Loading...
HomeMy WebLinkAboutBuilding Permit #043-13 - 31 ROYAL CREST DRIVE 7/19/2012 TOWN OF NORTH ANDOVER APPLICATION FOR PLAN EXAMINATION Permit NO: Date Received Date Issued: IMPORTANT:Applicant must complete all items on this page LOCATION Royal Crest BUILDING # Print PROPERTY OWNER AIMCO, Royal Crest Estates LLC UNIT# -� Print MAP NA V PARCEL:00 ZONING DISTRICT: Historic District yes no X Machine Shop Village yes no TYPE OF IMPROVEMENT PROPOSED USE Residential Non- Residential ❑ New Building ❑ One family ❑Addition ;, Two or more family ❑ Industrial ❑Alteration No. of units: /2- ❑ Commercial repair, replacement ❑Assessory Bldg ❑ Others: ❑ Demolition ❑ Other i p'SWelly ��filoodplain, DiVVetland's_I '�a0} WaterslieclDistnct� ❑Water/S ewers , DESCRIPTION OF WORK TO BE PERFORMED: 4? l9 &i4 h o O ,p•9 v 7-/..,j . (Identification Please Type or Print Clearly) OWNER: Name: 1�I M C-0 Phone: c178 6 gZ 7Zd� Address: C-P-eST DP-We /J OP7h r A�,OaVJ .o cul# , a ISJ�3 CONTRACTOR Name: Thomas H. Kinnal Phone: 978-360-0051 Address: 286 Broadway, Haverhill MA 01832 Supervisor's Construction License: CS 82747 Exp. Date: 6/20/201 Home Improvement License: Exp. Date: E ARCHITECT/ENGINEER Phone: Address: Reg. No. FEE SCHEDULE.BOLDING PERMIT:$12.00 PER$9000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost: $ O`�S FEE: $ , lel Check No.: a 2, Receipt No.:�2 NOTE: Persons contracting . S with u regi eyed contractors do not have access to the guarantyfund ,a ignatu�reiof�Ag &:(%7Wne�i.. :, _ w � ignature�of contiactorr:. Plans Submitted ❑ Plans Waived ❑ Certified Plot Plan ❑ Stamped Plans ❑ TYPE OF SEWERAGE DISPOSAL Public Sewer ❑- Tanning/Massage/Body Art ❑ Swimming Pools ❑ + Well ❑ Tobacco Sales ❑ Food Packaging/Sales D Private(septic tank,etc. ❑ Permanent Dumpster on Site ❑ THE FOLLOWING SECTIONS FOR OFFICE USE ONLY INTERDEPARTMENTAL SIGN OFF - U FORM DATE REJECTED DATE APPROVED 4 PLANNING & DEVELOPMENT ❑ ❑ COMMENTS I CONSERVATION Reviewed on Signature COMMENTS HEALTH Reviewed on Signature COMMENTS Zoning Board of Appeals:Variance, Petition No: Zoning Decision/receipt submitted yes Planning Board Decision: Comments Conservation Decision: Comments Water & Sewer Connection/Signature&Date Driveway Permit DPW Town Engineer: Signature: Located 384 Osgood Street FIRE DEPARTMENT - Temp Dumpster on site yes no Located at 124 Main Street - - Fire Department signature/date o COMMENTS Dimension Number of Stories: Total square feet of floor area, based on Exterior dimensions. Total land area, sq. ft.: ELECTRICAL: Movement of Meter location, mast or service drop requires approval of Electrical Inspector Yes No DANGER ZONE LITERATURE: Yes No MGL Chapter 166 Section 21A—F and G min.$100-$1000 fine NOTES and DATA— For department use ❑ Notified for pickup - Date Doc:.Building Permit Revised 2008mi I Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits ❑ Building Permit Application ❑ Workers Comp Affidavit ❑ Photo Copy Of H.I.C. And/Or C.S.L. Licenses ❑ Copy of Contract ❑ Floor Plan Or Proposed Interior Work ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit Addition Or Decks ❑ Building Permit Application ❑ Certified Surveyed Plot Plan ❑ Workers Comp Affidavit ❑ Photo Copy of H.I.C. And C.S.L. Licenses ❑ Copy Of Contract ❑ Floor/Crossection/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Mass check Energy Compliance Report (If Applicable) ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit New Construction (Single and Two Family) ❑ Building Permit Application ❑ Certified Proposed Plot Plan Li Photo of H.I.C. And C.S.L. Licenses ❑ Workers Comp Affidavit ❑ Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Copy of Contract ❑ Mass check Energy Compliance Report ❑ Engineering Affidavits for Engineered products VOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg .Permit Fn all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals :hat the appeal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording nust be submitted with the building application Doc: Doc.Building Permit Revised 2008mi V4ORTH Town of 2Andover No. -C% h ver, Mass,0 LAKE coc.ac«ew.cu �1 AERATED S Ll BOARD OF HEALTH L D PERRI Food/Kitchen Septic System THIS CERTIFIES THAT ...................... BUILDING INSPECTOR . Foundation ..................... has permission to erect .......................... buildings on ..........3.1..x.3............................................... Rough to be occupied as .., ......��er�y .. .. ........................................... Chimney provided that the person accepting this permit shall irespect conform to the terms of the application Final on file in this office, and to the provisions of the Codes and By-Laws relating to the Inspection, Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR VIOLATION of the Zoning or Building Regulations Voids this Permit. Rough Final PERMIT EXPIRES IN 6 MONTHS ELECTRICAL INSPECTOR UNLESS CONSTRUCTIOPPARTS Rough Service, ....................,. ...... ....:.................................... Final BUILDING INSPECTOR GAS INSPECTOR Occupancy Permit Required to Occupy Building Rough Display in a Conspicuous Place on the Premises - Do Not Remove Final No Lathing or Dry Wall To Be Done FIRE DEPARTMENT Until Inspected and Approved by the Building Inspector. Burner Street No. Smoke Det. SEE REVERSE SIDE NORT#1 Town of 2 _ ndover No. Y = h ver, Mass, ' lot ' C0CNIC"2WIC6t 1_ A0RgTED ►Pp�.(5 S U BOARD OF HEALTH T T D PER Food/Kitchen Septic System THIS CERTIFIES THATBUILDING INSPECTOR .. Foundation has permission to erect .......................... buildings on ..........3.1.......3............................................... Rough ldp to be occupied as .. ♦,�.....�... .... ..M�......��er�y .. .. .....................O.................... Chimney provided that the person accepting this permit shall respect conform to the terms of the application Final on file in this office, and to the provisions of the Codes and By-Laws relating to the Inspection,Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR VIOLATION of the Zoning or Building Regulations Voids this Permit. Rough Final . PERMIT EXPIRES IN 6 MONTHS ELECTRICAL INSPECTOR UNLESS CONSTRUCTIOPPARTS Rough ................ Service ...... Final BUILDING INSPECTOR GAS INSPECTOR Occupancy Permit Required to Occupy Building Rough Display in a Conspicuous Place on the Premises — Do Not Remove Final No Lathing or Dry Wall To Be Done FIRE DEPARTMENT Until Inspected and Approved by the Building Inspector. Burner Street No. Smoke Det. SEE REVERSE SIDE A�® CERTIFICATE OF LIABILITY INSURANCE 07/D�12MM/DDIYYYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACT Andrea Gallagher PRODUCER NAME: Fred C.Church,Inc. PHONE 978 3227172 FAX 978 4541865 41 Wellman Street Al No Ext: A/C No): Lowell,MA 01851 E-MAIL (800)225-1865 ADDRESS: agallagherQ(redcchurch.cem INSURER(S)AFFORDING COVERAGE NAIC# INSURER A: Peerless Insurance Company 24198 INSURED INSURER B: Thomas H Kinnal DBA East Coast General Contracting INSURER C: 286 Broadway INSURER D Haverhill,MA 01832-2908 - INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:21125 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ILTR TYPE OF INSURANCE �gR Syryyp POLICY NUMBER tNM%DD EFF MPM�ICY EXP LIMITS GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 X COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrence $ 100,000 CLAIMS-MADE Iq OCCUR MED EXP(Any one person) $ 5,000 A CBP8384091 2/15/2012 2!152013 PERSONAL&ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $ 2.000,000 POLICYF—IJECT L1 PRO- LOC $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 Ea accident $ ANY AUTO BODILY INJURY(Per person) $ A ALL TOO ED X SOS CHEDULED BA8382891 21132012 2/132013 BODILY INJURY(Per accident) $ HIRED AUTOS X NON-OWNED� OPE DAMAGE $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAR HCLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION WC STATU- OTH- TORY LIMITS ER AND EMPLOYERS'LIABILITY Y/N ANY PROPRIETOR/PARTNERlECECUTNE❑ NIA E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? (Mandatory In NH) E.L.DISEASE-EA EMPLOYE $ If yes describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (Attach ACORD 101,Additional Remarks Schedule,H more space is required) Property Name:Royal Crest Estates(North Andover) Contract No.:14549-404879-CP-00002 Coverage includes OWNER as Additional Insureds. CERTIFICATE HOLDER CANCELLATION AIMCO NORTH ANDOVER,L.LC. 50 Royal Crest Drive SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN North Andover,MA 01845 ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Cr.nt a Mst# Cert Holder# ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 26(2010105) The ACORD nam and logo are registered marks of ACORD A CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYW) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER FRED C CHURCH INC CONTACT NAME: CONNECTOR PARK 41 WELLMAN ST PHONE AIC No Ext): 978 458-1865 FAx A/C No): 978 454-1865 LOWELL, MA 01851 E-MAIL ADDRESS: INSURER(S)AFFORDING COVERAGE NAIC# INSURER A: Liberty Mutual Insurance INSURED INSURER B: THOMAS H KINNAL DBA EAST COAST GENERAL CONTRACTING INSURER C: 286 BROADWAY INSURER D: HAVERHILL MA 01832 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 13591924 REVISION NUMBER: THIS IS TOCERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE A DL SUBR POLICY EFF POLICY EXP LIMITS LTR D POLICY NUMBER MMIDD/YYYY MM/DD/YYYY GENERAL LIABILITY EACH OCCURRENCE $ DAMAGE TO RENTED COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) $ CLAIMS-MADE F-I OCCUR MED EXP(Any one person) $ PERSONAL&ADV INJURY $ GENERAL AGGREGATE $ GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG Is POLICY PRO- F-1 LOC $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ _ ANY AUTO BODILY INJURY(Per person) $ ALL OWNED 8 SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS NON-OWNED PROPERTY AMAGE AUTOS Per acciden HIRED AUTOS t $ $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB HCLAIMS-MADE AGGREGATE $ DED RETENTION$ $ A WORKERS COMPENSATION WC5-31S-353816-022 2/23/2012 2/23/2013WC STATU- OTH- AND EMPLOYERS'LIABILITY Y/N ✓ TORY LIMITS ER ANY PROPRIETOR/PARTNER/EXECUTIVE - E.L.EACH ACCIDENT $ 500000 OFFICERIMEMBER EXCLUDED? aY N/A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $ 500000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 500000 DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES (Attach ACORD 101,Additional Remarks Schedule,if more space is required) THE WORKERS COMPENSATION POLICY DOES NOT PROVIDE COVERAGE FOR THOMAS KINNAL Workers compensation insurance coverage applies only to the workers compensation laws of the state MA. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE AIMCO NORTH ANDOVER L.L.C. THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 50 ROYAL CREST DRIVE ACCORDANCE WITH THE POLICY PROVISIONS. NORTH ANDOVER MA 01845 AUTHORIZED REPRESENTATIVE LQCkAlco Ir. Jeff Eldridge ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010105) The ACORD name and logo are registered marks of ACORD CERT NO.: 13591924 Anne Chandler 7/13/2012 5:23:36 AM Page 1 of 1 This certificate cancels and supersedes ALL previously issued certificates. The Com wnweal'th o�`'Hassochusetts. Departmentoffkdustri I.AccSden& office oflmestiga dorrs 600 YPashhwffin Street .Bosto74 IWA 02111 Vww.maysgovIdra Worker$' compensation lnsmr'aurz Afadavit DIdNerdCoaixactors/E ciansffllmmbeZ A Zm �dce Name Sr 66�/�4 r �o dl 4�"fr.v 40 .Address: 6 V*per City/statemp: I-1� � �A� ©!$y Z- Phone Are van an employer?checkthe appropriate box: Type ofproject(regvj red): •11 am a employer wig_ _ 4. ❑1 am a general contractor and 1 6. []New eonstrvotion employees(fallmadJorpart tirlxe)�` hwehired the sub-confraetors 7 []Remodeling 2.[] 1 am a soleproprieetor orpa finer- HsWd on the attached sheet: ship andhave no employees These sub-ca*actors have 8. ❑Demolition workazNS forme is any cepacit : wo*ffe comp'insurance. g• ❑Building additum [No woAMW comp.fiasurar►ce S. [] We arta a corporation and its 1011 Bleddoal repairs or additions rargaired.1 officers have wwroised dick tia�npeurMCIL• 11.Q Pl rgmhs or additions 3.❑.1 am a bomeo finer doing allwork of a pand we have no 12•[1 Rcof repairs myself Wo workers'comp. 152,§2(4), a insurance xegnir'ed j t employees.[No workers 1311 Odwr comp.ins+nnrace d3 ',Any%Vtcantthat&cob kxt#lmustsi�filt outthosaction batawsbowia8ttanrwm3deas'�mga�i{oapolugrin�m�ion. ? wflo submtttWs e�davitindtce�n8�a9ffi0 doingail warts and 8smthtce outdo oamaaabarsmaatsnbmitsnewaffdavft�adi�n8 snob. #ConiraatarstLai ofleakttds GoxmQatattec>�an additionatehaetsLowingtiieaama o�the�andt�firwodaers'comp,poxiay3�rruation. I m an employerthat fspmvLwngworlaors°coz vmywon insraiancefornv mph' Below itstxiepo?YCjrand/ob state - 7nsuraztoe Companly Nsme: h___c___ z.�a 3 2 �!3 Poliay#or Self-ire.Lio.#: ail G ate- 3 S - 3.S3 S'!G� – Z Z . $ onDaire: Yob M Adirest: ,tea �1 �l2tsr 01 cry/stip: •�� . �l - e/may Attach a coP1r oftheworbwe compensatim polfcydeciaratiou page(showingthe policynumber and eVkatlou date). Foibue to secure oovemge as requiredmider$eodoon25A of MtOL.c.152 omleadto tha imposition ofmalpeneWw ofa fmo up to$1,500.00=Nor one-year ioa�as well as afvil penalties tithe$orm o£a STOP WORK QRDBR and a� ofup to$250.00 a day ainstIhS vIolatrnr. Be advised.that a copy ofthis atd eutxnayba foxv�mrdedto a Offtoe of ag ruvesapdons ofths DIA.for hummm coveirage veiffloation. I rro hereby certify under the pdns pwaffles ofyadhry that the tri,formattonprovideaYaboue Is true andcorrec>± oA7Zdarose on}y. Do not wrUefrr this area;to he completed by d&or town offal City or Town: Pexmft/1.fcerase# — ?ssuingAuthority(cfrcle one): L Board of Health 2.Building])epartment 3.City/Town Clerk 4.Mectried inspector 5 Emmbing Inspector 6 Other • ContsctPerson: . X'kone#: - ' ? Massachusetts - Department of Public Safety Board of Building Regulations and Standards j Cowaruction Supers icor License. CS-082747 :,. ' THOMAS H KINNAL t 286 BROADWAY= HAVERHILL MA 01832 Expiration Commissioner 06/20/2014 n i i A *1MC0 i To: Tom Kinnai at East Coast General Contracting From: MATULA, DAN, Executive Vice President Redevelopment&Construction Services ORGAN,TONY,Vice President of Construction,Construction Services STEICH,MATTHEW,Regional Manager of Construction,Construction Services Milinazzo, Dan, Project Manager,Construction Services Date: July 11,2012 Re: Executed Contract and Related Matters Attached is your copy of the executed contract with AIMCO NORTH ANDOVER, L.L.C., an affiliate of Apartment Investment and Management Company "Aimcol, for construction services at Royal Crest P 9 P ( Estates (North Andover). We want to take this opportunity to inform you that Aimco is committed to conducting its business in accordance with applicable taws, rules and regulations and the highest standards of business ethics. If during the period of your business relationship with Aimco,you believe the Aimco team members with whom you are dealing are not living up to these standards, we ask that you report such conduct to one of the following: • MATULA,DAN,Executive Vice President Redevelopment&Construction Services:(303)691-4547 • COHN,LISA, Executive Vice President and General Counsel:(303)691-4415 • HANSON,MIKE,Vice President—Internal Audit(303)691-4376 If you prefer to remain anonymous, you may make a report using Aimco's anonymous and confidential reporting system, MySafeWorkplace,which is available 24 hours a day,seven days a week via the Internet at www.MySafeWorkplace.com or by calling 1-886-481-7123.We encourage you to use MySafeWorkplace only if you do not feel comfortable reporting Issues directly to an Aimco representative. We would also like to remind you that Aimco has a Code of Business Conduct and Ethics,which prohibits Almco employees from accepting meals, entertainment, services or gifts from anyone who does business with Aimco unless the amount of such item is less than$25.AIMCO Construction Services has a$0 policy. This provision is to specifically include, but is not limited to, suppliers or other contracted labor utilized under this project. It is the responsibility of this Contractor to advise any subcontracts or suppliers of the AIMCO Code of Business Conduct and Ethics. Short Fonn,GC,Lump Sum,Contract,2-,JAN-12 1 of s GENERAL CONSTRUCTION SERVICES CONTRACT Contract Number.14549-404879-CP-00002 Contractor East Coast General Contracting prombf. Royal Crest Estates North Andover Address: 268 Broadway Street Location: 50 Royal Crest Drive Haverhill,MA 01823- North Andover;MA 1845 Representatim Tom IOnnal Issuing Office. AIMCO Regional Office Telephone: 978 360-0051 Address: Two Greenwood Square 3331 Street Road Facsimile: 978 372-4215 Bensalem,PA 19020 E-mat: tkinnalgDeorricastnet Contract Sum: $17,491.80 Contract Type. Lump Sum This General Construction Services Contract ('Contract") Is effective as of 7/11/12, by and between East Coast General Contracting ('CONTRACTORI and AIMCO NORTH ANDOVER,L.L.C. ('OWNER1 for construction and services to be performed andfor material to be suppled for the property known as Royal Crest Estates (North Andover) (the "Properly'). In consideration of the aoceptance of CONTRACTOR'S bid and/or proposal for furnishing supplies,goods and/or services to the Property and the mutual covenants and agreements set forth herein,the partes agree as follows: 1.0 WORK OF THIS CONTRACT 1.1 CONTRACTOR agrees to fully execute and perform the construction and services required by,and reasonably inferable from,the Contract Documents(as hereinafter defined)in connection with the Property,Including,but not limited to,the construction and services set forth in,and reasonably inferable from Exhibft'A'attached hereto(the'Workl:Unit Restoration. The"Contract Documents'consist of this Contract, Exhibits to the Contract(including the drawings,specifications or addenda referenced In Exhibit 1131,and any Change Orders executed after the execution of the Contract. CONTRACTOR acknowledges that the Work shall be perforated for the benefit of both OWNER and the beneficial owner of the Property(the"Property Owner"). The Work shat comply with all applicable federal,state and local lades and regulations,including, by way of Illustration and not limitation,the Americans with Disabilities Act,the Fair Housing Act and the Occupational Safety and Health Act(29 CFR)rLaws°). 1.2 CONTRACTOR accepts the relationship of trust and confidence established with OWNER by this Contract and covenants with OWNER to exercise the highest degree of skill,care and judgment in the performance of the Work hereunder and in furthering the interest of OWNER. 2.0 DATE OF COMMENCEMENT,CONSTRUCTION SCHEDULE,ACCELERATION AND LIQUIDATED DAMAGES 2.1 The date of commencement of the Work shall be the date set forth below,unless a different date Is set forth In a written Notice to Proceed issued by OWNER, In which case the date set forth in the Notice to Proceed shat.control (the Date of Commencemenr). CONTRACTOR shall achieve Final Completion of the Work no later than the Dale of Final Completion set forth below. 'Final Completion"or 'Finally Complete'shat mean the stage in the progress of the Work when the Work,or designated portion thereof,is,in OWNER's reasonable opinion,fully complete(including any punch list items)in accordance with the Contract Documents so that OWNER can occupy or utilize the Work for its intended use. Date of Commencement: 07/2312012 Date of Final Completion: 08/03/2012 2.2 CONTRACTOR shat prepare and submit to OWNER for approval a construction schedule(the'Construction Schedule)based on and consistent with the dates set forth above and any other OWNER requirements, Upon approval of the Construction Schedule shat become part of this Contract as Exhibit"D". TIME IS OF THE ESSENCE. The Work shall be perforned In strict accordance with the Construction Schedule,subject to any adjustments thereto in accordance wth the terms of this ContracL 2.3 if CONTRACTOR's rate of progress is such that the amount of Work completed within any time period specified by the Construction Schedule is less than the amount required to be completed within such time,and it reasonably appears that CONTRACTOR shall be unable to achieve the completion of the Work in accordance with the dates set forth In the Construction Schedule,OWNER may direct CONTRACTOR to accelerate the Work by issuing a notice to acceierate. Upon such notice,CONTRACTOR shall be obligated to employ such extraordinary measures as necessary to bring the Work Into conformity with the Construction Schedule and CONTRACTOR shall not be entitled to an increase in the Contract Sum. OWNER may also direct CONTRACTOR to accelerate the Work without cause by Issuing a written notice to CONTRACTOR requesting such acceleration. CONTRACTOR expressly agrees that its sole and exclusive remedy for such acceleration shall be an adjustment of the Contract Sum by Change Order (as hereinafter defined) in the amount of the costs incurred directly by the subcontractors as a result of the acceleration. 2.4 CONTRACTOR acknowledges that in the event that it fails to achieve Final Completion of the Work,or designated portions of the Work by the dates set forth in this Contract,OWNER will incur substantial damages and the extent of such damages shall be Incapable or very difficult of accurate measurement. Nonetheless,the parties acknowledge that as of the execution date of this Contract the amount of liquidated damages set forth in Exhibit"C'represents a good faith estimate on the part of the parties as to the actual damages that would be incurred as a result of late completion. The amount of such liquidated damages does not include any penalty. Liquidated damages will be assessed by OWNER when incurred or in such manner as OWNER deems appropriate, 3.0 COMPENSATION,PAYMENTS AND FINAL PAYMENT Short Form,GC,Lump Sum,Contract,2-JAN-12 2 of 6 3.1 OWNER will pay CONTRACTOR the Contract Sum In current funds for CONTRACTOWs full and faithful performance of the Work in accordance with the terms of the Contract. The Contract Sum shall be as set forth In Exhibit V,subject to additions and deletions as provided in the Contract Documents. 3.2 For the Work provided hereunder,CONTRACTOR agrees to provide OWNER with`Applications for Paymenr in the form attached hereto as Exhibit"E'or as otherwise directed by Owner, in writing. CONTRACTOR shall send each Application for Payment to the person(s)and locations)designated by OWNER. Based upon OWNER's review and approval of Applcations for Payment submitted to OWNER by CONTRACTOR for performance of the Work,OWNER will make payments as provided herein. The period covered by each Application for Payment shall be one calender month. CONTRACTOR shall submit Applications for Payment no more than once a calendar month. Owner will pay CONTRACTOR that amount set forth in the Application for Payment within 30 days after OWNER's receipt of an Application for Payment,less those amounts property withheld pursuant to the terms of this Contract. Owner may utilize any one of the following as a basis for rejecting,and requiring CONTRACTOR to resubmit,an Application for Payment:1)failure to specify the full contract number;11)failure to submit fug supporting documentation required by Paragraph 3.3;Iiq submission of an Application for Payment bearing a date that Is more than seven(7)days earlier than the date such Application for Payment is actually received by OWNER;or Iv)any other basis provided In this Contract. 3.3 Unless waived by OWNER in writng, CONTRACTOR agrees to provide waivers and releases of gens from CONTRACTOR, all subcontractors and suppliers of Work under this Contract(the"Release Documents)in the form attached hereto as Exhibit"E'and any other evidence in a form satisfactory to OWNER demonstrating that all labor,materials,bills, invoices, payroll taxes of any kind and any other indebtedness Incurred by CONTRACTOR up to and Including the date of Invoicing have been paid in full prior to or in exchange for payment to CONTRACTOR. If CONTRACTOR Is aware or becomes aware that the Release Documents are not effective under,or otherwise do not satisfy, the Laws and requirements of the state in which the Project Is located,it shelf be the responsibility of CONTRACTOR to notify OWNER and to provide the lien waivers and releases required hereunder on forms that satisfy the Laws and requirements of such state. Failure to notify OWNER where CONTRACTOR knew,or sharld have known,that the Release Documents were Inflective under,or otherwise failed to satisfy, the laws of the state in which the Project is located shall be a breach of this Contract and CONTRACTOR shag be gable for any damages incurred by OWNER as a result of such breach. 3.4 OWNER may withhold any payment,including the retainage,to CONTRACTOR,for CONTRACTOR's failure to fulfil Its contractual obligations in any manner(a"Disputed Amounf). OWNER may withhold such Disputed Amount until the dispute Is resolved by settlement, dispute resolution or judicial determination. However,both OWNER and CONTRACTOR shall use best efforts to resolve any such disputes expeditiously. CONTRACTOR shall continue to perform the Work through any dispute and shall not have the right to terminate performance under this Contract other than as provided In Paragraph S. 3.5 When the entire Work is Finally Complete In.accordance with this Contract,CONTRACTOR's subsequent Application for Payment shall be calculated to include a slap sufficient to increase the total payments to the full amount of the Contract Sum. 'Final Payment,consisting of all amounts actually remaining due CONTRACTOR pursuant to this Contract,will be made by OWNER not later than 30 days after CONTRACTOR has achieved Final Completion,has satisfied all requirements for Final Payment ad forth therein,and has submitted to OWNER the"Application for Payment. A precondition to CONTRACTOR's entitlement to Final Payment shall be the execution and delivery of final Release Documents. The acceptance of Final Payment shall constitute a waiver of all claims by CONTRACTOR against the Indemnified Parties (as defined in Paragraph 7.2),except insofar as CONTRACTOR has previously notified OWNER In writing. The making of Final Payment shall not constitute acceptance of the Work or of any goods or materials provided under the Contract nor shall it conte a waiver of any rights or claims of OWNER. 3.8 CONTRACTOR shall maintain books and records with respect to the Work to be provided hereunder and the fees to be paid hereunder. OWNER will,for a period of two(2)years after the expiration,completion or the termination of this Contract,have the right to review and audit the!rooks and records of CONTRACTOR with respect lo such Work and fees. The CONTRACTOR shell include a provision similar to this Paragraph 3.8 In each of its subcontract agreements requiring Subcontractor to,among other things,keep detailed accoun irg records and to permit OWNER and the OWNER's accountants access to the Subcontractors' records, books, correspondence, Instructions, drawings, receipts,subcontracts,purchase orders,vouchers,memoranda and other data relating to this Project 4.0 CHANGES IN THE WORK 4.1 OWNER,without Invalidating the Contract,may at any time order extra work or make changes by akering,adding to or deducting from the Work, the Contract Sum being adjusted accordingly. All such extra or changed work shall be authorized by a written order to CONTRACTOR signed by OWNER authorizing an extra or a charge In the Work or an adjustment In the Contract Sum or the Construction Schedule,as applicable(a'Change Order). The form and substance of the Change Order will be as set forth on Exhibit*E'unless OWNER provides CONTRACTOR with written notification that an alternate form will be utilized Upon receipt of such Change Order executed by OWNEi,CONTRACTOR shall promptly proceed with such extra or changed Work Involved and such extra or changed work will constitute a portion of the Work. 5.0 OWNER 5.1 OWNER will designate the representative authorized to act on OWNER's behalf with respect to the Project("OWNER's Representative"). OWNER,either directly or through its representative, will provide admintstretion of this Contract OWNER's Representative whit have authority to reject Work that does not conform to the Contract Documents. OWNER may change OWNER's Representative by notice to CONTRACTOR in writing. OWNER s Representative will be the following Individual(s): Name: Mllinazzo,Dan Address: Two Greenwood Square 3331 Street Road Bensalem,PA 19020 5.2 If CONTRACTOR falls to perforin or correct Work that Is not in accordance with the Contract Documents, OWNER may direct CONTRACTOR,in writing,to atop the Work unfit the correction is made, OWNER will have the right at any time to direct CONTRACTOR to Short Form,GC,Lump Sum,Contract,2-JAN-12 3 of e suspend CONTRACTOR's performance of the Work or any portion of the Work for any reason whatsoever,or without reason,for such period of time as OWNER may determine. 5.3 OWNER reserves the right to perform constriction or operations related to the Project with OWNER's own forces,and to award separate contracts In connection with other portions of the Project 6.0 CONTRACTOR 6.1 CONTRACTOR shall solely have control over or charge of and will be solely responsible for construction means, methods, techniques,sequences or procedures,or for safety precautions and programs In connection with the Work. CONTRACTOR shall be solely responsible for failure to carry out the Work in accordance with the Contract Documents.The CONTRACTOR shall require all on-site personnel of the CONTRACTOR,its Subcontractors,Sub-Subcontractors or any other entity for whom CONTRACTOR may be responsible,to wear hard hats and orange colored vests, as well as any other appropriate protective clothing and gear as may be required by Law or reasonably requested by the Owner. 8.2 CONTRACTOR warrants to OWNER that materials and equipment furnished under the Contract will be of good quality and new unless otherwise required or permitted by the Contract Documents,that the Work will be free from defect not inherent In the quality required or permitted,will be fully compatible with existing materials and equipment and that such Work will cordons with the requirements of the Contract Documents. Work not conforming to these requirements may be considered detective. CONTRACTOR's warranty excludes remedy for damage or defect caused by abuse,modifications not executed by CONTRACTOR,Improper or Insufficient maintenance,Improper operation or nominal wear and tear under normal usage. 6.3 Upon notice from OWNER, CONTRACTOR shall promptly remedy any Work that is found not to be in accordance with the requirements of the Contract Documents,and pay for any damage to other work resulting therefrom,which shall appear wlthln a one(1)year period from the actual date of Final Completion of the Work. Notwithstanding the foregoing if the terms of specific warranties required by any of the Contract Doaments stipulate a longer time period,the longer time period shall govern. 6.4 All Wait shall be subject to tests and inspections at all reasonable times and at all pieces prior to acceptance. Inspections and tests shall not be construed as constituting or implying acceptance of the Work. 6.5 Regardless of passage of title,the risk of loss to any materials,equipment and furnishings,provided or to be provided pursuant to this Contract shall remain with CONTRACTOR until OWNER accepts such materials,equipment and furnishings. 6.6 All laborers and workers,while working in and around the Project,shall ac In a professional manner. CONTRACTOR shall enforce proper discipline and decorum among all laborers and workers on the Project and shall control,among other things:i)noiee,including music;ti) the use of offensive language;tiq smoking or drinking of alcoholic beverages on the Project Site;iv)physical violence;v)riding in the passenger elevators;A)thievery,and AD the transportation of articles or materials deemed hazardous. If OWNER determines,In its sole discretion,that any laborer or worker need to be removed due to his or her failure to comply with the terms of this provision,CONTRACTOR shall remove such laborer or worker from the Project Site immediately. 6.7 CONTRACTOR shall be responsible for protecting the Work,and any designated portions of the Work(including any units and floors), against the elements at the end of each working. In addition,no occupied portion of the Work shall be left without essential services,heat,light and water at the end of each working day as the result of Work. 6.8 CONTRACTOR shall coordinate and cooperate with separate contractors employed by OWNER 6.9 CONTRACTOR covenants,represents and warrants that the Work shall be free of all products,constituents,materials or processes containing asbestos,lead-based paint,or any other toxic or hazardous materials. 6.10 The CONTRACTOR shall submit the standard form of agreement between Contractor and Subcontractor to the Owner for the Owner's review and approval prior to the execution of any subcontracts,and shall provide the Owner with a copy of all executed subcontract agreements, prior to the performance of any Work by Subcontractors of any ter. 7.0 INSURANCE AND INDEMNIFICATION 7.1 CONTRACTOR shall purchase and maintain,at its sole expense,commercial general lability and automobile liability Insurance with limits of no less than$1,000,000 each occurrence and In the aggregate. The commercial general liability insurance shall cover all labor, materials or services furnished hereunder and shall include a contractual liability endorsement CONTRACTOR's liability insurance shall name the indemnified Parties(as hereinafter defined)as additional Insured(the'Additional insureds. CONTRACTOR shall also purchase and maintain workers compensation Insurance as required by Laws and shall furnish OWNER with evidence of such insurance. CONTRACTOR shall furnish OWNER with certificates of insurance before any Work Is donne and any materials are delivered to the Site. Failure to provide certificates of insurance shall not relieve CONTRACTOR of its contractual obligations and CONTRACTOR shall remain liable for each of the Insurance obligations set forth hereunder. insurance certificates shall dearly Identify OWNER,the Additional Insureds,contract number and all insurance coverages and special conditions as required by this ContracL 7.2 To the fullest extent permitted by law,CONTRACTOR shall indemnity,protect,defend and hold OWNER,Its affiliates,parent and subsidiary entities,Including,without limitation,Apartment Investment and Management Company(AIMCO),and any of AIMCO's subsidiaries and affiliates that may directly or Indirectly own or manage the property at or for which CONTRACTOR performs any Work, and their respective partners, managers, members, employees, officers, directors, trustees, shareholders, counsel, representatives,agents,successors and assigns(the"Indemnified Parties)free and harmless from any and all liabilities,penalties, fines,losses,claims,demands,actions,suits and costs(Including,without limitation,reasonable attorneys'fees,expert fees,court costs and expenses),If caused by reason of or as a result of the performance of the Work,whether based upon or claimed to be based upon statutory,contractual,tort or other liability hereunder;provided that no person or entity indemnified hereunder shall be Indemnified for claims arising from such person's or entity's own negligence,and the provisions of this Paragraph shall not be Short Form.GC,Lump Sum,Contract,2-JAN-12 4 of 6 construed to requireCONTRACTOR to Indemnify any person or entity Indemnified hereunder for or against such person's or entity's own negligence or to require any indemnification which would make the provisions of this Paragraph void or unenforceable. in the event any provision contained In this Paragraph or elsewhere in the Contract Documents shall be deemed void or unenforceable,it shall not thereby invalidate or be construed to invalidate any other provision contained In this Paragraph or elsewhere In the Contract Documents,all of which shall remain In full force and effect, The obligations of CONTRACTOR pursuant to this Paragraph are not to be construed to negate or reduce any other right or obligation of Indemnification which would otherwise exist as to any party or person described in this Paragraph. 7.2.1 If a claim Is made against any person or entity Indemnified under this Paragraph 7.2 by any employee of CONTRACTOR,a subcontractor,anyone directly or indirectly employed by them or anyone for whose acts they may be liable,the Indemnification obligation under this Paragraph shall not be limited by a limitation on the amount or type of damages,compensation or benefits payable by or for CONTRACTOR or a subcontractor under worker's or workmen's compensation acts,disability benefit acts or other employee benefit acts. 7.2,2 All provisions of this Contract that require CONTRACTOR to Insure, defend or Indemnify OWNER shall survive any termination of this Contract. Other provisions of this Contract,which,by their reasonable terms,are intended to survive termination of this Contract,shall survive termination. 7.3 CONTRACTOR waives and releases all claims for or right to any consequential,incidental,exemplary,punitive or special damages. 8.0 TERMINATION 8.1 CONTRACTOR may suspend performance of the Work or any portion thereof after thirty(30)days prior written notice If.through no act or fault of CONTRACTOR or any other persons performing portions of the Work under Contract with CONTRACTOR,any of the following occurs:1)issuance of an order of a court or other public authority having jurisdiction:U)an act of government,such as a declaration of national emergency,making material unavailable;Ilq OWNER has repeatedly not made payment within the time stated in the Contract;or tv)OWNER has persistently failed to fulfill OWNER's obligation under the Contract with respect to matters important to the progress of the Work. If for the reasons set forth In this Paragraph 8.1,the Work Is suspended for thirty(30)days and no cure has been effectuated,CONTRACTOR may,upon twenty(20)additional days written notice to OWNER,terminate this Contract. In the case of a partial suspension of the Work,CONTRACTOR shall cohtknue to perform work riot affected by such partial suspension. If the Work Is suspended,an equitable adjustment may be made In the Contract Sum,Guaranteed Maximum Price and the Construction Schedule. 6.2 OWNER may terminate the Contract if CONTRACTOR: i) refuses or falls to supply enough property skilled workers or proper materials;I)fails to make payment to subcontractors for services,materials or labor;ii)disregards any Laws;or iv)otherwise has materially breached a provision of this Contract. When any of the above reasons exist,OWNER may without prejudice to any other rights or remedies of OWNER and after giving CONTRACTOR five(5)days'written notice,terminate employment of CONTRACTOR and may:l)take possession of the Site and of all materials,equipment,tools,and construction equipment and machinery thereon owned by CONTRACTOR;or ii)accept assignment of subcontracts and finish the Work by whatever reasonable method OWNER may deem expedient. When OWNER terminates the Contract for one of the reasons stated In this Paragraph 8.2,CONTRACTOR shall not be entitled to receive further payment until the Work is complete. If OWNER's termination of CONTRACTOR pursuant this Paragraph 8.2 is,for any reason, adjudicated to be unwarranted or unjustified,OWNER's termination of CONTRACTOR shall be treated as though It were accomplished pursuant to Paragraph 8.3 hereof. 8.3 OWNER may,without cause,terminate performance under this Contract by CONTRACTOR. OWNER will give written notice of such termination to CONTRACTOR specifying when termination becomes effective. CONTRACTOR shall incur no further obligations In connection with the Work and CONTRACTOR shall stop Work when such termination becomes effective. CONTRACTOR shall also terminate outstanding orders and subcontracts. OWNER may direct CONTRACTOR to assign CONTRACTOR's right,fide and interest under termination orders or subcontracts to OWNER or its designee. Upon termination pursuant to this Paragraph,CONTRACTOR shall be entitled to payment for that Work actually completed prior to the termination for converdence as well as, If applicable, reimbursement of the actual costs Incurred by CONTRACTOR to terminate outstanding orders and subcontracts. 9.0 MISCELLANEOUS 9.1 Nothing in this Contract shall create,or be construed to create,any third party beneficiary rights in any person not a signatory to this Contract except OWNER will be third party beneficiaries of CONTRACTOR's agreements with all of Its subcontractors and CONTRACTOR shall Include or cause to be included similar provisions in each of the aforementioned agreements naming OWNER as third party beneficiaries. 9.2 All trade discaats,rebates and refunds and all returns from sales of surplus materials and equipment shall gong to and accrue for the benefit of OWNER. 9.3 CONTRACTOR Is prohibited from providing gifts or other things worth more than 825 to OWNER or any of Its employees. CONTRACTOR's violation of this precept shall constitute grounds for Immediate termination. 9.4 CONTRACTOR shall not bring claims or lawsuits against any principals,employees,agents,officers,directors,stockholders,partners or affiliates of OWNER,AIMCO,AIMCO Properties,L.P.or AIMCO-GP,Inc. CONTRACTOR further agrees that the sole and exclusive remedy of CONTRACTOR for payment andlor performance of this Contract shall be against the assets of OWNER. 9.5 CONTRACTOR acknovAedges,understands and agrees that OWNER may execute or make payments under 1Ms Contract by or through an authorized representative(s) of the OWNER. Notwithstanding anything contained herein to the contrary, such authorized representative(s)andlor its affiliates shall not incur any liability,or other obligation,under this Contract to CONTRACTOR,for any reason, including,but not limited to,for any payments that may be due CONTRACTOR hereunder,nor shall any payment made by an authorized representative(s)create,or be construed to create,a contract between the CONTRACTOR and such authorized representalive(s). Short Folin,GC,Lump Sum,Contract,2-JAN-12 6 Of 6 9.6 CONTRACTOR hereby irrevocably submits itself to the original jurisdiction of the District Court of Denver of the State of Colorado with regard to any controversy In any way arising out of or relating to the execution or performance of Contract and agrees that any,such suit,action or legal proceeding shall be brought In such state court. CONTRACTOR further irfevocaby(t)consents to the jurisdiction of such state court in any such suit,action or legal proceeding,(in waives any objection it may have to the laying of venue of any such suit,action or legal proceeding In such state court(fir waives any defense based upon Inconvenient forum or improper venue and(Iv)waives any right it may have to remove such suit,action or legal proceeding to the courts of the United States. CONTRACTOR further agrees that any and all disputes arlsIng out of or relating to Contract or the performance of it by either party shall be adjudicated solely by and be govemed by the laws of the State of Colorado without regard to conflicts of law analysis.EACH PARTY HEREBY WAIVES AND RELEASES ITS RIGHT TO CLAIM A TRIAL BY JURY WITH RESPECT TO ANY ACTION BY OR AGAINST THE OTHER PARTY ARISING HEREUNDER.The CONTRACTOR shall include a similar provision in each of its subcontract agreements requiring the Subcontractor to waive its right to claim a trial by jury. 9.7 CONTRACTOR shall not publicize,publish or otherwise use the name of OWNER,AIMCO or any of their affiliates In any advertising, customer list or similar document,or otherwise disclose the contractual relationship with OWNER,AIMCO,or their affiliates,without the prior written approval of AIMCO,which may be given or withheld In AIMCO's sole discretion. This Contract entered Into as of the day and year first written above. OWNER AIMCO NORTH ANDOVER,L.L.C. CONTRACTOR:East Coast General Contracting By: STEICH,MATT,solely uU>orized re tative o Owner _ Authorized Signature: xx Authorized Signature: ° Print florins Matt Steic Print Nam: Tom Kmnai PrintTitle: Regional Dlrecor of Construction Print Title: President Short Form,GC,Lump Sum,Contract,2-JAN-12 6 of 8 EXHIBIT"A" SCOPE OF WORK For Contract:14549-404879-CP-00002 CONTRACTOR shall perform the following Work in strict accordance with the terms of the Contract: 1.0 WORK SYNOPSIS Interior,Restoration Post-Abatement-Units 45-2,39-2,31-3 2.0 SCOPE OF WORK Standards and Description of Work Performance ROYAL CREST ESTATES NORTH ANDOVER Units 45-2,39-2,31-3 Construction Requirements: The work of the CONTRACTOR and their employees shall be performed in a good and workmanlike manner. Workmanlike quality is defined as workmanship that meets or betters those criteria indicated in applicable building codes, using materials and installation methods identified in the construction plans and this Scope of Work Code Requirements: All jobs shall conform to those standards stipulated in the building code, health code, mechanical code, plumbing code, and electrical code applicable in the local jurisdiction.All construction on the OWNER'S properties shall meet or exceed NAHB Performance and Building Standards. CONTRACTOR is responsible for acquiring any and all needed permits/certificates for the work and any associated costs. Safety: CONTRACTOR agrees to comply with OSHA and/or any other governmental agency's safety rules and regulations.Should any citations,fines,and/or penalties,etc.,be incurred by the OWNER due to the negligence of the CONTRACTOR, the CONTRACTOR agrees to indemnity the OWNER for any and all penalties, fines, etc., incurred. CONTRACTOR shall perform the following Work in strict accordance with the terns of the Contract: Location: Royal Crest Estates North Andover,Units 45-2,39-2,and 31-3 Turnkey Job: The CONTRACTOR will furnish all equipment, supervision, material and labor necessary to deliver a finished projectiproduct which completes the scope of work and successfully addresses the projects intentions. Intent: Restore unit and building damage resulting from moisture damage and ACM abatement procedures o the OWNER'S quality standards,such that the unit and building can be used and occupied comfortably after the work; Scope of Work: 1. Seal all foundation cracks and apply Drylock foundation coating to interior of exposed foundation. 2. Provide and install unfaced fiberglass batt insulation in exposed exterior wails. a. 45-2 approx.350 Sq/Ft of exposed exterior walls b. 39-2 approx. 153 Sq/Ft of exposed exterior walls c. 31-3 approx. 300 Sq/Ft of exposed exterior walls 3. Provide and install 6 mil poly vapor barrier over installed insulation. General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 1 of 12 4. Provide two 4 inch openings in exterior brick. 5. Provide and install two new 4 inch galv.Vent pipe runs.(One to each bathroom) 6. Provide,install,paint and caulk 2 new 4 Inch vent heads. 7. Provide licensed electrician to install Aimco provided bathroom exhaust fans. 8. Provide and install new M.R.sheetrock to ceilings in both bathrooms. .9. Provide and apply compound,sand smooth,prime and paint bath ceilings to match existing. 10. Provide and install M.R.sheetrock on all areas removed by others. a. 45-2 approx.608 Sq/Ft of M.R.sheetrock b. 39-2 approx.656 Sq/Ft of M.R.sheetrock c. 31-3 approx.450 Sq/Ft of M.R.sheetrock 11. Provide and apply compound to all new sheetrock. 12. Sand smooth,prime and paint all new sheetrock surfaces two coats. 13. Provide and install new baseboard to match existing. a. 45-2 approx.42 UR.of 3%inch wooden baseboard b. 39-2 approx.32 UFt.of 3%inch wooden baseboard c. 31-3 approx.40 UR.of 3%inch wooden baseboard 14. Paint baseboard to match existing. 15. Patch ceilings after popoom/texture removal by others. a. 45-2 living room,dining room,hallway and kitchen ceilings b. 31-3 living room,dining room,hallway,both bedrooms and kitchen ceilings 16. Prime ceiling with BIN primer and apply new popcorn/texture to match existing. a. 45-2 approx.528 sq/ft b. 31-3 approx.875 sq/ft 17. Paint new popcom/texture 2 coats to match existing. 18. Grind deteriorated mortar from exterior brick joints. a. 45-2 Grind 18 inches in height by 52 feet long. (approx.78 sq/ft.) b. 30.2 Grind 4 feet in height by 25 feet wide from living room A/C unit to corner of master bedroom window.(Approx. 100 sq./ft.).Grind 30 I/ft of foundation to brick mortar joint around comer of unit and 2nd bedroom. 19. Provide and apply new mortar to all affected joints. 20. Mortar to match existing color and pointing style as best as possible. 21. Repair 3 foot exterior vertical brick crack at 39-2 near building comer 22. 39-2 Provide and install cement board in tub and shower areas. 23. 39-2 Provide and install 3 piece tub surround unit. 24. 39-2 Repair joint where cement board and existing drywall meet. 25. 39-2 Caulk new tub surround as necessary. 26. Provide plastic floor and wall protection through out the project. 27. Clean up and removal of all job related debris. 28. Household cleaning of affected areas. 29. Provide and install new ceramic tile on window sills demolished by others. 30. Removal,cleaning,and reinstallation of baseboard heating units to remain. General Construction Contract Extitbits A,B,C,D and E,2-JAN-12 2 of 12 i 31. Provide a written schedule for the project. 32. Provide copies of necessary permits to main site office and to Owner's Representative. 33. Provide a minimum 1 Veer workmanship warranty effective starting from the date of final aooeptance by OWNER. 34. Reinstallation of bathroom light bars and mirrors(in all 3 units-45-2,39-2,31-3)provided by service manager/maintenance shop 35. Reconnect existing smoke detectors(removed by others) 36. Resecure existing heat detectors Inspection Reports(if required by OWNER): 1. The CONTRACTOR and the OWNER must walk the job together and complete the pre-work section of the inspection report(s)before work may begin.The pre-work section of the inspection report(s)must be signed-off by both parties. 2. The CONTRACTOR and the OWNER shall walk the Job together and complete each section of the inspection report(s). 3. The CONTRACTOR and the OWNER must sign-off on all sections of the inspection report(s)attesting that the job is 100-percent complete and is correct per the job requirements found in this Scope of Work The final section of the inspection report(s)must be completed and signed-off on by both parties. 4. The CONTRACTOR must correct any deficiency found during the inspections and the job must be 100- percent complete before payment will be made. Prolect Reauirements: 1. Provide all materials,tools,equipment and labor,in appropriate quantities,to complete the following work in a workman-like manner to the best of industry standards,following all Manufactures(see contractors proposal)required material installation specifications 2. Provide protection of all surrounding areas, including, but not limited to landscaping,driveways,gutter systems,walkways,doors,roof overhangs,windows,masonry,etc.,from falling debris and or material maneuvers during work in progress,or any material storage. 3. Additional work(if required due to unforeseen Conditions)must be brought to the attention of Construction Services and be approved in writing prior to the commencement of additional work outside of this scope. 4. All new materials must be installed securely,and show good appearance including,but not limited to being installed straight and true. 5. All work must follow CONTRACTOR provided schedule,with daily updates through the site management team,with a minimum of 48 hours notice of any changes to schedule. This allows management to notify residents that this work will be taking place and whatever restrictions to normal traffic and or pedestrian traffic flow. 6. All work related debris must be kept clear of walkways and must be cleaned-up and removed to the dumpster or to an area designated by the OWNER at the end of each day of work.CONTRACTOR is responsible for removing all scraps and debris and placing them in the dumpster or designated trash site. The job will not be considered complete and payment will not be issued until all trash and debris are removed from the house and/or site. 7. Upon passing inspection by Owners Rep(Construction Services Rep),contractor may request payment for work completed by submitting an invoice accompanied by a waiver of lien identifying the same dollar amount as invoiced and indicating the percent of the contract amount that is due and payable. General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 3 of 12 8. Building/Property will be occupied during the project. CONTRACTOR shall make all reasonable efforts to limit the disruption and impact on regular users of the Building/Property,including but not limited to,the OWNER and its employees,residents,guests,visitors,etc. 9. CONTRACTOR is responsible to field verify all quantities,dimensions,and layouts. Actuals may not match those provided to the CONTRACTOR by the OWNER,or any third parties. Third party information may not be all-Inclusive of the specified scope or the project intentions. CONTRACTOR is responsible for temporary utilities,facilities,storage containers and signage as necessary unless otherwise specified. Some site utilities MAY be offered temporarily at the OWNERS discretion, but may be withdrawn by OWNER with minimal advanced notice. General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 4 of 12 EXHIBIT'B" SPECIFICATIONS AND DRAWINGS For Contract:14649-404879-CP-00002 The Work shall conform to, and be performed, in strict compliance with the Specifications and Drawings identified below. 1.0 SPECIFICATIONS AND DRAWINGS ROYAL CREST ESTATES NORTH ANDOVER UNIT RESTORATION PART 1—GENERAL 1.1 SUMMARY A. Section Includes: 1. Insulation/Vapor Retarders 2. Finishes a. Wallboard b. Paint 1.2 DELIVERY,STORAGE,AND HANDLING A. Store materials in dry spaces protected from the weather, with ambient temperatures maintained within range recommended by manufacturers,but not less than 50 deg F or more than 90 deg F. 1.3 QUALITY ASSURANCE A. All work is to be done by trained,experienced individuals. 1.4 PROJECT CONDITIONS A. Paint 1. Paints and solvents should be maintained at a temperature between 50 degrees Fahrenheit (F) and 90 degrees F, and stored in a well-ventilated area. Freezing temperatures may permanently damage water-based paints as may subjecting paint to frost 2. Paints not stored within the recommended temperature range should be conditioned for at least 24 hours at a temperature of 65 degrees F to 85 degrees F. Paint materials should be mixed prior to delivery to the job and then hand-mixed just prior to use and periodically during application. Caution should be taken not to over mix,causing the incorporation of excess air. 3. Paint should be maintained at 65 to 85 degrees F at all times during application. Paint should not be applied when temperature is expected to freeze prior to drying. Paints should be applied at manufacturer's spreading rates. When successive coats are used, allow sufficient time for each coat to dry thoroughly before the following coat is applied. Materials below or adjoining the work should be covered or otherwise protected. ' 4. Surface and air temperatures should be between 50 and 90 degrees F for water-based coatings and 45 to 95 degrees F for other coatings unless the manufacturer stipulates otherwise. B. Paint 1. Painted or finished surfaces should present a smooth, unblemished, homogeneous appearance without drops,runs,lumps,streaking,or visible color variations.Each coat should be allowed to dry prior to the application of the next coat. 2. The final interior paint job will be inspected in both sunlight and normal room lighting. Any defect visible from a distance of 6 feet under these conditions will be considered unacceptable. C. Wallboard 1. Drywall panels should be cut to fit easily into place, with no gaps greater than 1/2 inch. Drywall should be securely fastened using fasteners of a type recommended for the intended application. Fasteners should be driven squarely and placed at least 3/8 inch from the edges and ends. Heads should be seated no deeper than 1/32 inch below board surface and should not break the facepaper. General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 6 of 12 i 2. The finished drywall should present a smooth, unblemished, homogeneous appearance with inconspicuous joining between boards and no visible fasteners.There should be no areas of ralsed fibers on the facepaper due to over-sanding. Clearly visible nail pops, seam lines and cracks are considered unacceptable through the first-year Warranty period and are absolutely unacceptable at the completion of the job. PART 2-PRODUCTS 2.1 INSULATION A. Fiberglass Batt insulation B. Low expansion spray polyurethane around exterior wall openings 2.2 4-6 MIL POLYETHYLENE VAPOR RETARDER 2.3 FINISHES A. 5/8"TYPE-X GYPSUM WALLBOARD B. 618"MOLD RESISTANT GYPSUM WALLBOARD C. PAINT 1. Walls a. Non-Kitchen, Non-Bath;Single Tone Scheme: 1) Sherwin Williams 2) Flat, 3) ICI 1221, 4) Color to be site selected 2. Trim a. Sherwin Williams b. Semigloss, C. ICI 1427 d. Color to be site selected PART 3•-EXECUTION 3.1 EXAMINATION' A. Examine substrates, with Installer present, for compliance with requirements for maximum moisture content and other conditions affecting performance of the Work B. Verify that finishes of substrates comply with tolerances and other requirements specified In other Sections and that substrates are free of cracks, ridges, depressions, scale, and foreign deposits that might Interfere with adhesion of floor plank. C. Proceed with Installation only after unsatisfactory conditions have been corrected. 3.2 PREPARATION A. General 1. Prepare substrates according to manufacturer's written instructions to ensure adhesion of resilient products. 2. Fill cracks, holes, and depressions in substrates with trowelable leveling and patching compound and remove bumps and ridges to produce a uniform and smooth substrate. B. Doors/Windows 1. Protect all frames,jambs,and doors against warping delamination,and splitting. 2. Doors/Windows shall be shimmed,squared,and plumbed. 3.3 INSTALLATION General Construction Contract Exhibits A,B,C.D and E,2-JAN-12 6 of 12 A. DoorsNVindows 1. If any framed opening is not correctly sized, or is out of square or not level, and the CONTRACTOR cannot easily correct the problem,the OWNER should be immediately notified. 2. All windows and doors shall be installed so that they are centered in the framed opening and level within 1/16 of an inch.Casing trim margins shall be between 1/8 In.to%In. 3. Set and putty all nails in wood to receive paint or stain. Nail trim with finishing nails of proper size to hold the member firmly without splitting the wood. Pre-drill if necessary. 4. Sand all finished wood surfaces to provide a uniformly smooth surface. Always sand in the direction of the grain. 5. Windows shall be square.plumb,and level to 1/8 in.and shall operate freely and latch securely. B. Paint 1. All nicks, gouges, scrapes, damage, etc., should be repaired, treated, or otherwise taken care of before painting begins,both in the drywall and trim. 2. All nail holes in trim areto be filled with wood filler,sanded,and smoothed.All nail holes in drywall shall be repaired with drywall mud,not caulk. 3. Excess damage to drywall,trim,or doors is to be reported immediately to the OWNER. 4. All interior trim paint shall be applied with a brush and shall have two(2)coats. 5. Paint drippings and spills must be cleaned from tubs,showers,countertops,and all other areas. 6. All over-spray on window glass and aluminum window trim(inside and outside)must be wiped off with a damp rag before it dries. Aluminum window trim, especially the white baked-on finish, is easily damaged by razor blades and other items when the cleaners try to remove dried paint over- spray. 7. Paint drippings or spills on vinyl or wood flooring must be cleaned immediately without damage to the vinyl or wood flooring. 8. The final interior paint job will be inspected in both sunlight and normal room lighting. Any defect visible from a distance of 6 feet under these conditions will be considered unacceptable. 9. The CONTRACTOR is to take care not to damage work done by other CONTRACTOR&If any sink is used for washing brushes, etc., the sink shall be cleaned of any paint residue prior to the job being considered complete. 10. Exterior paint shall be specified by OWNER. 11. Exterior paint shall be two(2)coats,both of which may be sprayed. 12. Exterior trim paint shall be specked by OWNER. 13. Exterior trim paint shall be two(2)coats, both of which must be brushed. 14. All exterior areas to be painted,including the foundation,shall be free of dirt,mud,excess caulking, and any other foreign matter, 15. No thin spots in either interior or exterior paint are allowed. 16. Finishes shall be uniform and smooth, with no lumps, drips, runs, streaking, or visible color variations. 17. Any over-painting on trim must be cleaned from surrounding area. 18. Paint must be cleaned from all hinges and other hardware. 19. All door painting must be smooth, with no lumps, bumps, runs, color variations, and of a uniform appearance. Any defect visible from a distance of 6 feet in sunlight and normal lighting is unacceptable. 20. Over-spray must be cleaned from any brick,stucco,or other finish. 21. Decks, porches, outside handrails, etc., are a part of the outside paint package and shall be painted,stained,or left untreated per plan. 22. Any defect in outside paint(walls,trim, etc.)visible from a distance of 6 feet in normal sunlight will be considered unacceptable. 23. Interior handrail coatings shall be uniform with no drips, runs, light spots, etc. Any defect visible from a distance of 6 feet in sunlight and normal lighting is unacceptable. 24. All interior base, casing, shoe molding, door, and window jams, crown molding, chair rail and any other wood trim will be caulked. 25. All exterior siding joints, corner boards, fascia boards, overhangs, cantilevers, windows, doors, vents, and any other wood trim or siding shall be caulked. On houses with brick fronts, all gaps between the brickmold and brick will be caulked. 26. All thresholds must be caulked to prevent moisture and insects from entering the house. 27. All exposed metal lintels shall be wire-brushed to remove any rust and painted with a black, rust- P roofP aint General Construction Contract Exlrbits A,B,C,D and E,2-JAN-12 7 of 12 I i 28. All doors that have been taken down to paint shall be rehung,straight,level,and undamaged. C. Wallboard 1. Seam lines and cracking can be minimized by avoiding large gaps during installation and by installing panels in a manner that avoids conspicuous butt-end joints. When butt-end joints must occur, they should be staggered and as far from the center of walls and ceilings as possible. Whenever possible, panel ends and edges that are parallel to supporting members should fall on those members. 2. Measurements should be taken accurately at the point of installation to allow for irregularities in framing. Cut edges should be smoothed to fit accurately. Ceiling panels should be placed first and cut so as to fit easily into place without forcing. Tapered panel edges should butt tapered edges and square job-cut or mill-cut ends should butt other square-cut ends. 3. Fasteners should be applied starting in the middle of the panel and moving toward the outside. Nails or screws should be seated squarely while the board is held in firm contact with the framing support-Where adhesive is used, bonding surfaces should be free of dirt, grease, oil, or other foreign materials. 4. All beads must be installed per the manufacturer's instructions.All corners,ceiling lines,etc., must be straight with no hairline cracks. 5. Three coats of joint compound are required: an embedding coat to bond the tape and two finishing eats over the tape. Each coat must be thoroughly dry before the next is applied to ensure that the surface incurs maximum shrinkage and can be readily sanded. For the final coat,sufficient lighting must be utilized to ensure a quality finish. 6. Drywall Is to be installed either vertically or horizontally depending on the most efficient use of the material. 7. CONTRACTOR will keep waste to a minimum. B. Ceilings will be stippled unless notified otherwise. Stipple shall be uniform with no thin or missed spots.Stipple must be uniform from room to room. 9. All corners, lines of tray, and vault ceilings shall have begs and be installed per the manufacturer's instructions. 10. Drywall should be out accurately and should fit together with a maximum 112-inch gap between sheets. 11. No cut-on-site edges shall be used in vault ceilings.Factory-cut edges must be used at the peak of the vault. 12. Drywall should be firmly attached to all framing using nails,screws,and adhesive.There should be no give,bows,or warps in any board. 13. Heads of fasteners should be seated no deeper than 1132 inch below board surface and should not break the facepaper.Fasteners shall be installed every 16 inches on center. 14. All drywall edges shall be smooth and dean. Drywall shall not be cut with anything that leaves a ragged edge. 15. Hairline cracks in comers are unacceptable. 16. There should be no areas of raised fibers due to over-sanding. 17. Al electrical boxes are to be free and clean of any drywall debris or mud before the CONTRACTOR leaves the job. 18. Drywall installed around tubs and showers shall fit snugly with no gaps larger than V4 inch. 19. Drywall around the fireplace box,any door,window,or electrical box shall fit level and snug against jacks, fireplace box, or electrical boxes. If drywall is broken around electrical boxes, it shall be cut and patched with drywall to fit snugly around the box. 20. The CONTRACTOR and its employees are not to stand on tubs, sinks, or countertops, or place any materials on them. Any fasteners dropped on tubs and sinks shall be picked up so as not to damage the finish of tubs and sinks. 21. The CONTRACTOR shall not leave any holes in storage rooms, around heating units, etc. All areas that receive drywall shall be taped,mudded,and sanded. 22. After primer coat of interior paint is applied to walls,CONTRACTOR is responsible for touch-up on walls and ceilings at no additional charge. 23. CONTRACTOR Is responsible for a final touch-up,as required,after the OWNER's walk-through. 24. The CONTRACTOR shall furnish heaters as required.The CONTRACTOR is not required to leave his or her own heaters overnight unless they are returning the next day. If the job requires heat overnight notify the OWNER. General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 8 of 12 3.4 CLEANING AND PROTECTION A. Comply with manufacturer's written instructions for cleaning and protection of materials. B. Perform the following operations immediately after completing material installation: 1. Remove adhesive and other blemishes from exposed surfaces, 2.. Sweep and vacuum surfaces thoroughly. 3. Damp-mop surfaces to remove marks and soil. C. Protect products from mars, marks, Indentations, and other damage from construction operations and placement of equipment and fixtures during remainder of construction period. D. Unit Is to be left clean and broom-swept. END OF SECTION General Construction Contract EMbtts A,B,C,D and E,2-JAN-12 9 of 12 EXHIBIT"C" QUANTITIES,PRICING AND DATA For Contract:14649-404879-CP-00002 1.0 SCHEDULE OF VALUES Each Application for Payment pay item shall directly relate to the Schedule of Values defined below. Pay items set forth in the Schedule of Values may be revised only by Change Order("CO's in accordance with the terms of the Contract. Pay Item Work Description Additional Description Cost Code Amount 001 45-2 Re- intro 101200 $868.00 002 45-2 Drywall,Paint,Texture, 101320 $4,695.00 Bathroom 003 39-2 Re-pointing&Masonry 101200 $1,320.00 Re airs 004 39-2 Drywall,Paint,Texture, 101320 $5,123.80 Bathroom 005 31-3 Drywall,Paint,Texture, 101320 $4,895.00 Ballroom 006 Permits&Fees 101320 $60D.00 Contract Sum: $17.491.80 2.0 LIQUIDATED DAMAGES Liquidated damages will be deducted from the total Contract Sum in accordance with the schedule of liquidated damages defined-below: Unit of Description Measure Amount Assessed for for the number of days between actual achieved date and Any Final Completion Date setforth within the Construction Schedule perda $ 150.00.- 3.0 UNIT RATE PRICES The pricing of a Change Order may be based on the following Unit Rate Prices. Unit Rate Prices shall include all fees and costs including,but not limited to,labor,material,services,overhead and profit. Pay Unit of Item Unit Rate Description Measure Unit Rate Price See Attached Sheet . General Construction Contract Exhibits A,B,C.D and E,2-JAN-12 10 of 12 AIMCO Construction services 2 Greenwood Square,3331 Street Road,Suite 450,Bensalem,Pa 19020 Bid Form Project Name I Royal Crest North Andover Mold ak Asbestos Unit Pricing Work Page 1 of 2 CONSTRUCTION UNIT PRICE PROPOSAL BID DUE DATE: 3uly 6th, 2012 BIDDER: East Coast Genera/Contracting PREPARED BY: Tom xlanal DATE: 7/6/2012 Unit Rate Pricin UNIT UNIT 1 Baseboard(provide,install and a( 2.50 If 2 Door Casings(provide,install,and int 2.50 if 3 Crown Moulding(provide,install and int 3.25 If 4 Batt Insulation unface 1.15 Sf 5 Batt Insulation faced 1.35 Sf 6 Vapor Barrier for wail(Poly sheeting) 0.20 Sf 7 6 mill Poly Sheeting floor/wail protection(Including any necessary to in 10.20 Sf 8 Closet Shelving(provide,install,andpaint) 5.50 If 9 Ceiling Texture Application Owdure and 2 coatspaint) 1.45 sf 10 Gypsum Wallboard Installation(ind.tape,compound,accessories 1.45 sf 11 Paint wall paint-prime with 2 coats aint 0.69 sf 12 Foundation Paint(Drylok Masonry Waterproofing Paint provide and apply) 40.00 allon 13 2x4 Framing 8.801 if 14 2x4 Framing(Pressure Treats 18.90 If 15 2x3 Framing $17.20 If 16 4x4 Framing 4.10 if 17 2x10 Framing 4.60 If 18 Existing Window removal and reinstall $200.00 ea 19 Bathroom Fan Provide and install:Ducts,hood electrical.Atmoo to rovide Fan 350.00 ea 20 Masonry Repointing Grind out point with matching mortar,and strike to match 11.00 sf 21 Exterior Polyurethane Caulking 10.1-10.3 oz Tube(application+/-101f-3/8"bead 7.00 tube 22 Masoqry Caulking 10.1-10.3 oz Tube(application+/-101f-3/8"bead to minor crack) 7.00 tube 23 Fire Rated/Anti-Microbial Closed Cell is nene S 200 sf or less, V thickness 3.10 Sf 24 Fire Rated/Anti-Microbial Closed Cell Ic nene Spray 201-800 sf, V thickness 2,20 Sf 25 Fire Rated/Anti-Microbial Closed Cell Icynene Spray 601-1200 sf,1"thickness 1.50 sf 28 OTHER 29 OTHER 30 OTHER 31 OTHER 27 Mark-up Percentage for Overhead 10.00 % 28 Mark-up Percentage for Profit $10.00 Hourly Rate Chart UNIT UNIT Project Manager t65.00 Hour Site Foreman $52.001 Hour General Laborer $45.001 Hour PROPOSAL PRICING MUST BE GOOD THROUGH DECEMBER 31,2012 LIST EXCLUSIONS/CLARIFICATIONS ON SHEET TWO"EXCLUSIONS" This form must be signed and sealed by an officer of your company prior to submittal ADDITIONAL SHEETS ATTACHED: INITIAL: � AIMco construction services 2 Greenwood Square,3331 Street Road,Suite 450,Bensalem,Ps 19020 Bid Form Project Name Royal Crest North Andover Mold Sk Asbestos Unit Pricing Work Page 2 of 2 CONSTRUCTION UNIT PRICE PROPOSAL BID DUE DATE: duly 6th, 2012 BIDDER: East Coast General Contraatlng PREPARED BY: Tom Minna/ DATE: 7/6/2012 Notes: Exclusions: Sheetrock and_popcorn texture to be removed by others. Bid includes no charges for hidden damage. Bidder will complete the Work in accordance with the Contract Documents This bid Is submitted by: ••o''0� :.• •.s'4,�'''-.,- Corporation Name: ? Of e = t{ a State of Incorporation: Corp. Type: By, iitsefi `� (Signature-attached evidence of authority to sign) Name(Type or Print): Thomas iGnnal -title: Owner (Corporate Sea!) Attest: (Signature of corporate secretary) Date of Qualification to do Business in the State of Ma _: 2/5/2006 EXHIBIT"D" CONSTRUCTION SCHEDULE For Contract:14549-4o4s79-CP-00002 CONTRACTOR shall perform the Work of this Contract in strict acoordance with the following Construction Schedule,subject to any modifications thereto by Change Order in accordance with the Contract: 4.0 GENERAL CONSTRUCTION SCHEDULE Milestone Dates Milestone Description 07/23/2012 Commencement Date Substantial Completion Date 08/03/2012 Final Completion Date 2.0 CPM SCHEDULE OR BAR CHART CONSTRUCTION SCHEDULE If required by this Contract, or if otherwise requested by OWNER, CONTRACTOR shall prepare a Construction Schedule, for OWNER's review and approval, based on and consistent with the General Construction Schedule identified above and any other OWNER requirements,which schedule shall utilize critical path methodology(CPM) with a computerized data base and production program. Upon OWNER's approval, such Construction Schedule shall be attached to this Exhibit and made a part of the Contract. General Construction Contract EXhbb A,B,C,D and E,2-JAN-12 11 of 12 } EXHIBIT"E" FORMS For Contract:14549-404879-CP-00002 1.0 GENERAL CONTRACTOR shall utilize the forms listed here below and attached hereto as apart of this Exhibit in accordance with the Contract unless otherwise directed by OWNER in writing: Form Title or Description Rev.No. Application for Payment 1/02/12 Release Document—CONTRACTOR's Waiver of Lien 1/02112 Release Document—CONTRACTOR's Final Waiver of Lien 1/02/12 Release Document—CONTRACTOR's Affidavit 1/02/12 r General Construction Contract Exhibits A,B,C,D and E,2-JAN-12 12 of 12 APPLICATION FOR PAYMENT TO: Owner: EN02415-OP Property Mgmt,LLC PROPERTY: Property Name: 42391,Royal Crest Estates(North Andover) Address: 4582 S Ulster Street Parkway,Ste 1100 Address: 50 Royal Crest Drive City,State ZIP: Denver,CO 80237 Address: Attn: AIMCO Construction Services A/P City,State ZIP: North Andover,MA 1845 Entity ID(OCl): EN10001 FROM: Contractor: East Coast General Contracting Project Description:JInterior RestorationPost-Abatement-Units 46-2,3972,313 Address: 286 Broadway Street Address: Contract Number: CAPR-14549-404879-01 City,State ZIP: Haverhill,MA 01823- Vendor ID: 1404879 Attn: Phone Number: (978)360-0051 Application Number: _ entail Address:1 Application Date: Period to: Contract Date: 7/11/2012 The following identifies the apprication that is being requested for payment in The undersigned CONTRACTOR certifies that to the best of CONTRACTOR's knowledge, connection with the contract.Please make sure that items 3,7,8,and 9 on this page information,and belief the Work covered by this Application for Payment has been completed in match the totals of columns E,F,G,and J on page 2. accordance with the Contract Documents,ttrat all amounts have been paid by CONTRACTOR for 1. Original Contract Sum Work for which previous Certificates for Payment were issued and payments received from OWNER,and that current payment shown herein is now due. 2. Net Change by Change Orders: Contactors Name: Date: 3. Contract Sum to Date(add 1 and 2): Signature: 4. Total of Completed Work to Date: 5. Retainage: Architect's Certificate for Payment(if needed) 6. Total Earned Less Retainage(subtract 5 from 4): In accordance with the Contact Documents,based on on-site observations and the data comprising this application,Ard>itect certifies to OWNER that to the best of Architects knowledge,Information and belief the Work has progressed as indicated,the quality of the Work is in ac oordance with the 7. Less Previous Applications for Payment: Contract Documents,and CONTRACTOR is entitled to payment of the amount certified. Architects Name: Attach explanation if the amount certified differs from the amount applied for.Initial all figures on 8. Current Payment Due(subtract 7 from 6): this Application and on the Continuation Sheet that are changed to conform to the amount certified. 9. Balance to Finish,including Retainage(subtract 6 from 3): Dale. Signature: This Certificate,is not negotiable.The Amount CertNied to payable only to CONTRACTOR named herein.Issuance,payment and acceptance of payment are without pmJudiee to any rights of OWNER or CONTRACTOR under the contrect Appfice9on for Paymant.43 6. Page 1 of 2 Updated 7110/2008 Owners trftls: APPLICATION FOR PAYMENT Contractor., East Coast General Contracting Contract Number. CAPR-14549404879-0I Location of Project 42391,Royal Crest Estates(North Andover) Application Number: 60 Royal Crest Drive North Andover,MA 1845 Application Date: Project Description: IntedorRestoration Post-Abatemeryt-Units 4S-2,39-Z31-3 Notarized Lien Waiver:Yes J -Mrk' -A dt .7 be Pay A10"rivork Cd lato a" Idem Cto OW Otdor ......... .... 1.0 Original Contract PC Siding Wood l Other-101200 45-2 Re-vointing $858.00 45.2 Drywall, Paint,Texture, 2-0 Original Contract PCD I-101320 Bathroom $4,695.00 39-2 Re-pointing &Masonry 3.0 Original Contract PC Siding Wood/Other-101200 Repairs 39-2 Drywall, Paint,Texture, 4.0 Original Contract PCD -101320 Bathroom $5.123.80 31.3 Drywall, Paint,Texture, SIO Original Contract PC Drywall-101320 Bathroom $4.895.00 SIO Original Contract PC Drywall-101320 PenTft&Fees 600.00 7.0 8.0 9.0 10.0 11.0 12-0 13.0 14.0 15.0 16.0 17.0 18.0 19.0 20.0 P,W amdraeara ROAb 4- Appicatlon for PaymentAs Page 2 of 2 Upcinted:7/10MIN owners In ctivea. r.UeM Icatton or:Re ar; .. �:. ;:•.<< iy•..�,�=,ti:::n`+: .,. v< ...:k s �..;:�:- psi ::.. - 1 o1Uld. s. of aa.a d1 .the,c ct.::-. ,�...........::...t°:.;�:_; _ ., _ . ..... C pu...!»_.... _drpa4....ae11AQ..a.._ .ofttfa $; eiot fle41 r�ur ?m�Apmarpd Addensa etnsot�flald yatailY4ata9>YoAttaetvyslaellinad, F s hr jc � ><1pr9pRrty Haid.inlet th4 penia trod dddrafs�f t(to.propaftgwltgta th.worlFlNaa parWpnad � ��" �'-� .� �+i aja�t pasPrlR(1On 11a1d.antgr A` 4oft df�tltfp omha�►wkaomphEsd g,��-�adraptNum"4artielcM�nf�td6Cp-��re:��!iamtiiir:lr�;diuia'cpntta�.t t �t�� � � �� � ��. � ���,wy.�„ j. y�}Agpiktdon w�iuearlt��..creat t1� Uon r. ih. a tdd co �4' ' ;;ti 1Q numb pf aPlmwa fef PAYIt a $U68�dyt.0r A 111eCI�C CQlpjt i 3 �+ t a� S y ' AppUeationDala fleld`antartha dAte You inland tp}f9tl th �pplton v 1012oe�PrMaitaeo� rA.k�ilgd7lt4410 �tdBYie( lek►9 x 43t a1, Ihe'elec6ionlo#Otm.ff a"rME@d_ ooi ltgiw, .. .. .. . y 1.,AU a delN autamaunal _populet@#rgm .1 Jf yQ►„�,�i�®tri: =.- ='1{jrouere tlsftt ilpnnred c�iy plassa it atro sJgelheltdotmRHon`oi�ttds'�age rpa i�ihe`lntgprwttatpt�p p 1, s f k-rt-,N x $.plactM j,oatracC otttw chaMao�dar14mb1 Rnfi " " 3L501@Clthellfo+JSlJaa¢dP liLden4fipd�ttlbA cAadU143vLiLld!}klh4fihl�a act i ' w7 ' mat l' 4,�ttl in iha a eta for Cepgllns.P,E ali(dh`;end JA fl Agddasi�CohmtCta 1!r*ti antlttla Totab`.4;r lk I;u Itucema► oit are u�no ste erearoatQan 1r you i aatOp apr1(�+PY lid tot3�t rtll erto�nia�na� t�itr t K you neQd M►�ddioa s11`t tt1e�1#I R4yrbyttoR and ptln a lhaYteRue fGRlamn t+ t aAd dat¢yy�h,:a APPtiealteA and re�3t 14 the�onipct7deR11riad h`l;�e 44rMrAet. °e ;��.� `'',�f„,i�L�k Yeti l t�x eta Thla fpml�aa dael8ned fof easy use Yyb@n tAling oat eteob+anicailYG-KYRu e1'a Atik�outq.Pdn�afl. '�J{1�g-��;�: '����t that ellyaigWaticme ace cotntt.Uaa the work deperlRdena halpw to s�tepra Ih�they mgtcl�,Rte wwk dsaotlpgont l�t!$te� r SehednleofYaitisa-tnUrobonfraek.. ...",�._.. --... ,;' >.<,.= . .. .�. ;; . . .:-:. .. ...•.. :`���'��' :���?t.._:!....:."� AppOcation for Payment.xls updated 7/10/2006 page 3 of 3 CONTRACTOR'S WAIVER OF LIEN KNOW ALL MEN BY THESE PRESENTS,That,WHEREAS, the undersigned of East Coast General Contracting (hereinafter referred to as "CONTRACTOR") and AIMCO NORTH ANDOVER, L.L.C. (hereinafter referred to as "OWNER")have heretofore entered into a certain written contract dated the covering work to be performed and/or materials to be furnished at the premises located at City of North Andover,State of MA;and WHEREAS, CONTRACTOR has performed work and furnished materials provided for under said contract up to and including the date hereof, and upon supplying lawful waivers of liens, rights of lien, and claims of CONTRACTOR, subcontractor's and materiaimen, is entitled to payment from the OWNER the sum of Dollars and Cents ($ ) under said contact; NOW, THEREFORE, in order to Induce the OWNER to make payment of said sum, CONTRACTOR hereby represents that all work performed and materials furnished under said contract up to and including the date hereof, including work and materials, if any, performed or furnished by subcontractor's and materialmen, have been paid for in full;and CONTRACTOR hereby waives any and all liens, rights of lien and claims on or against the premises at the address above given and on any and all structures and buildings located thereon arising under any law of the State wherein said premises are situated and hereby releases and agrees to save harmless OWNER from and against any and all claims for and on account of work performed or materials furnished by or for CONTRACTOR under said CONTRACTOR or otherwise. CONTRACTOR represents that all sales and use taxes if any applicable to any materials furnished by or for the CONTRACTOR have been paid in full. CONTRACTOR further represents that CONTRACTOR has not provided, directly or indirectly, any gift or other items individually or in the aggregate worth more than$25.00 to OWNER or any of its affiliates, parent or subsidiary entities(including without fimftation, AIMCO or any of AIMCO's subsidiaries or affiliates),or their employees or any employee's family members. SIGNED this day of 201_ ATTEST: By: PRINT NAME: TITLE: STATE OF ) )SS COUNTY OF ) On this day of 201_, before me,the undersigned, a Notary Public in and for said County and State, personally appeared the individual who signed the foregoing waiver, being personally known to me,and the execution of same was the free and voluntary act and deed of the CONTRACTOR named and further certified, that if CONTRACTOR is a corporation, it appeared by the officer who signed on its behalf, and such officer to me acknowledged that the execution was by authority duly granted, IN WITNESS WHEREOF, I have hereunto set my hand and affixed by official seal the date and the year last above written. My commission expires: Notary Public in and for Directions for Certificates of Insurance,2-JAN-12 1 of 5 CONTRACTOR'S FINAL WAIVER OF LIEN STATE OF ) )SS COUNTY OF ) TO WHOM IT MAY CONCERN: The undersigned, for and in consideration of a final payment of Dollars and Cents ($ ), and other good and valuable consideration, the receipt whereof is hereby acknowledged, does hereby waive and release any and all lien or claim of,or right to, lien, under the statutes of the State of MA, relating to mechanics liens or their statutory equivalent (regardless of the precise terminology used to describe such rights)with respect to and on the premises known as Royal Crest Estates(North Andover),and located at 50 Royal Crest Drive, North Andover, MA, and the improvements thereon, and on the material,fixtures, apparatus or machinery furnished, and on the moneys,funds or other considerations due or to become due from the OWNER, on account or labor services,material,fixtures, apparatus or machinery,furnished by the undersigned to the extent Of Dollars and Cents ($ ) for the above-described premises. Additionally, CONTRACTOR represents that CONTRACTOR has not provided, directly or indirectly, any gift or other items individually or In the aggregate worth more than $25.00 to OWNER or any of its affiliates, parent or subsidiary entities(including without limitation,AIMCO or any of AIMCO's subsidiaries or affiliates),or their employees or any employee's family members. By: STATE OF ) )SS, COUNTY OF ) On this day of 201_, before me,the undersigned,a Notary Public in and for said County and State, personally appeared the individual who signed the foregoing waiver,being personally known to me, and the execution of same was the free and voluntary act and deed of the CONTRACTOR named and further certified, that if CONTRACTOR is a corporation, it appeared by the officer who signed on its behalf, and such officer to me acknowledged that the execution was by authority duly granted. IN WITNESS WHEREOF, I have hereunto set my hand and affixed by official seal the date and the year last above written. Notary Public Directions for Certificates of Insurance,2-JAN-12 2 of 5 CONTRACTOR'S AFFIDAVIT .STATE OF ) COUNTY OF SS TO WHOM IT MAY CONCERN: The undersigned,being duly sworn,deposes and says that he is Tom Kinnal, of East Coast General Contracting who was employed by AIMCO NORTH ANDOVER,L.L.C. to furnish Unit Rest rat on for the premises known as Royal Crest Estates(North Andover),and located at 50 Royal Crest Drive,North Andover,MA. That the total amount of the contract Including extras is ($ )on which East Coast General Contracting[the companly)ars has received payment of nts ($ )prior to this payment. That a(I waivers Dollars and Cents are true,correct and genuine and delivered unconditionally and that there is no claim either legal or equitable to defeat the validity of said waivers. That the following are the names of all parties who have furnished material or labor,or both,for said work and all parties having contracts or sub contracts for specific portions of said work or for material entering into the construction thereof and the amount due or to become due to each,and that the items mentioned include all labor and materials required to complete said work according to plans and specifications: NAMES TYPE OF WORK CONTRACT AMOUNT THIS BALANCE PRICE PAID PAYMENT DUE INCUDING EXTRAS East Coast General Interior Restoration Post- $17,491.80 —$- Contracting Abatement That there are no other contracts for said work outstanding, and that there is nothing due or to become due to any person for materials, labor or other work of any kind done or to be done upon or in connection with said work other than above stated. That CONTRACTOR has not provided, directly or indirectly,any gift or other items individually or in the aggregate worth more than $25.00 to OWNER or any of its affiliates, parent or subsidiary entities (including without limitation, AIMCO or any of AIMCO's subsidiaries or affiliates), or their employees or any employee's family members. By: STATE OF ) COUNTY OF )SS. On this day of 201_,before me,the undersigned,a Notary Public in and for said County and State,personally appeared the individual who signed the foregoing waiver, being personally known to me,and the execution of same was the free and voluntary act and deed of the CONTRACTOR named and further certified, that if CONTRACTOR is a corporation, it appeared by the officer who signed on its behalf,and such officer to me acknowledged that the execution was by authority duly granted. IN WITNESS WHEREOF, I have hereunto set my hand and affixed by official seal the date and the year last above written. Notary Public Directions for Certificates of Insurance,2-JAN-12 3 of 5 �Cr./ DIRECTIONS FOR CERTIFICATES OF INSURANCE REQUIREMENTS The sections below provide explanations and directions that correspond to the sections on the Insurance Certificate to be provided by CONTRACTOR to OWNER. 1 This is the date the Certificate of Insurance was typed. 2 This is the name and address of the agent or broker who placed the insurance coverage for CONTRACTOR. 3 This is the name and address of CONTRACTOR. The name of CONTRACTOR must be the same as CONTRACTOR named in the Contract. 4 This is the name(s) of the insurance companies providing the Insurance. Insurance shall be placed with insurers which have an A.M. Best's rating of A-or higher and financial size category of VII or higher. 6 Letter designation will Indicate which insurance company is providing Insurance coverage from the list of insurance companies under Companies Affording Coverage. 6 Type of Insurance identifies the specific insurance being provided. Commercial General Liability is the insurance generally available to CONTRACTOR and required under the insurance provisions of the Contract including but not limited to: • Premises and Operations • Products and Completed Operations • Contractual Liability • Braad Form Property Damage • Explosion,Collapse and Underground Hazards • Personal Injury Liability CONTRACTOR shall maintain limits of liability of at least: Contract Value <$15K >$15K-<$200K A Commercial General Liability olio form: $1,000,000 each occurrence bodily injury and property damage, Ix $1,000,000 general aggregate X $500,000 general aggreciate. Ix B Automobile Uabili : $500,000 combined single limit per accident, bodily injury S property X X damage. C)Workers Compensation: Coverage as required by law. Ix 7 This is the policy number of the insurance policy provided by CONTRACTOR. 8 The policy effective date must be effective on or before the contract inception date. 9 The policy expiration date must expire on or after the Final Completion date. The Final Completion date is defined in the Construction Schedule of the contract. If the expiration date is before the Final Completion date, OWNER will monitor to insure receipt of renewal certificates. If CONTRACTOR fails to provide a renewal certificate,access to any Jobsite may be withdrawn. No claims for delay or associated costs will be approved by OWNER In the event of any denial of access to any jobsite. 10 OWNER's special request items: Directions for Certificates of Insurance,2-JAN-12 4 of 5 A) Reference the Property Name(Royal Crest Estates(North Andover))&Contract number (14549-404879-CP-00002)indicated on the contract. B) Insert,verbatim,the following Additional Insureds statement: "Coverage Includes OWNER as Addidonal Insureds." Z The certificate holder is OWNER, which requested the Certificate of Insurance from CONTRACTOR, not any individual person of OWNER. 12 The Certificate of Insurance must be signed to be valid. It can be signed by the agent,the broker, or the insurance company. OWNER will verify that the types of Insurance and the limits of coverage being provided are consistent with the contract requirements. Approval of CONTRACTOR's Insurance Certificate will be"subject to this verification. Original Certificates)of insurance must be mailed to: Tracey Warner Two Greenwood Square 3331 Street Road Bensalem,PA 19020 PLEASE NOTE: The coverage limits above are guidelines Intended to provide Contractors general Insurance coverage limits that AIMCO requires. Contractors must review each contract and provide Insurance coverage and certificates for the amounts required by each contract. i Directions for Certificates of Insurance,2-JAN-12 5 of 5 CERTIFICATE OF INSURANCE EXAMPLE ISSUE DATE(MMIDDIM PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CON NO RI HTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND, OR ALTER THE [Insert Name and Address Of COVERAGE AFFORDED BY THE POLICIES LISTED BELOW. CONTRACTOR's Agent or Broker] COMPANIES AFFORDING COVERAGE 2 COMPANY A LETTER COMPANY B INSURED LETTER East Coast General Contracting COMPANY C 4 Tom Kinnal LETTER 286 Broadway Street Haverhill,MA 01823- COMPANY D 3 LETTER COMPANY E . COVERAGES LEI R THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED OR MAY ERTAJ , ANY REQUIREMENT,TERMOR CONDITION OF ANY AGREEMENT OR OTHL R DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS MAY HAVE BEEN REIXJCED BY PAID CLAIMS. COMPANY P Y EFFECTNE POLICY EXP81A N ATTER TYPE INSURANCE POLICYNUMBER DATE MWwrfY DATE 5 GENERALLIABILRY L16tR81NTHOUSANDS X COMMERCIALGENERALLWBILITY 7 8 8 TE CIAIOAR PRO S-0OMpTOPS E OWNERS d OWNER'S PRDT. E b OV.i X XCU-0 E i flRE DAMAGE one Gre AUT0MOU BLLIIY EDICAL ENBE One n S _ COMBINED SINGLE s LIMIT ALLOWNEDAUTOS BODILY INJURY SCH DLA DAUTOS (Perpemon) S 6 HI ED AUTOS BODILY INJURY $ , NON-ONMED OS (Per ato'deM) GARAGE LIABILITY X AUTOMOBIL �NTRACTUALLIABIUTY PROPERTY DAMAGE $ PJLCE8 IABLIfY UMBRELLA FORM - EACH OCCUR S OTHER THAN UMBRELLA FORM WORKER'S OMPENSATION EMPLDYERS'LIABILMY AND STAMORY LIMITS $EASE--POLICY LIMIT s OTHER ISEASE—EACH EMPLO DESCRIPTION OF OPERATIONS(LOCATIONSIVEHICLESISPECIAL ITEMS Property Name: .Royal Crest Estates Contract No.:14549-404879-CP-00002 ANO Andover) Insert 'Coverage Includes OWNER as Additional Insureds."as expressly nominated under the Insurance provisions of the Contract] 10 CERTIFICATE HOLDER[Insert Name and Address CANCELLATION of OWNER]11 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED,TERMIN]THE AIMCO NORTH ANDOVER,L.L.C. OR MATERIALLY ALTERED BEFORE THE EXPIRATION DATE THEREOF, 50 Royal Crest Drive ISSUING COMPANY WILL MAIL 30 CALENDAR DAYS WRITTEN NOTICE TO North Andover,MA 01845 CERTIFICATE HOLDER, [OWNER does not Include the name of any individual]. AUTHORIZEDREPRESENTATIVE 12 1 Of 1 ACS CERTIFICATE OF LIABILITY INSURANCE Of 2012'x°°""'"' THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT., H the certl8cate holder Is an ADDITIONAL INSURED,the pollcy(tes)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder In lieu of such andorseme s. PRODUCER6: Ardree Ga1bghor Fled C.Ckyck Irm 2- CT 41 WalhW Sued E 9782277172AX Ne 97845418f6 Lowell.MA 01051 ExIld 9p� (800)22(L18(IB AE _ INSURER(S)AFMPLN13COVERAGE MAIC/ INSURER A: Peerless Insurance Company 24190 INBUREO INSURER B: 'Hoots H Mnnel DBA End OwA General C**WkV INSURER C: 286 Have",MA 01832-2909 INSURER D: — INSURER E: INSURERF: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAK)CLAIMS. 1 OR TYPE OF INSURANCE ItMIR POLICY HUMBER LIMITS GENERAL LIABILITY ENCHOCCURRENCE $ 1•�� X NMMBICI I.GENERAL LIABILITY PREMISES nce S 100.000 CLAIMS-MADE M OCCUR MED EXP one ) S 5.000 A CSP8284081 ?HS2012 21162013 PERSONAL SAW INJURY S 1.000.000 GENERALAGGR83ATE S 2.000.000 GEM AGGREGATE LIMIT APPLIES PER: PR000CT8-CCMP/OP AGG S 2.000.000 POLICY PRO•IECT F-1 LOC --- S AUTOMOBILE LIABILITY 1.000 ANYAUTO BODILY INJURY(Per Poison) S A AA�,�1® X AUTOS �D BA038?B91 2/192012 2/132013 BODILY INJURY UWa ddenq $ X HIRED AUTOS X AUT ® aockent $ t UMBRELLA LLABOCCUR EACH OCCURRENCE $ EXCESS UAB HCLAIMS4MOE AGGREGATE S R $ WORMERS COMPENSATION AND EMPLOYERS'LIABILITY YIN ITORYUIMI ANY PROPRI TORIPARTNEWEXECUTNE E.L.EACH ACCIDENT S OFFlCERIMEMSEREXC.UDED? NIA (MandNmyIn rel) EL CS(i18E-FA BAPLOYE YES If deecd1X]Nbe under POF OPERATIONS beIDW E..a8EASE-POLICY UMIT i DESCRIPTION OF OPERATIONS I LOCATION$I VEHICLES ch ACORD 101,Additional Rwnarlre Schad If mores m h required) Properly Rame:Royel Cred (Nath Andover) (� rdo Pa n9 ) Conbed No.:14649-404879-CP-00002 Coverage Mdudes CER as Additlonel Insureds. CERTIFICATE HOLDER CANCELLATION AIMCA NORTH ANDOVER,LLC. 50 RoYw Grow Drive SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Nodh Andover.MA 01846 ACCORDANCE WITH TME POLICY PROVISIONS. AUTHORIZEDREPRESENTATVE C1190111 M54# Cert Holder# ®1888 2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD �® CERTIFICATE OF LIABILITY INSURANCE r DATE(MMIDDNYW) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT, If the certificate holder is an ADDITIONAL INSURED,the pollwAles)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement s PRODUCER FRED C CHURCH INC Co E: CONNECTOR PARK 41 WELLMAN ST veoee o�Illl:L�ZB)45 16 Ne 5 1 LOWELL, MA 01851 E4FAL AWRE06: INSUR AFFORDING COVERAGE NAICS INSURER A INSURED INSURERS: THOMAS H KINNAL DBA EAST COAST GENERAL CONTRACTING INSURER C: 286 BROADWAY INSURER D: HAVERHILL MA 01832 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 13w102_4 REVISION NUMBER. THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, p EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, LTR TYPE OF INSURANCE POLICY NUMBER PO EFF PNDLN:Y P LIMITS GENEWLLLIABIUTY EACH OCCURRENCE $ COMMERCIALOENERALLUIBILRY ooartenee $ CLAIMS44ADF n OCCUR ME)EXP(Any oneperson) $ PEtSONALAADVIWURY $ GENERAL AGGREGATE S GENT AGGREGATE LIMIT APPLIES PER: PRODUCM-COMPIOPAGG S PoUCY PRO Loc $ AUTOMOBILE LIABILITY NuLt UNIT i . ANYAUrO SODILYINJURY(Pwpenon) $ ALLOWNEI SCHEDIAPD AUTOS AUTOS BODILYINJURY(Peraxllem S HIREDAUIUB F1 AUNT r S $ UMBRELIAUAB OCCUR EACH OCCURRENCE EXCESSUAa CLAIMS-MADE AGGREGATE S ' i DED RETENTION S $ S S A WORKERS COMPENSATION WC5.319-353615.022 2/23/2012 2/23/2013 pTH AND EMPLOYERS'UABILITY YIN TORYLIMrTB ER ANY OPFI(M MEMBER�EJOLIJAE�UiNEa N/A EL.FACHAOCIDE4T S 5=00 (MarpmtscribeMIn ) EL 131SEASE-EAEMPLO $It IPTIONOFO EL DISEASE-POUCYUMIT S 5=00 DESCRIPTION OF TIONS below OEBCRIPTKIN OF OPERATIONS/LOCATIONS I VENICLES(Adaeh ACORD 101,Additional Rma"Sched=Smote apace Is nqu" THE WORKERS COMPENSATION POLICY DOES NOT PROVIDE COVERAGE FOR THOMAS KINNAL Workers compensation insurance coverage applies only to the workers compensation taws of the state MA. HOLUER SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE AIMCO NORTH ANDOVER L.L.C. THE EXPIRATION DATE THEREOF, NOTICE WILL TGE DELIVERED IN 50 ROYAL CREST DRIVE ACCORDANCE WITH THE POLICY PROVISIONS. NORTH ANDOVER MA 01845 AUTHORIZED REPRESENTATIVE ', H fid � Jeff Eldridge ®1988 2010 ACORD CORPORATION. AN rights reserved. ACORD 25(2010105) The ACORD name and logo are registered marks of ACORD Ci01?NO., 13591924 Anne Chandler 7/13/2012 6:23e36 AN Page 1 of 1 Thio certificate caaaelo and eupereedea ALL prey oly iooued cortificatee. V Location f�b )d No. 44 5—I Date 1 e - TOWN OF NORTH ANDOVER • _ Certificate of Occupancy $ Building/Frame Permit Fee $ , t Foundation Permit Fee $ � raAn,y ^' Other Permit Fee $ TOTAL $ Check#-6u,21 25520 Building Inspector