE OF IMPROVEMENT PROPOSED USE Residential Non- Residential ❑New Building ❑ One family ❑ Addition ❑Two or more family ❑ Industrial Alteration No. of units: ❑ Repair, replacement ❑Assessory Bldg ❑ Commercial ❑ Demolition ❑ Moving(relocation) ❑Other ❑ Others: ❑ Foundation only DESCRIPTION OF WORK TO BE PREFORMED Identification Please Type or Print Clearly) OWNER: Name: C V, Phone: Address: CONTRACTOR Name: Q{c� '—PQ)-P, pe hoQ A�io VIS Phone: 4 0,-7&', 4C,,W S3 a Address: �� �01 S� �. r �+ -hC�UL� r Supervisor's Construction License: CS 0�-3 S o Exp. Date: �U ' Home Improvement License: l i3� Exp. Date: ARCHITECT/ENGINEER Name: Phone: Address: �---�� Reg. No. FEE SCHEDULE:BULDING PERMIT:$12.00 PER$1000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost :$ /GI sl-o 1 EE:$ Qg2== Check No.: �L Y Receipt No.:��- Page 1 of 4 Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits ❑ Building Permit Application ❑ Workers Comp Affidavit ❑ Photo Copy Of H.I.C. And/Or C.S.L. Licenses ❑ Copy of Contract ❑ Floor Plan Or Proposed Interior Work Addition Or Decks ❑ Building Permit Application ❑ Surveyed Plot Plan ❑ Workers Comp Affidavit ❑ Photo Copy of H.I.C. And C.S.L. Licenses ❑ Copy Of Contract ❑ Floor/Crossection/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Mass check Energy Compliance Report (If Applicable) New Construction (Single and Two Family) ❑ Building Permit Application ❑ Certified Proposed Plot Plan ❑ Photo of H.I.C. And C.S.L. Licenses ❑ Workers Comp Affidavit ❑ Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Copy of Contract ❑ Mass check Energy Compliance Report In all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals that the appeal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording must be submitted with the building application Doc:INSPECTIONAL SERVICES DEPARTMENT:BPFORM05 Pave 4 of 4 TYPE OF SEWERAGE DISPOSAL Swimming Pools ❑ F] Tobacco Art ❑ g Public Sewer Tobacco Sales ❑ Food Packaging/Sales ❑ Well ❑ Permanent Dumpster on Site ❑ Private(septic tank,etc. ❑ Electric Meter location to project NOTE: Persons contracting with unregistered contractors do not have access to the guaranty fund V, Signature of A ent/Owner g g Signature of contractor U4e---� Plans Submitted ElPlans Waived ❑ Certified Plot Plan ❑ Stamped Plans ❑ THE FOLLOWING SECTIONS FOR OFFICE USE ONLY INTERDEPARTMENTAL SIGN OFF-U FORM DATE REJECTED DATE APPROVED PLANNING & DEVELOPMENT ❑ ❑ []Water Shed Special Permit ❑ Site Plan Special Permit j ❑ Other COMMENTS DATE REJECTED DATE APPROVED CONSERVATION ❑ ❑ COMMENTS DATE REJECTED DATE APPROVED HEALTH ❑ s COMMENTS Zoning Board of Appeals: Variance, Petition No: Zoning Decision/receipt submitted yes Planning Board Decision: Comments Conservation Decision: Comments Water&Sewer connection/Signature& Date Drivewav Permit Temp Dum ster on site yes�no_ Fire Department signature/date �� Building Setback ( Front Yard Side Yard Rear Yard Required Provided Required Provides Required Provided Dimension Number of Stories: Total square feet of floor area,based on Exterior dimensions. Total land area,sq.ft.: NOTES and DATA—(For department use) i I Page 3 of 4 Doc:INSPECTIONAL SERVICES DEPARTMENT:BPFORM05 Created JMC.Jan.2006 C Location No. Z— Date v - MaRT� TOWN OF NORTH ANDOVER N 9 + Certificate of Occupancy $ 'Ss,cMusE Building/Frame Permit Fee $ Foundation Permit Fee $ Other Permit Fee $ TOTAL $ Check # �� c 937 3 _ Building Inspector I 5� . o S \SV RED APPLE RENOVATIONS home 37'fliodeClll.1tr ptufo"sw'ott(it's Construction Contract This construction contract (the "Contract"), dated June 21, 2006 is by and between the following homeowner(s) and contractor: Homeowner(s): Chris and Becky Sullivan Property address 171 Kara Drive City, State, Zip North Andover, MA 01845 Contractor: Red Apple Renovations, Inc. Representative: Chris Matey, President Street 9 Bartlet Street, #332 Andover, MA 01810 Telephone 978.409.1293 Federal Identification Number: 56-2309042 Massachusetts License Numbers: Construction Supervisor CS 083511 Home Improvement 138132 1. GENERAL In consideration of the mutual promises contained herein, Contractor agrees to perform the following work: furnish all labor, materials, tools, equipment, and supervision to construct or renovate the Homeowner's residence according to this Contract and the following documents (collectively with this Contract, the "Contract Documents"). The project is generally described as remodeling the master bathroom (the "Project"). The Contract consists of this document, Exhibit I - General Conditions, Exhibit II - the Project, and Exhibit III - Shower Sketch. Change orders and modifications shall be in writing and shall become part of this Contract. 2. PRICE The total projected price for the work agreed upon is $19,350. Payment terms are set out below in Paragraph 6. 3. STARTING AND SUBSTANTIAL COMPLETION PROVISIONS The work will begin on or about August 7, 2006 through August 18, 2006. The work will be substantially completed on or about September 18, 2006 through September 30, 2006. co PY P 4. SPECIFIC REQUIREMENTS FOR MATERIALS SrA`ND WORtor in a gKMdANSH IP a. This Contract willcompleted manner, using good quality materials. es the allowances listed in the Contract Details b. If applicable, the Contract price includ Section. S. EXPIRATION OF THIS CONTRACT This Contract will expire thirty (30) days after the da afirs at titten above if not accepted in writing by Homeowner returned to Contractor within 6. PAYMENT r of a. Timely payment by the B sums due under this Contract is of owne The essence to this Contract. parties agree to the to the following schedule of payments; 1. Initial payment: $4,500 (due at time of Contract signing). 2. Progress payments: leted The Homeowner will sit ill ly for Homeowonerthe rk cw Ilpbe applied d to the final h the end of that week. The depo paid by the invoice. 3,000 Demolition Complete 1,500 Shower Framing Complete 1,200 Shower Pan Installed 2,350 Rough Plumbing Completed 1,300 Finish Plumbing completed 2,000 Floor Tile Completed 2,000 Shower the Completed 3. Final payment: $1,500 Due at the completion of the project. The Contractor shall provide the Homeowner with hisown s paymenaiver tr cumulative subcontractors' waivers equal to the amount paid for any progressdoes not eowner as required herein b. The Contractor may cease operation cath to collif the Hom ect any balance due with any legal make any progress payment, and p remedy. Alternatively, the Contractor may continue operations, as set forth in the attached. 7. SIGNATURE the Attached hereto as EXHIBIT I are General Conditionsffurther subject o the' dobligations laws of Massachusetts the parties to this Contract. The parties a governing contracts and mechanics'ale s,arty of the acknowledge o dge the herright of the Contractor to place a lien or security interest on t property IN WITNESS WHEREOF, we have hereunto set our hands and seats this 3 day of �J r , 20 r__(____-- DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES Homeowner(s) Contractor Homeowner(s) -= EXHIBIT I GENERAL CONDITIONS These General Conditions are part of the Contract between Chris and Becky Sullivan ("Homeowner") and Red Apple Renovations, Inc. ("Contractor") for work at 171 Kara Drive, North Andover, MA 01845, dated June 21, 2006. 1. CONTRACTOR'S DUTIES — GENERAL a. To direct and control the work contracted for in accordance with the terms of this Contract and all applicable codes, laws, and regulations, and as the building permits, if any, issued for this project require. b. To inspect the site, examine the plans and specifications, if any, and supervise all of Contractor's employees, and to direct the work of all subcontractors selected by Contractor. c. To maintain the work site in a safe and clean condition, to the extent consistent with the Contract. The worksite will be left in a"broom clean" condition at the end of each day. d. To advise the Homeowner promptly if concealed conditions are ascertained which require additional or different work, and to proceed in such event in accordance with this agreement. 2. HOMEOWNER'S DUTIES — GENERAL a. To provide adequate utilities for the work agreed upon. b. To advise the Contractor of any condition of the property which affects Contractor's ability to perform. c. To provide secure storage areas for materials delivered to the work site. d. To execute in a timely manner all permit applications and other documents necessary for the work to proceed as identified by the contractor. e. To perform no work on the project without a written agreement with the Contractor. f. To avoid interfering with workers. g. To make no agreements with any tradesperson, subcontractor, or Contractor's employee outside the scope of this Contract without the written consent of the Contractor. h. Homeowner shall notify his insurance agent of the execution of this Contract and obtain any necessary Riders to his current coverage or any locally customary forms of coverage, such as Builder's Risk, to cover Homeowner's interests and liabilities during the construction process. 3. DELAY Contractor shall not be responsible for delays caused by events beyond the control of the Contractor, including but not limited to: strikes, war, acts of God, riots, governmental regulations and restrictions. Delays caused by Homeowner's failure to make allowance materials' selections or caused by the performance by Contractor of additional or necessary work shall likewise be excusable delays. CC to Homeowner and demand payment for all completed work and materials ordered through the date of work stoppage, and any other loss sustained by Contractor, including the balance of the Contract. Thereafter, Contractor is relieved from all other contractual duties. Upon such termination, the Contractor shall have all remedies provided by law, including such lien rights as then apply. The Homeowner may terminate this Contract upon the following conditions: a. Any other failure on the part of the contractor to perform this Contract required by the terms of this Contract. b. No termination shall be effective unless 10 days notice of Homeowner's intent are given as provided below, during which time the default may be cured by the Contractor. 9. DISPUTE RESOLUTION AND ATTORNEYS' FEES a. Dispute Resolution. The Contractor and the Homeowner hereby mutually agree in advance that in the event that either party has a dispute concerning this contract, either party may submit such dispute to a private arbitration service which has been approved by the Office of Consumer Affairs and Business Regulation and the consumer shall be required to submit to such arbitration as provided in M.G.L. c. 142A. Contractor: Homeowner: Homeowner: NOTICE: The signatures of the parties above apply only to the agreement of the parties to alternate dispute resolution initiated by the Contractor. The Homeowner may initiate alternative dispute resolution even where this section is not signed separately by the parties. b. Small Claims Court. Any controversy or claim arising out of or related to this Contract involving an amount of less than $2,500.00 (or the maximum limit of the court) must be heard in the Small Claims Division of the District Court in Essex County. c. Attorneys' Fees. In the event of any litigation between the parties relating to this Contract, the party against whom any adverse final judgment is entered (as specifically determined by the Court), following the expiration or exhaustion of all appeals, shall reimburse the other party for such party's costs and expenses (including, without limitation, all reasonable attorneys' fees, expenses and disbursements) of such litigation. d. Inquiries Regarding Contractor. All home improvement contractors and subcontractors shall be registered and that any inquiries regarding a contractor or subcontractor relating to a registration should be directed to: NOTICE OF CANCELLATION You may cancel this Contract, without penalty or obligation, within three (3) business days from the date this Contract is fully executed. If you cancel, any property traded in, any payments made by you under the Contract, and any negotiable instruments executed by you will be returned within ten (10) business days following receipt by the Contractor of your Cancellation Notice, and any security interest arising out of the Contract will be cancelled. If you cancel, you must make available to the Contractor at your residence, in substantially as good condition as when received, any goods delivered to you under this Contract; or you may, if you wish, comply with the instructions of the Contractor regarding the return shipment of the goods at the Contractor's expense and risk. If you do make the goods available to the Contractor and the Contractor does not pick them up within twenty (20) days of the date of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the Contractor, or if you agree to return the goods to the Contractor and fail to do so, then you remain liable for performance of all obligations of the Contract. To cancel the Contract, mail or deliver a signed or dated copy of this Cancellation Notice or any other written notice, or send a telegram to RED APPLE RENOVATIONS at 9 BARTLET STREET, #332, ANDOVER, MASSACHUSETTS 01810 not later than midnight of the third (3rd) business day after the execution of the Contract. I HEREBY CANCEL THIS CONTRACT. Date: Homeowner: i RED APPLE RENOVATIONS honi!' Exhibit II The Project Remodel Master Bathroom This project involves remodeling the existing master bathroom within the existing footprint. The renovation of the master bathroom would include the following: n.: The existing shower will be removed and replaced. The the walls, floor and ceiling of the existing shower will be removed. A new custom shower pan will be installed. A vapor barrier will be installed over the framing and then 1/2 inch cement board will be installed to provide a solid base for the tile. The following tile will be installed in the new shower: Type Manufacturer Model Number Description Shower wall tile BT:Austin 20131141 OA3900002 Bronce 10x16 (15 pc AZUAUBRIO16 per package) Shower border tile BT: Kenitra 20331550OK0501002 Bronce 2.6 x 10 Listel AZUKEBR310 Shower bullnose tile BT:Austin 20331269OA3910003 Bronce pressed AZUAUBRBN bullnose 3 x 10 Shower floor tile BT: Satin to AOTD1222 Almond 2x2 GRPI The design of the shower will be based on the sketch attached as Exhibit III. n' A single corner bench will be installed. The ceiling of the shower will also be tiled. This proposal includes an allowance of $250 for a new shower door. `' A new recessed light fixture will be installed in the shower ceiling. Based on the water damage around the shower, there may be some damage to wall or floor framing underneath the shower tile. Once the tile is removed, the framing will be examined to determine if any repair is required. If repair is needed, the homeowner will approve any repairs before they are done. Any additional repairs required are not included in this contract. n The existing tile floor and baseboard molding in the bathroom and toilet closet will be removed. The floor will be covered with ceramic tile installed over 1/4 inch cement board. All of the installed the will be grouted and the grout will be sealed. The following the will be installed on the floor of the bathroom in a grid pattern: T e Manufacturer Model Number Descri tion Floor the BT: Austin 202511720A3900003 Bronce 12.6 x 12.6 AZUAUBR13P Porcelain The existing tub will remain in place. The area above the tub deck approximately 18 inches up the wall will be tiled. The wallboard in this area will be removed and replaced with 1/2 inch cement board to provide a stable surface for the the installation. The following tile will be installed on the wall around the tub approximately 18 inches high: T e Manufacturer Model Number Description Whirlpool BT: Austin 203511720A3935006 Br 6 x 12 6 Mosance 4x4 ic backsplash tile AZUAUBR44 mounted The following new fixtures will be installed: T e Model Number Descri tion Shower Fixture 28.179.000 To 4 Hand shower Shower Fixture 28.417.000 59 inch shower hose Shower Fixture 28.401.000 Ad ust handle:shower Mower Fixture 26.409-000 00 0 Walt Union:shower S ' Shower Fixture 28.275.000 Showerhead shower arm Shower Fixture 27.412.000 Volume control: Shower Fixture 29.358.000 shower 1A inch t 2 Shower Fixture 19.614.000 Trim: shower Shower Fixture 34.122.000 Valve: shower RED APPLE RENOVATIONS l�nrtrr rru,url�lli�l;; j�rr.,�i•.�.�irriri.l.� Exhibit III Master Bathroom Renovation •1. } Z [ f IaA r� 1x H; 9 Bartlet Street#332,Andover,MA 01810 tel: 978.409.1293 fax: 978.945.2446 BOg6tp p!cE1IAS C(3lVST£313GT1f ,:SCIF'viftS.OR ��date T(3/2`$fT,g� Tx.DO: 83511 CHfiiSTOPk#Efi.J,.MATEY . 32 k AS} NGTF AVE r- A�VaOYEFi A311 0181 ;`i Adnin�stratcr HOWE INSURANCE Fax:9784752171 Jun 2 2406 9:13 P.02 i CORD m CERTIFICATE of LIABILITY INSURANCEmmm 06(0212006THE HOWE iNSURANG (979)4TE G Fax:(87B)e18 2171 ! THIS CERTIFICATE Is ISSUED A9 A MATTER OF INFORMATION AGENCY ONLY AND CONFERS Nb RIOWS UPON THE CERTIFICATE 4 ANDOVER MA HOLOGR. THIS CERTMATE DAM NUT AMEND, BXTESID OR ANDOVER MA 01810 L ALTER 1"I 9933ME AFFOROW BY THE M. 0 NUM om By INSIUMM AI°FOMINev COVERAGE MAIC# INSURED INSURER A: Nodonal Granov Mutual RED APPLE RENOYATIONB INC INSURER S: Commerce Insurance Co 32 WASHINGTON AVENUE ANDOVER MA 01810 INSURER Q granite 5tete Nlsuranu;a Compa INSURER M •- THE i POLIOUS OF INBIIRA ME USTEO BELOW HAVE tS TO THE MUM ksAft ABOVEFOR ANY REQUIREMENT,TERM OR CONDITION OF ANY WffPW 9R gnio OOWmmr WRIT I b N TMSTANOING MAY PERTAIty TNfi INSURANCfi AFIiaRpBp By THE pOL D Ii H IN IS SUBJECT TO ALIT ICATE" DE 138UEp OR PDUClE3.AGGREGATE LIMITS SIIt141h1 MAY NAVI; AE4UCEo 6Y PAID CLAIMS TFJTAAS EC4LU610N9 AND OONOITION3 OF SUCH NSR IT*I TYPE OF INSURANCE PONCYNVIlIM �flmllfpwm b�leutAl.GIA8IUTY LIMITS ' i26�e 08t25m7 H S 1 000 X COMMERCIAL GENERAL LIABILITY INCE G(AIMS WDEFX WGUR PReMSBS °°01a'� s x,000 A MSO E7�(AIT Dna aelsvlli i 101000 PEr�94NAl3AtnYINauRY 9 1,000,000 'TE LMITavr PS $GENLAGGREGATE 2,000 000 POLLCIf LOC PRooum94OMPPDPAQ% i 2,000,000 AUTOMOSU UANUTY 08MMNHNT24 10/13/OS 10/18106 ANY AVM j (OOMaINED'INME UMIT i ALL OWNED AUTOS i X 80ON.Y INJURY B s eow.co alrros (Pwr ) S 250,000 X HIREDAUTOS , X NON-OWNED AUM fNJURY i DOOILY(Far Aam i PROPERry W NA4150000,,00000GARAGE UABUTY A ONLY-EAACCDENTANpip 0 i OT►IERTtiAN EI,Ax s AUTO ONLY: A� S -- •. F SIUMBMLAUAINUTY WH ORZCURRENCE OCCUR D CWM8 MALIE i AGGREGATE i OEDUCTIBLE i RETENTION j WORKLMCOMPIINSATIONAND EMPLOYERS!LIABILITY WC87461t18 06/08/08 08f08/OT ill 01MEn ARYPPAFWM APAMWOMOMOVIAPE EJ-EACH ACCIDENT i 100,000 . 6 L OISEASEEwxor� $ 100,000 OTHM, -O�EAS�Pgd.1CYLiMTT $ 500,000 --- i DESCRIPTION OF CIPERATKINSILOCATIONNMICL SS/EXCLUSIOK ADDED BY EN DORS A$MT/SI CIAL PROVISIONS CERTIfiTB HOLDER I CANCELtA7WN ICED APPLE T RENOVATION ! SNOULO ANY Op TME ABOVE DESCRIBE)POLICIES BE 32 WASHINGTON�1VPJVUE 004RAYION DATE TFIF.RBW CET IED BEFORE TNR AN THE 5UU1A INSURER WILLGNMVORTO MAIL70 0AY8 DCY6R,MA 0191b WRITTEN NOTICE TO TMfi CERTIPM�q 1 HOLDER NWEO BUT WR8 S#gw IMP086 NOOOLIdAT4pw Ma f MJMn OF ANY rpNp up�om-mm jm VRM1. t S�AGENT90gk6arisgENrATNE$. i i AUTNORIZfD AVE 4 Atterrtion: 97580.2" f/ ACORD 26(2m/") I Ouis Cerfificabe}# 1801 18 ACORD CORpgRAnON 1988 The Commonwealth of Massachusetts Depaninent of Industriall Accidents (^i Office of Investigations d 600 Washington Street Boston, MA 02.111 uwiv.nlass.govIdla Workers' Compensation Insurance Affidavit: Build ers/Contractors/El ectricia us/Plumbers _Applicant Information Please Print Le E:ibly fi n r��oyatt�yr s ►`( Name (Business/Organization/individual): Address: City/State/Zip: �—r�cn of Phone #: - � Are you an employer? Check the-appropriate box: Type of project(required)-. 1. I am a employer with 15- 4- F1 am a general contractor and I 6. El New construction employees (full and/or part-time).* have hired the sub contractors 2.❑ I am a sole proprietor or partner- listed on the attached sheet. t 7. PVRemodeling ship and have no employees These sub-contractors have 8. ❑ Demolition working for mein any capacity. workers' comp. insurance. 9. ❑ Building addition [No workers'comp. insurance 5- ❑ We are a corporation and its • 10.❑ Electrical repairs or additions required.] officers have.exercised their Tight of exem tion' er MGL 11.0 Plumbing repairs or additions 3.El am a homeowner doing all workp 'p myself. [No workers' comp. c. 152,§1(4), and we have no 12.0 Roof repairs insurance required.) t employees. [No workers 13.El Other camp.insurance required.] ;Any applicant that checks box It 1 must also fill out the section below showing their workers'compensation policy information: t Homeowners who submit this affidavit indicating they are doing all work and then hire;outside contractors must submit a new affidavit indicating such. tContractors that check this box must attached an additional sheet showing the name of the sub-contractors and their workers'comp.policy information. I an: an employer that is providing workers'compensation insurance-for my employees. Below is the.policy and job site information_ Insurance Company Name: C S '` � G f � � � Policy#or Self-ins. Lic. #: C s14: CF t Expiration Date: (04-10-7 i I `� Sob Site Address: 1'-I \ X-arl, City/State/tip: Attach a copy of the workers' compensation policy declaration page(showing the policy number and expiration date). Failtue to secure coverage as required under Section 25A of MGL c. 1!52 can lead to the imposition of crirninal penalties of a fine up to$1,500.00 and/or one-year imprisonment, as well as civil penalties in the form of a STOP WORK ORDER and a fine of up to $250.00 a day against-the violator:-Be advised that a copy of this statement may be forwarded to the Office of Investigations of the DIA for insuxance coverage verification. I do hereby cert' urt er the pains and penalties of perjury that the information provided above is true and correct r « G Signature: Date: Phone# Official use only. Do not write in this area, to be completed by city or town official. City or Town: Permi�Liceuse# I Issuing Authority (circle one): 1.Board of Health 2.Building Department 3. City/Town Clerk 4.Electrical Inspector 5. Plumbing Inspector 6. Other Contact Person: I Phone#- I t � F NORTH omm Of 4Andover No. = dover, Mass.,,T� COCHICHEWICK 11 ADRATED C5 S BOARD OF HEALTH PERMIT T D Food/Kitchen Septic System * � BUILDING INSPECTOR THISCERTIFIES THAT........ ....... R. .......4.11.5 .t. . .........................................................�............... Foundation tA has permission to erect........................................ buildi s on .....�.1...I..........�. ......... ............................ Rough to be occupied as-MAN �. llow *. ......................................... Chimney .�� .... ......... ... provided that the person accepting this permit shall in every respect conform to the terms of the application on file in Final this office, and to the provisions of the Codes and By-Laws relating to the Inspection, Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR VIOLATION of the Zoning or Building Regulations Voids this Permit. Rough Final PERMIT EXPIRES IN 6 MONTHS ELECTRICAL INSPECTOR UNLESS CONSTRUC ST S Rough .. . ................ ................................................... Service BUILDING INSPECTOR Final Occupancy Permit Required to Occupy Building GAS INSPECTOR Display in a Conspicuous Place on the Premises — Do Not Remove RoughFinal No Lathing or Dry Wall To Be Done FIRE DEPARTMENT Until Inspected and Approved by the Building Inspector. Burner Street No. SEE REVERSE SIDE Smoke Det.