Loading...
HomeMy WebLinkAboutBuilding Permit #623 - 258 BRIDGES LANE 5/14/2009BUILDING PERMITr. D b�tio TOWN OF NORTH ANDOVER c2 b.'''. ` ~'.'° o� APPLICATION FOR PLAN EXAMINATION '' O 7° o Permit NO: �� Date Received ��SSACH15 �� Date Issued:' IMPORTANT: Applicant must complete all items on this page LOCATION r .QS LQ-Kf_:, Print PROPERTY OWNER Pent MAP NO: LoDPARCEL: ZONING DISTRICT: Historic District yes no Machine Shop Village yes no TYPE OF IMPROVEMENT PROPOSED USE V �tq Phone: 211 1:a—yo— � -q Residential Non- Residential New Buildinga famil Additi Two or more family Industrial Iteration No. of units: Commercial Repair, replacement Assessory Bldg Others: Demolition Other Septic Well Floodplain Wetlands Watershed District Water/Sewer DESCRIPTION OF WORK TO BE PREFORMED: �2 e\,-f,o6eA V; C�e o, OWNER: Name `n Identification Please Type or Print Clearly) �1- `C1Ur e eve griga lLlfT(n Address: QJ� s,tAts L'one.... CONTRACTOR 'Name: C M s V �tq Phone: 211 1:a—yo— � -q Address: kal "Z 1W O- Y\ r Supervisor's Construction License: S o� �jJ� Exp. Date: I C) a l o/ C Home Improvement License: Exp. Date: a) as 1.aoll ARCHITECT/ENGINEER Phone: Address: Reg. No. (* FEE SCHEDULE: BULDING PERMIT. $12.00 PER $1000.00 OF THE TOTAL ESTIMATED COST BASED ON $125.00 PSR S.F. Total Project Cost: $ Jam) FEE: $_ Check No.: "7 �( Receipt No.: NOTE: Persons contracting . u egistered contractors do not have access to the guaranty fund Signature of Agent�Owner' Signature of contractor --- CABICO FULL OVERLAY FRAMED DOOR SME 615/6/D MAPLE WITH PORCELAIN FINISH FOR ALL CABINETS CEILING HEIGHT 90" HANGING HEIGHT 84" CLOSED SOFFIT DM/CRW15S8 FOR CROWN MOLDING DM/SHA01 S8 FOR FASCIA DM/ACT02S8 FOR LIGHT VALANCE WITH PLYWOOD CONSTRUCTION FOR ALL CABINETS PLAIN SIDES FOR ALL EXPOSED ENDS OF CABINETS WITH UPGRADED DRAWER FRONTS CENTER PANELS TO BE SOLID WOOD CUSTOMER TO SIGN OFF ON WAIVER 1 -BASE FARM SINK CABINET WHITEHAUS COLLECTION MODEL 0 WHNCMAP3321 WITH MB201B FRONT FLUSH TOEKICK AND FLUTED EXTENDED CLIPPED FILLERS ON EACH SIDE AND CABINETS 27" DEEP 2 -BASE COOKTOP CABINET 27' DEEP WITH FLUTED ANGLED FILLERS ON EITHER SIDE COOKTOP MODEL GE PROFILE # PHP 960DM DOWNDRAFT GE MONOGRAM MODEL #ZVBMH WITH FRONT FLUSH TOEKICK MB2018 CABINET WILL HAVE TWO DOORS 3 -BASE CORNER CABINET WITH DOORS THAT REVOLVE INSIDE THE CABINET DOORS FOR THIS CABINET WILL NOT BE FULL OVERLAY 232{" 33' 65{• 33" 1014• 60" 394" 77{•20" �69}"� 31{^ B{^�36"� '�21" 87413' 4 -TALL OVEN CABINET WITH GE MONOGRAM WARMING DRAWER MODEL #ZTD910BF/SF/WF WITH GE MONOGRAM SINGLE OVEN ABOVE MODEL#ZETI RMSS WITH GE MONOGRAM ADVANITIUM OVEN ABOVE MODEL # ZSC1201 NSS WITH THREE TRAY DIVIDERS ON THE LEFT SIDE EQUALLY SPACED &REFRIGERATOR JENWAIR JCB2287KEY REFRIGERATOR SPACE LEFT 36' X 73" CABINET SPECIAL HEIGHT 11" 6 -TALL CABINETS WITH THREE DRAWERS BELOW AND TWO DOORS ABOVE WITH ADJUSTABLE SHELVING ABOVE SPECIAL HEIGHT 78' HIGH WITH CROWN MOLDING ONLY OPEN SOFFIT ABOVE WITH VALANCE AT TOEKICK TO BE INSTALLED ON-SITE SPECIAL DIMENSION 18" DEEP 7 -WOOD UTENSIL ORGANIZER IN TOP DRAWER THREE DRAWER BASE 8 -HALF WALL TO BE BUILT ON -SITE BY CONTRACTOR JACKSON KITCHEN DESIGNS NOT PROVIDING FINISH MATERIAL FOR BACK OF HALF WALL 9-13ASE CABINET WITH FULL HEIGHT DOOR AND WOODEN TRAY DIVIDER CENTERED IN CABINET 10 -BASE CABINET WITH TOP DRAWER AND DOUBLE ROLLOUT TRAYS 11 -WOODEN UTENSIL ORGANIZER IN TO DRAWER W3330 i �� I i it I . �i 24.DISHW 83D21 3 O7 1 O O O 0 0 O m i O EPOISP24841518 10 _ -- 1 SFO1S3X78.5 91Z@ TMSOZ3384 fF W361124 W2730B � © 1 All dimensions _size designations given are subject to verification on job site and adjustment to fit job conditions. JESSICA ZAPPALA JACKSON KITCHEN DESIGNS This is an original design and must not be released or copied unless applicable fee has been paid or job order placed. Designed: 4/30/2009 Printed: 5/11/2009 MAGAURAN FINAL FINAL All Drawing #: 1 r RED APPLE RENOVATIONS 111)Mr tY�fl�rx�r�i�?1r -Pro /r.s�reII?+els Construction Contract This construction contract (the "Contract") dated "I is by and between the following homeowner(s) and contractor: Homeowner(s): Property address City, State, Zip Contractor: Representative: Street Telephone Federal Identification Number: Massachusetts License Numbers: Construction Supervisor Home Improvement Maureen Magauran & Patrick Hanks 258 Bridges Lane North Andover, MA 01845 Red Apple Renovations, Inc. Chris Matey, President 9 Bartlet Street, #332 Andover, MA 01810 978.409.1293 56-2309042 CS 083511 138132 1. GENERAL In consideration of the mutual promises contained herein, Contractor agrees to perform the following work: furnish all labor, materials, tools, equipment, and supervision to construct or renovate the Homeowner's residence according to this Contract and the following documents (collectively with this Contract, the "Contract Documents"). The project is generally described as Remodel the Kitchen and Dining Room (the "Project"). The Contract consists of this document, Exhibit I - General Conditions, and Exhibit II - the Project. Change orders and modifications shall be in writing and shall become part of this Contract. 2. PRICE The total projected price for the work agreed upon is $81,000. Payment terms are set out below in Paragraph 6. 1 The Commonwealth of Massachusetts Department of Industrial Accidents Office of Investigations 600 MTashin; ton Street Boston, MA 02111 r , www.nzass gov1&a . Workers' Compensation Insurance Affidavit Builders/Contractors/Electricians/Plumbers Mficant 1n♦f'ATn Po+:nn - i k AMAL iLOtauI Nalne (Business/Organiza6an/Individual): Address: 32— City/State/Zip 2- City/State/Zip:NDOVer 1,7,¢ Phone #:. gra X09-/29 3 Are you an employer? Check the appropriate box: 1. I am a employer with __ 27 4. ❑ I am a general contractor and I L(full and/or part-time).* 2.[] am.a:sole proprietor or have Lured the sub -contractors listed partner. on the attached sheet i Ship and have no employees These sub -contractors have working for mein any capacity, [No workers' comp. insurance workers' comp. insurance. 5. ❑ Weare a corporation and its required.] 3. ❑ I ain a homeowner doing officers have exercised their all work right of exemption per MGL myself. [No•worker's' comp, c, 152, § 1(4), and we have no insurance required.] t .employees. [No workers' comp. insurance required.] Type of project (required): — 6. ❑ New construction 7. ❑ Remodeling 8. ❑ Demolition 9. ❑ Building addition 10.0 Electrical repairs or additions I l.❑ Plumbing repairs or additions 12.[] Roof rcpairs ME] Other 'Airy applicant that checks bm � I must also fill out the section below show.in their workers' from ? fiomeoatiotL wn6m who submit this afridavit indicating they are doing all work end �� hire outside contnutors mustpolitubm a new affidavit indicating suaiL tContractors that check this box mustached an additional shear showing. the name of the sub-contmetm and their workers' cin «. li„ .:_ r po � .�,fomLation. I ant an employer that isprovWMg workers' compensation insurance for ►try employees: Below is the policy and job site information. Insurance Company Name:_ 4/AZ/1 Policy # or Self -ins. Lic. #:_f f Expiration Date: e /8/ O Job Site Address:__ 25� 3�L1 ji(C / F r ` _ City/State2iP��t`�.�✓Dl�✓+�/l O ��1� Attach a copy of the workers' compensation policy declaration page (showing the policy number and expiration date), Failure to secure coverage as required under Section 25A of MGL c. 152 can lead to the impositi0r) of criminal penalties of a fine up to $1,500.00 and/or one-year imprisonment, as well as civil penalties in the farm of a STOP WORK ORDER and a fine of up to $250.00 a day against the violator. Be advised that a copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. 1 do hereby certify under the a d 'es of perjury that the information provided above is true and correct Si Lure. Date: s O Phone #: %28- �f3G- 036-V Ofj`JCW use only. Do not write in this area, to be completed by city or town ofeia[ City or Town: Permit/License # Issuing Authority (circle one): L Board of Health 2. Building Department 3. City/Towu Clerk 4. Electrical Inspector 5. Plumbing Inspector 6.Other �� Contact Person' Phone*: E9 * M O Z4 W w w w 0 z o a CLQ w a x O W a Fo w u o w°. a O., w° w�' U w w in w a°' w W x Gp o C/)cn v .c I- 0 m c c w O � C y O C O cy.3 C3 •d C ev ea m C CD o CD w3 "ID o is " = Q d CA op M p +r * o m c i. CL= CD N W o Z' 3 cm N > C � 'C •: C a m A 'O N W _ xCDC H m m �o CMZ m cv c Z 0Qo CDCD N C :a W C 10:5ui_ O r •N �dt O C CLW•E C2 'fl Gmi •N C.3 CD VD CL m� O:8 2 O SM == z sa4m J 0 IN 3. STARTING AND SUBSTANTIAL COMPLETION PROVISIONS The work will begin on or about ci . The work will be substantially completed on or about (c /: J L"C, . This project, once construction starts, is estimated to take eight to ten weeks to complete (exclusive of any punch list items). This time estimate, as well as the projected start date, is dependent upon some or all of the following variables: • Weather • Delays in the availability of materials required for the project. • Condition of materials once delivered to worksite. • Unforeseen conditions arising in the course of the project • Other delays as outlined in Section 3 Exhibit I of the contract. 4. SPECIFIC REQUIREMENTS FOR MATERIALS AND WORKMANSHIP a. This Contract will be completed by the Contractor in a good and workmanlike manner, using good quality materials. b. If applicable, the Contract price includes the allowances listed in the Contract Details Section. 5. EXPIRATION OF THIS CONTRACT This Contract will expire thirty (30) days after the date first written above if not accepted in writing by Homeowner and returned to Contractor within that time. & PAYMENT a. Timely payment by the Homeowner of all sums due under this Contract is of the essence to this Contract. The parties agree to the following schedule of payments: 1. Initial payment: $20,000 (due at time of Contract signing). 2. Progress payments: The Homeowner will be billed weekly for the work completed through the end of that week. The deposit paid by the Homeowner will be applied to the final invoice. Demolition complete 6,500 Rough electrical complete 6,500 Rough plumbing complete 6,500 Drywall installed and finished 6,500 Kitchen cabinets installed 7,000 Kitchen flooring installed 6,000 Finish electrical complete 5,000 Finish plumbing complete 4,000 Countertop installed 5,000 Floors Refinished 4,000 Trim installed and painting complete 2,000 3. Final payment: $2,000 Due at the completion of the project. The Contractor shall provide the Homeowner with his own waiver or cumulative subcontractors' waivers equal to the amount paid for any progress payment. b. The billing schedule is for the convenience of the homeowner and does not reflect the percentage of effort or actual work expended at the time of the payment. If for any reason the project should be discontinued during the construction process, the client will be for the actual work completed to date. . c. The Contractor may cease operations if the Homeowner as required herein does not make any progress payment, and proceed to collect any balance due with any legal remedy. Alternatively, the Contractor may continue operations, as set forth in the attached. 2 7. SIGNATURE Attached hereto as EXHIBIT I are General Conditions governing the rights and obligations of the parties to this Contract. The parties are further subject to the laws of Massachusetts governing contracts and mechanics' liens, and acknowledge the right of the Contractor to place a lien or security interest on the property of the Homeowner. JN WITNESS WHEREQF, we have hgreunto set our hands and seals this day of , 20 {` i DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES Homeowner(s). Homeowner(s) Contractor nn b The Homeowner may cancel this Contract if it has been signed by the Homeowner at a place other than the office of the Contractor, provided that the Homeowner notifies the Contractor in writing at the Contractor's office by ordinary mail, telegram or personal delivery, not later than the midnight of the third business day following the signing of the Contract. See attached Notice of Cancellation for further explanation of this right. 3 EXHIBIT I GENERAL CONDITIONS These General Conditions are part of the Contract between Maureen Magauran and Patrick Hanks ("Homeowner") and Red Apple Renovations, Inc. ("Contractor") for work at 258 Bridges Lane, North Andover, MA 01845, dated 1. CONTRACTOR'S DUTIES — GENERAL a. To direct and control the work contracted for in accordance with the terms of this Contract and all applicable codes, laws, and regulations, and as the building permits, if any, issued for this project require. b. To inspect the site, examine the plans and specifications, if any, and supervise all of Contractor's employees, and to direct the work of all subcontractors selected by Contractor. c. To maintain the work site in a safe and clean condition, to the extent consistent with the Contract. The worksite will be left in a "broom clean" condition. d. To advise the Homeowner promptly if concealed conditions are ascertained which require additional or different work, and to proceed in such event in accordance with this agreement. 2. HOMEOWNER'S DUTIES — GENERAL a. To provide adequate utilities for the work agreed upon. b. To advise the Contractor of any condition of the property that affects Contractor's ability to perform. c. To provide secure storage areas for materials delivered to the work site. d. To execute in a timely manner all permit applications and other documents necessary for the work to proceed. e. To perform no work on the project without a written agreement with the Contractor. f. To avoid interfering with workers. g. To make no agreements with any tradesperson, subcontractor, or Contractor's employee outside the scope of this Contract without the written consent of the Contractor. h. Homeowner shall notify his insurance agent of the execution of this Contract and obtain any necessary Riders to his current coverage or any locally customary forms of coverage, such as Builder's Risk, to cover Homeowner's interests and liabilities during the construction process. 3. DELAY Contractor shall not be responsible for delays caused by events beyond the control of the Contractor, including but not limited to: strikes, war, acts of God, riots, governmental regulations and restrictions. Delays caused by Homeowner's failure to make allowance materials' selections or caused by the performance by Contractor of additional or necessary work shall likewise be excusable delays. 4 4. PERMITS The contract will obtain the following permits: Town of North Andover Building Permit It is the obligation of the Contractor to secure such permits as the Homeowner's agent. Note: if the Homeowner secures its own permits or deals with unregistered contractors, the Homeowner is excluded from the Guaranty Fund provisions of MGL c. 142A. S. PREFERRED VENDOR CLAUSE Except where expressly permitted, all material and fixtures will be purchased by Red Apple Renovations. This is done to ensure that all materials are of the highest quality and that the vendors offer good customer support. If, for some reason, materials for the project are not purchased by Red Apple Renovations, the following conditions apply: a. Red Apple may at its discretion charge a handling fee to supervise the installation and coordination of these materials b. Any and all materials not purchased by Red Apple are excluded from the project warranty. 6. INSURANCE Contractor agrees to maintain all necessary forms of insurance to protect the Homeowner from liability for any occurrence arising from the performance of this Contract. Contractor agrees that he shall cover his own employees for worker's compensation and carry general liability, and that all forms of insurance carried hereunder shall be with reputable companies licensed to do business in this state. Homeowner agrees to carry full coverage on the subject property covering Homeowner's risk of loss during the construction period, together with all special forms required by reason of the performance of this Contract. 7. HIDDEN, CONCEALED and UNFORESEEABLE CONDITIONS The parties agree that in the event Contractor discovers a condition requiring an extra cost that they shall proceed as follows: The Contractor shall notify the Homeowner verbally at once to expedite agreement as to the charge to correct or cure such condition, and provide a written estimate as soon as practicable. The parties must agree to such extra charges, or agree to a resolution method, or this Contract may be canceled by either of them. For purposes of this section, a "hidden, concealed and unforeseeable condition" shall mean a condition not readily observable to a prudent contractor inspecting the subject property for the purpose of performing this Contract. S. WASTE REMOVAL CONTAINERS The project may require a dumpster to be located on the property. It is the owner's responsibility to provide a location and adequate access for a dumpster location. In some cases, a dumpster can damage the surface it is placed on. Dumpsters are generally placed on boards to minimize surface damage. Every effort is made to minimize any damage as a result of dumpster presence. The types of damage possible may include, but are not limited to, dead grass, gouges in the soil and scrapes or chips on asphalt or pavement. Unless expressly included in this contract, Red Apple is not responsible for the repair of this damage. 9. ADDITIONAL WORK Any additional work or materials desired by the Homeowner shall be agreed upon in writing and such extras shall become a part of this Contract. Unless otherwise agreed, any additional work shall be paid for as performed. Failure of the Homeowner to sign a change order shall not preclude recovery for same by Contractor, and acceptance of said additional work or materials shall be presumed, unless there is written notice to the contrary. Contractor shall advise Homeowner at the time of agreement on any additional work as to any additional time required to perform this Contract. 10. TERMINATION and CANCELLATION Contractor shall have the right to stop all work on the project and keep the job idle if payments are not made to Contractor in accordance with the payment schedule set forth above, or if Homeowner repeatedly fails or refuses to furnish Contractor with access to the job site or product selections or information necessary for the advancement of the work. Simultaneous with stopping work on the project, Contractor shall give Homeowner written notice of the nature of Homeowner's default. If work is stopped due to any of the above reasons (or for any other material breach of Contract by Homeowner) for a period of seven (7) days after notice, and the Homeowner has failed to cure the default, then Contractor may, without prejudicing any other remedies Contractor may have, give written notice of termination of the Contract to Homeowner and demand payment for all completed work and materials ordered through the date of work stoppage, and any other loss sustained by Contractor, including the balance of the Contract. Thereafter, Contractor is relieved from all other contractual duties. Upon such termination, the Contractor shall have all remedies provided by law, including such lien rights as then apply. The Homeowner may terminate this Contract upon the following conditions: a. Any other failure to perform this Contract required by the terms of this Contract. b. No termination shall be effective unless 10 days notice of Homeowner's intent are given as provided below, during which time the default may be cured by the Contractor. 11. DISPUTE RESOLUTION/AND ATTORNEYS' FEES i a. Dispute Resolutions je Contractor �tra he Homeown,�► hi;reby mutually agree in advance that in the Oent that the Cor hasa dispute c8cerning this contract, io� � die Contractor ma8/su mit such,ispute toga pri a arbitrat n service which has ben approved by the Of ice of Consumer Af a' and Busines R ulation and the consumer shall/be required th submit to su arbitration as pr,vided in M.G.L. c. 142A. Contractor. f Homeowner: / Homeowner: NOTICE: The signatures of the parties above apply only to the agreement of the parties to alternate dispute resolution initiated by the Contractor. The Homeowner may initiate alternative dispute resolution even where this section is not signed separately by the parties. b. Small Claims Court. Any controversy or claim arising out of or related to this Contract involving an amount of less than $2,500.00 (or the maximum limit of the court) must be heard in the Small Claims Division of the District Court in Essex County. c. Attorneys' Fees. In the event of any litigation between the parties relating to this Contract, the party against whom any adverse final judgment is entered (as N specifically determined by the Court), following the expiration or exhaustion of all appeals, shall reimburse the other party for such party's costs and expenses (including, without limitation, all reasonable attorneys' fees, expenses and disbursements) of such litigation. d. Inquiries Regarding Contractor. All home improvement contractors and subcontractors shall be registered and that any inquiries regarding a contractor or subcontractor relating to a registration should be directed to: Registration Division, Program Coordinator One Ashburton Place, Room 1301 Boston, MA 02108 Tel: (617) 727-3000 ext. 25239 12. WARRANTIES a. The work of the Contractor, including materials and labor, shall be guaranteed for a period of two (2) years during which period Contractor shall at its own expense correct any defect arising from its work unless Paragraph 7 of these General Conditions applies. This provision is in lieu of all other warranties, express or implied, and Homeowner has no action at law or in equity against the Homeowner after said date. b. Any and all warranties for appliances or mechanical systems shall be delivered to Homeowner when Contractor's final payment is received. c. Notwithstanding any manufacturer's warranty of any component, appliance, or system, no action may be brought against the Contractor on this contract, for the performance of this work, except as provided above. 13. NOTICES Notices may be sent to either party at the addresses shown above, or mailed by certified or registered mail. Any mailed notice shall be deemed given as of the date of mailing. 14. SEVERABILITY If any portion of this agreement is found invalid or unenforceable by any court, the remaining provisions shall remain in force between the parties. 15. ENTIRE AGREEMENT This Contract consists of the documents defined above, and constitutes the entire agreement of the parties. It can be modified only by a written document. 7 NOTICE OF CANCELLATION You may cancel this Contract, without penalty or obligation, within three (3) business days from the date this Contract is fully executed. If you cancel, any property traded in, any payments made by you under the Contract, and any negotiable instruments executed by you will be returned within ten (10) business days following receipt by the Contractor of your Cancellation Notice, and any security interest arising out of the Contract will be cancelled. If you cancel, you must make available to the Contractor at your residence, in substantially as good condition as when received, any goods delivered to you under this Contract; or you may, if you wish, comply with the instructions of the Contractor regarding the return shipment of the goods at the Contractor's expense and risk. If you do make the goods available to the Contractor and the Contractor does not pick them up within twenty (20) days of the date of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the Contractor, or if you agree to return the goods to the Contractor and fail to do so, then you remain liable for performance of all obligations .of the Contract. To cancel the Contract, mail or deliver a signed or dated copy of this Cancellation Notice or any other written notice, or send a telegram to RED APPLE RENOVATIONS at 9 BARTLET STREET, #332, ANDOVER, MASSACHUSETTS 01810 not later than midnight of the third (3rd) business day after the execution of the Contract. I HEREBY CANCEL THIS CONTRACT. Date: Homeowner: Note: Massachusetts State Law requires that all construction contracts include two copies of a cancellation notice. NOTICE OF CANCELLATION You may cancel this Contract, without penalty or obligation, within three (3) business days from the date this Contract is fully executed. If you cancel, any property traded in, any payments made by you under the Contract, and any negotiable instruments executed by you will be returned within ten (10) business days following receipt by the Contractor of your Cancellation Notice, and any security Interest arising out of the Contract will be cancelled. If you cancel, you must make available to the Contractor at your residence, in substantially as good condition as when received, any goods delivered to you under this Contract; or you may, if you wish, comply with the instructions of the Contractor regarding the return shipment of the goods at the Contractor's expense and risk. If you do make the goods available to the Contractor and the Contractor does not pick them up within twenty (20) days of the date of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the Contractor, or if you agree to return the goods to the Contractor and fail to do so, then you remain liable for performance of all obligations of the Contract. To cancel the Contract, mail or deliver a signed or dated copy of this Cancellation Notice or any other written notice, or send a telegram to RED APPLE RENOVATIONS at 9 BARTLET STREET, #332, ANDOVER, MASSACHUSETTS 01810 not later than midnight of the third (3rd) business day after the execution of the Contract. I HEREBY CANCEL THIS CONTRACT. Date: Homeowner: Note: Massachusetts State Law requires that all construction contracts include two copies of a cancellation notice. 17 RED APPLE RENOVATIONS llnrNl'!7'iNrr(✓`r'7fifti'�11'rr,I'.5�rri)7r,f.S Exhibit II- The Project The following work will be done: Overall Obtain all necessary permits and oversee all needed inspections. The job site would be broom clean at the end of each day. Demolition Install dust protection to separate the construction area from the rest of the house. Install floor protection as needed to protect the floor from the door to the construction area. Remove all .cabinets, countertops, fixtures and appliances from the kitchen. Remove the existing kitchen flooring down to the subfloor. Remove the wall between the kitchen and dining room. Remove the drywall from the kitchen and dining room walls and ceiling as needed. Properly dispose of all debris. Heating Install a kick space heater under the kitchen sink cabinet. Walls Patch the existing ceiling and walls as needed with interior drywall sanded and finished with three coats of joint compound sanded to a smooth finish. Skim coat the ceiling of the kitchen and dining room to a smooth finish. Doors & Windows Install anew door in the opening from the kitchen to the sunroom. The style of this door has not been determined, but options include a double French door, single t=rench door or a sliding door. 10 This contract includes an allowance of $2,500 for a new door. The actual cost of the door will depend on the unit selected by the homeowner. Install 5 new windows in the dining room. The type of window has not been selected, but this contract includes an allowance of $450 per window for five windows for a total window allowance of $2,250. This contract does not include the cost of moving any electrical, plumbing or mechanical wires or pipes that are found in the location of the new windows. If any mechanical systems are found in this area, the homeowner would approve the additional cost of relocating the systems prior to the work being done. Electrical and Lighting Install new lighting and outlets as indicated on the plan as well as required by code. This contract contains an allowance of $600 for new lighting fixtures. Remove and relocate any wires, outlets and switches located in the wall between the kitchen and dining room. Flooring Install 2 1/4 inch wide unfinished oak flooring in the kitchen to match the oak flooring in the dining room. Finish the new flooring in the kitchen and refinish the hardwood flooring in the dining room and living room. The floors will be sanded and finished with three coats of polyurethane. Cabinets and Countertop An allowance of $25,000 is included in this contract for the cost of cabinets. Install a new countertop. This contract contains an allowance of $6,500 for new countertop material. Appliances Install and vent new appliances as needed. This contract does not include the cost of new appliances. Plumbing Install a new sink and faucet. This contract contains an allowance of $1,800 for a new sink, faucet and garbage disposal. Walls and Trim Install new door, window and baseboard trim where needed. 11 Paint Paint all interior walls, ceilings and trim in the kitchen and dining room with two coats of primer and two coats of finish paint in color selected by the homeowner. Notes: 1) An allowance is an amount set aside in the contract when a specific item has not been specified. The actual cost of the item, once specified, will be included in the contract price. Homeowner Homeowner 12 Date Date 10 �la••:�chu•ctt. - DclrtiKmcnt ��t' t'uhlir �ut'rt� B�ru'd nt' Buil( im-, Rc�gulatiun. and Stand:u d� Construction Supervisor License License: CS 83511 Restricted to: 00 CHRISTOPHER J MATEY 32 WASHINGTON AVE ANDOVER, MA 01810 Expiration: 10/28/2010 ( ,uuni••nncr Tr: 4178 CHRIS MATEY 32 WASHINGTON AVE.�� ANDOVER, MA 01810 Administrator License or registration valid for individul use only before the expiration date. If found return to: Board of Building Regulations and Standards One Ashburton Place Rm 1301 Boston, Ma. 02108 a Not valid without signature :Te eammonweuld d/, i�aua�uaella Board of Building Regulations and Standards t '- HOME IMPROVEMENT CONTRACTOR Registration: 138132 Expiration: 2/20/2011 Tr# 279536 Type: Private Corporation RED APPLE RENOVATIONS, INC. CHRIS MATEY 32 WASHINGTON AVE.�� ANDOVER, MA 01810 Administrator License or registration valid for individul use only before the expiration date. If found return to: Board of Building Regulations and Standards One Ashburton Place Rm 1301 Boston, Ma. 02108 a Not valid without signature Location 6 (z 1E7-� S& No 6:1 3,13 Date TOWN OF NORTH ANDOVER Certificate of Occupancy $ qr�- Building/Frame Permit Fee $ Foundation Permit Fee $ Other Permit Fee $ TOTAL $ Check # -72%7 22U67 Building Inspector Location' No. Date 7 + TOWN OF NORTH ANDOVER Certificate of Occupancy $ Building/Frame Permit Fee $ Foundation Permit Fee CHU I t- , Other Permit.,Fee $ Sewer ConnectioR: Fee $ Water Connection Fee $ TOTAL $ Building Inspector C S' 3 5 Div. Public Works i a �Ia Y s 0 M m W ❑ < N W N_ m H a Q N a � of w W a0 m O m Z < Om J ~ ¢ O at 0 ° 0 Z 0 IL F O IO W W N m D N IL Z m m m o t 09 W d; r 0 0 Q Z IO a , Q 0 Z a� W m E W C < �. f ❑ z <❑ m t Z Z < � 0 O m m W w < W W ~ p Q Z U z z I N 0 0 4 JJ V I 16 z L m m z z 0 C < l! ❑ Z l7 0 Z L6~ IL 0 0 U. LL ' = 0 W N = m W { 7 0 N Z { Z 0 F o, J { m 1 U o I J W m o - J 0 H H � z 7 W 0 Z 0 f 0 H W J z 0LL F O t C F 0 U m C 0 U W W m J 3 0�w i U< J 0 0 m W r i l z < < m L � a w 0 W F l V F. L < 8 ` } Z_ Z_ Z W it U U U Z ❑ ❑ ❑ j O W Z Z Z 0 J J m ❑ m Z} A N m C° m O m❑❑ 0< Y 3 m M- C 4 C ILId O > I- x i 0I.- F 0 Uz U 0 U a K < 0 a 0 0 0 ❑ ►W- ; OO L< m m J; O C O m V z z z 1- W W 0 0 < A J W m,q J 0 0 0 m z z 0 C < l! ❑ Z l7 0 Z L6~ IL 0 0 U. LL ' = 0 W N = m H z W V < O W N rc W { 7 z N Z { Z 0 F o, J { m 1 U o I J W m o - J 0 H H � z 7 W 0 Z 0 f 0 H W J z 0LL F O t C F 0 U m C 0 U W W m J 3 0�w i U< J < Z 0 0 m W r i l z < < Z L � a w 0 W F l V F. L < ` Z_ Z_ Z W it U U U {i. ❑ ❑ ❑ j O W Z Z Z 0 J J m ❑ m m A N m C° m O m❑❑ 0< 3 m H z W V < O W N rc { N Z { Z 0 F o, J { m 1 U L 1 0 { � Z J W m in 0 H H � _� 0 m m W Z 0 Z O m �. O U U m U U W i w (A m O J J mW j 0 J J m W r i l 0 N m W W F l V F. ` m L L W H z W V < O W N rc X -IA V ti J J U H H � W 3 o o O U U Z X -IA Y.' f; '., r i �ytr Fz. 0 z a a a v A ) w° w°' U w ui �i O E CDL z o, O y � C I Ccm O•— y p •p 'E m m Z O.0 �3 -o Cc oa �a c arm cc C 40ccZ V y O C C c d .y O : O O Dq V Ci •nC Q C �cc 2 mor O a � 0 0 v o a. Ec mi :C.me E cc � m CD ... ,.. cm C C O Q TL Iwor : v m is � jz o ... C ` O d o� C Q _m C �+ O RC ry m t t � h IS E O E �+ Z o ca N -ca a��� g � h .0 2% 2 = . CL 32 �i O E CDL z o, O y � C I Ccm O•— y p •p 'E m m Z O.0 �3 -o Cc oa �a c arm cc C 40ccZ V y O C C c d .y O I' FORM U - LOT RELEASE FORM INSTRUCTIONS: This form is used to verify that all necessary approvals/permits from Boards and Departments having jurisdiction have been obtained. This does not relieve the applicant and/or landowner from compliance with any applicable local or state law, regulations or requirements. ****************Applicant fills out this section***************** APPLICANT: /� �1�— � Ae 5 il L` Phone LOCATION: Assessor's Map Number Parcel Subdivision Lot(s) Street R j C/ 4 ,L St. Number ,2 - ************************Official Use Only************************ RECOMME3WTI0NS OF OWN AGENTS: . Date Approved `7 Co se ation Admin strator Date Rejected Comments j (Ubj ` AD / Town Planner Comments Food Inspe^ctor-Health Septic Inspector -Health Comments Public Works - sewer/water connections - driveway permit Fire Department Received by Building Inspector Date Approved Date Rejected Date Approved Date Rejected Date Approved C� 0�7 7 Date Rejected MAY 2 7 697 Date 010 G 0 y � 'd O � U C C d ..•y W ft7 1 ~ � LOC W A m o Nocn o�Ny 9 _ ' p s 4a VQpi Nt O co f ~fy4mow N t, M . iC W 0 =Jq s r as va d' P. a rn o tr a 6 PSG H -.V•i .. -1V 0.7 p aik " L661 L Z AVW `\ 0' */v ,, i t, /V , Y - 4�-t- .) IP 80-r" / 0' */v ,, i t, /V , Off; #-C- .4 Y cc O 3 J J 2 a6 F- W CC W W co D W z Se (40)w00 pc c0 X40 NJLO LL t( LL W H � d� N 3w1 w 2 LOLO O I- W O � d I-Uio 4 . / ............. Date .. TOWN OF NORTH ANDOVER PERMIT FOR WIRING This certifies that ....................... ............................... has permission to perform ............................. wiring in the buildin .... ,gof ........... .......... .. ........................................................ North Andover, Mass. at ... c7l� .................... .... . ..... ...... . Fee7A5 ............. Lic. .... 7,1Z ......................... ELEcrRICAL INSPEcrOR Check # /-2 0 �- 5177 _ Commonwealg o/ /r/asaaclLtwelfs OCli = Use Only �. r; a1.Je�arfnrenl a��}ire �ervicae Permit No. Occupancy and Fee Checked BOARD OF FIRE PREVENTION REGUL/TINS Rev [ . 1 1/991 (leave blank) APPLICATION FOR PERMIT TO/PERFORM-ELECTRICAL 1iV0RK All work to be pertornted in accord:il11ice with tile Massachusetts Glcctrical code (i�1CC), X27 ChIR 12.00 (PLEASE PRINTININKORTYPE.-ILL/Nr'bR.11,11'1f til) llate: t9 � � � 2. City or 'Town of: ni � /� /,,j r�E�.� - / l / � � � To the hispector of 1 -Vires: IIy this application the undersigned gives notice o1 lits or cr intention to per(orm the elccn lent work described below. Location (Street �C Number) Owner or Tenant f %6 L1 17F1 h tr % t/ Telephone tNo. Owner's Address . r7 - Is this permit in conjunction Nvith n building permit? yes ❑ No L� (Check Appropriate Bos) 1'ut liose of Building r��tir �' Utility Authorization No. Existing Service Antes / 1'01ts Overhead ❑ Uttdgrd ❑ No. o(Aieters . Nev., Scrvicc Antps / Volts OverheadUnd_rQd (� `n Number of Feeders and Antpacity v Location and Nature of Proposed Electrical Work: Se Corr letiorr o%the follow, (able nrat, bc• halved by the hrs ecror• o%JVir•cs. No. of Recessed Fixtures No. of Ceil: Susp. (Paddle) Falls No. °t Total Transformers L"A No, of Lighting Outlets No. of I -lot Tubs Generators I\VA t No. of Lighting Fixtures Swimntittg Poul above ❑ In- t o, o cnerencv tg (ting rttd. rad. ❑ Battery Unitsg No. of Receptacle Outlets No. of Oil Burners FIRE ALARMS No. of Zoites 1� No. of Switches No. of Gas Burners No. of Detection and Initiating Devices No. of Ranges No. of Air Cond. ToTo -ns No. oCAlertittg Devices No. of Waste Disposers Heat Pump 1.Nuniber 'Pons _ KW __ No. of Self=Contained Totals: --" " Detectiott/Alertino Devices No. of Dishivaslters Space/Area Heating KW` Local ❑ i1lunieipal [I Other Connection No. of Dryers Heating Appliances Kli; Security Svstems: No. of NaterNo. of No. of No. of Devices or Equivalent Heaters KW Data Wiriug- Si,us Ballasts No. of Devices or Equivalent No. Hydromassage Bathtubs No. of tllotors Total HP 17elecontntunications W irutg: No. oC Devices or E uivalent OTHER: Attach additional detail if desired, or as required by the Inspector of Wires. INSURANCE COVERAGE: Unless waived by the owner, no permit for the performance of electrical work may issue unless the licensee provides proof of liability insurance including "completed operation" coverage or its substantial equivalent. 'I'lte undersigned certifies that such coverage is in force, and has exhibited proof of same to thepermit issuin. office. CHECK ONE: INSURANCE ET BOND ❑ OTI•}ER ❑ (Specify:) Estimated Value of Electrical Work: (When required by municipal policy.) (Expiration Date) Work to Start: Inspections to be requested in accordance with MEC Rule 10, and upon completion. I certif, utrder the pains and penalties of perjuiy, that the information on this application is trite and complete. FIRiN1NAIIE: Buddy Electric Inc LIC. NO.:12017__A Licensee: Vincent B. Danders JR Signature L1C.N0:. 23684 E (If applicable, enlcr ••erempl - in the license nwnber liue.) Bus. Tel: No.: 975 —4455 Address: 24 ('off ate lir Ti And�vpr Ma 01 45 V Alt. Tel. No.: OWNER'S INSURANCE WAIVER: I am aware that the Licensee does not have the liability insurance covera`o normally required by law. By illy signature below, I hereby waive this requirement. I atn the (check onc) ❑ owner ❑ owner's a�uent. Owner/Agent C1� Signature 'I'clephone No. [P:j:-_R:1:f:JTT FZ•E: S �� Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits ❑ Building Permit Application ❑ Workers Comp Affidavit ❑ Photo Copy Of H.I.C. And/Or C.S.L. Licenses ❑ Copy of Contract ❑ Floor Plan Or Proposed Interior Work ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit Addition Or Decks ❑ Building Permit Application ❑ Certified Surveyed Plot Plan ❑ Workers Comp Affidavit ❑ Photo Copy of H.I.C. And C.S.L. Licenses ❑ Copy Of Contract ❑ Floor/Crossection/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Mass check Energy Compliance Report (If Applicable) ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit New Construction (Single and Two Family) ❑ Building Permit Application ❑ Certified Proposed Plot Plan ❑ Photo of H.I.C. And C.S.L. Licenses ❑ Workers. Comp Affidavit ❑ Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Copy of Contract ❑ Mass check Energy Compliance Report ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit In all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals that the appeal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording must be submitted with the building application Doc: INSPECTIONAL SERVICES DEPARTMENT:BPFORM07 Revised 2.2008