Loading...
HomeMy WebLinkAboutBuilding Permit #179 - 53 QUAIL RUN LANE 9/2/2009 BUILDING PERMIT °f NORTH q TOWN OF NORTH ANDOVER o° I ` y APPLICATION FOR PLAN EXAMINATION Permit N0: Date Received p°A4 T!° SFy�y 9SStCHUS�� Date Issued: f IMPORTANT:Applicant must complete all items on this page A x i''`-1 1; YA'f NE � QCATf, �ttAPnNO�° � � ,AF��E ONI GrST � .�Fttstort�C��kstrlCt �"'` rY o � p I<tlachne`Slla�e yeses -no TYPE OF IMPROVEMENT PROPOSED USE Resid Non- Residential New Building Onefamily Addition wo or more family Industrial Alteration No. of units: / Commercial Repair, replacement Assessory Bldg Others: Demolition Other II ` t(oodplaln W tfarids � ateshed R�trtct f f I DESCRIPTION OF WORK TO BE PREFORME M 1 �hGiv Re, a d o vim. ,sG"i aG Gcw�l4tt bac{. Identification Please Type or Print Clearly) OWNER: Name: Al '/P-e- Phone: Address: 53 Qua.;1 Aum , ONTRAC�OR Name' � Phone _ � �' /�idreSS n ~ - nstrLtGttOrlL MN '#a3at_ t Horne trraprorement tcer�se ..- t _ p Date . ARCHITECT/ENGINEER f l� Phone: N� Address: N JA Reg. No. �)IA. FEE SCHEDULE.BULDING PEIRRMIT:$12.00 PER$1000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost: $ 7 /3, 00q . It FEE: $ 15-k Check No.: I Receipt No.: NOTE: Persons con ratting withun egistered contractors do not have access to the guaranty fund Sec Co+v ' rrat tr--i A ent/Owrier` . Si afore of contracfor _ Plans Submitted Plans Waived Certified Plot Plan Stamped Plans TYPE OF SEWERAGE DISPOSAL Public Sewer Tanning/Massage/Body Art Swimming Pools Well Tobacco Sales Food Packaging/Sales Private(septic tank,etc. Permanent Dumpster on Site THE FOLLOWING SECTIONS FOR OFFICE.USE ONLY INTERDEPARTMENTAL SIGN OFF - U FORM DATE REJECTED DATE APPROVED PLANNING & DEVELOPMENT COMMENTS CONSERVATION Reviewed on Signature COMMENTS F EALTH Reviewed on Signature. COMMENTS 1 Zoning Board of Appeals: Variance, Petition No: Zoning Decision/receipt submitted yes Planning Board Decision: Comments Conservation Decision: Comments Water & Sewer Connection/Signature&Date Driveway Permit DPW Town Engineer: Signature: Located 384 Osgood,Street Dimension Number of Stories: Total square feet of floor area, based on Exterior dimensions. Total land area, sq. ft.: ELECTRICAL: Movement of Meter location, mast or service drop requires approval of Electrical Inspector Yes No DANGER ZONE LITERATURE: Yes No MGL Chapter 166 Section 21A—F and G min.$100-$1000 fine NOTES and DATA— For department use ❑ Notified for pickup - Date Doc.Building Permit Revised 2008 Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits ❑ Building Permit Application ❑ Workers Comp Affidavit ❑ Photo Copy Of H.I.C. And/Or C.S.L. Licenses ❑ Copy of Contract ❑ Floor Plan Or Proposed Interior Work ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit Addition Or Decks ❑ Building Permit Application ❑ Certified Surveyed Plot Plan ❑ Workers Comp Affidavit ❑ Photo Copy of H.I.C. And C.S.L. Licenses ❑ Copy Of Contract ❑ Floor/Crossection/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (if Applicable) ❑ Mass check Energy Compliance Report (If Applicable) ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit New Construction (Single and Two Family) ❑ Building Permit Application ❑ Certified Proposed Plot Plan ❑ Photo of H.I.C. And C.S.L. Licenses ❑ Workers Comp Affidavit ❑ Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Copy of Contract ❑ Mass check Energy Compliance Report ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit In all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals that the appeal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording must be submitted with the building application Doc:INSPECTIONAL SERVICES DEPARTMENT:BPFORM07 Revised 2.2008 Location l9 v No. � Date NaR,h TOWN OF NORTH ANDOVER �? •. • OL 9 ' Certificate of Occupancy 4L � •; P Y $ sA�MuSEt� Building/Frame Permit Fee $ Foundation Permit Fee $ Other Permit Fee $ TOTAL $ Check # �' r Building Inspector BUSINESS CONDITIONS TO THIS CONSTRUCTION CONTRACT This Contract, dated 07/13/2009 is by and between: Al Yee and Barbara Noga 53 Quail Run North Andover, MA 01845 Blackdog project code YEE-8802 (Hereafter referred to as OWNER), and Blackdog Builders, Inc. 7 Redroof Lane, Unit#1 Salem, NH 03079 (603)898-0868 Hereafter referred to as CONTRACTOR). Work will be performed at: 53 Quail Run, North Andover, MA 01845 (Hereafter referred to as PROPERTY) 1. GENERAL This CONTRACT is for the following work and materials to be performed by the CONTRACTOR on the PROPERTY address shown above. The project is generally described as follows: Remove and replace kitchen remodel (Hereafter referred to as WORK) The CONTRACT consists of this document, any plans, the specifications, the Blackdog client package and the Construction Contract. (Hereafter collectively referred to as the"CONTRACT") 2. PRICE The total price for the WORK agreed upon is $13,004.71. Payment terms are set out below in Paragraph 6. This proposal may be withdrawn by us if not accepted within thirty(30)days. 3. STARTING AND COMPLETION PROVISIONS The WORK will begin on approximately 9/2009 and will be completed, absent unusual or unforeseen circumstances, on 10/2009 providing this CONTRACT and any related CONTRACT documents are accepted when presented. Projects requiring two contracts(one for construction work and one for bath or kitchen product) will not be slotted into the schedule until both agreements have been executed. The aforementioned dates reflect our present workload. Projects are assigned a slot in our work schedule as they are accepted, on a first come first served basis. These dates may move based on the completion time of the project that immediately preceded yours. 4. PERMITS AND APPLICABLE CODES: COMPLIANCE WITH LOCAL LAW a. All work to be done under this CONTRACT will be in accordance with local, state and county building code. The CONTRACTOR shall obtain all necessary permits and pay all required permit and plan fees from, the CONTRACT sum, unless otherwise agreed. The CONTRACT price does not include any fees, which may be incurred to obtain a variance, if required. The CONTRACT price does not include any unbid items required by any local building official to bring the project into compliance with any relevant local, state and county building code. 07/13/2009 Contract Proposal—Page 4 of 18 b. All home improvement contractors/subcontractors working in the state of Massachusetts must be licensed and registered by the Bureau of Building Regulations and Standards. All inquiries concerning the CONTRACTOR should be transmitted to that office. In Massachusetts Blackdog Builders, Inc. operates under License number CS048847 and Registration number 106877. 5. SPECIFIC REQUIREMENTS FOR MATERIALS AND WORKMANSHIP a. This CONTRACT will be completed by the CONTRACTOR in a good and workmanlike manner, using quality materials. b. If applicable, the CONTRACT price includes the following allowances: See allowances under specifications. 6. PAYMENT a. Timely payment by the OWNER of all sums due under this CONTRACT is of the essence to this CONTRACT.The parties agree to the following schedule of payments: Deposit with this contract: $650.24 V Payment Schedule amounts reflect a Partner Plan credit of$750.00 b. Payment Schedule Start of demolition $2,669.03 Start of electrical rough-in $2,669.03 Start of countertops $2,669.03 ak,r.. a% -��....beb�> -� � $2,669.03 Substantial Completion $580.22 Completion of Punch List $348.13 c. Allowances for Owner Selected Components d. The CONTRACTOR may cease operations if any payment is not made by the OWNER as required herein, and proceed to collect any balance due through any remedy provided by law. Payments are due when the aforementioned progress milestones have been reached. It is understood that minor adjustments to the payments schedule may be necessary due to the flow of work or delays beyond the control of the CONTRACTOR. e. DEFINITIONS Substantially complete-The space or project is substantially complete when the space or project can be used for its intended purpose and only punch list items remain. Punch list-Work or product that has not been performed or provided. Warranty item -A product or service that has been provided or performed that does not meet or exceed industry standards. THESE CONDITIONS MUST BE ACCOMPANIED BY THE CONSTRUCTION CONTRACT 07/13/2009 Contract Proposal—Page 5 of 18 Section II Construction Contract of the Contract/ Proposal for Al Yee and Barbara Noga CONSTRUCTION CONTRACT This Contract is by and between: Al Yee and Barbara Noga hereafter referred to as "OWNER", and Blackdog Builders, Inc hereafter referred to as "CONTRACTOR" for work at 53 Quail Run, North Andover, MA 01845 dated 07/13/2009. This CONTRACT consists of this document, any plans, the Specifications and Business Terms that are enclosed and the Blackdog Builders Client Package. (Hereafter collectively referred to as the"CONTRACT") 1. CONTRACTOR'S DUTIES--GENERAL a. To direct and control the work contracted for in accordance with the terms of this CONTRACT and all applicable codes, laws, and regulations, and as the building permits issued for this project, if any, require. b. To inspect the site, examine the plans and specifications, if any, and supervise all of CONTRACTOR's employees, and to direct the work of all subcontractors selected by CONTRACTOR. c. To maintain the work site in a safe and clean condition, to the extent consistent with the CONTRACT. d. To advise the OWNER promptly if concealed conditions are ascertained which require additional or different work, and to proceed in such event in accordance with this CONTRACT. e. To provide locked storage for any equipment, tools, or other PROPERTY used in the performance of this CONTRACT, unless otherwise agreed in writing. 2. OWNER'S DUTIES--GENERAL a. To provide adequate utilities for the work agreed upon. b. To advise the CONTRACTOR of any condition of the PROPERTY which affects CONTRACTOR's ability to perform. c. To provide secure storage areas for materials delivered to the work site. d. OWNER shall be entitled to make periodic inspections of the work site, provided such inspections do not interfere with the work and can, in the judgment of the CONTRACTOR, be made safely. Any other entry onto the construction site shall be at OWNER's risk. e. OWNER shall notify his insurance agent of the execution of this agreement and obtain any necessary riders to his current coverage or any locally customary forms of coverage, such as builders risk, to cover OWNER's interests and liabilities during the construction process. IF. To perform no work on the project without a written agreement with the CONTRACTOR. g. To make no agreements with any trades person, subcontractor, or CONTRACTOR'S employees outside the scope of this CONTRACT without the written consent of the CONTRACTOR. 07/13/2009 Contract Proposal—Page 7 of 18 3. MATERIAL SUBSTITUTION CONTRACTOR reserves the right to substitute other materials, products and/or labor of equal or superior quality, utility, or similar color. 4. DELAY CONTRACTOR shall not be responsible for delays caused by events beyond the control of the CONTRACTOR, including but not limited to: strikes, war, acts of God, riots, governmental regulations and restrictions. Delays caused by OWNER's failure to make allowance materials selections or caused by the performance by CONTRACTOR of extras or necessary work(as described in Paragraph 6)shall likewise be excusable delays. & INSURANCE CONTRACTOR agrees to maintain all necessary forms of insurance to protect the OWNER from liability for any occurrence arising from the performance of this Contract. CONTRACTOR agrees that he shall cover his own employees for worker's compensation and carry general liability insurance, and that all forms of insurance referenced herein shall be with reputable companies licensed to do business in the state where the project is located. 6. HIDDEN. CONCEALED and UNFORESEEN CONDITIONS a. The parties agree that in the event CONTRACTOR discovers a hidden, concealed or unforeseen condition requiring an extra cost that they shall proceed as follows: The CONTRACTOR shall notify the OWNER verbally to expedite agreement as to any charge necessary to correct or cure such condition, and provide a written Work Order (as described in paragraph 7a) as soon as practicable. The parties must agree to such extra charges, or agree to a resolution method, or this CONTRACT may be cancelled by either of them. b. For purposes of this section, a "hidden, concealed and unforeseeable condition" shall mean a condition not readily observable to a prudent CONTRACTOR inspecting the subject PROPERTY for the purpose of performing this Contract. Examples of such conditions can include, but are not limited to; rot under siding; ledge below grade; pre-existing plumbing or electrical work not performed to code and pre-existing mold. c. Any change in the WORK required by building officials assigned to this project, including structural and/or any environmental hazards will be billed as an EXTRA charge to this CONTRACT and paid for by the OWNER as a Work Order. CONTRACTOR may cease operations if OWNER refuses to pay 7. EXTRAS a. Any extra work or materials desired by the OWNER shall be agreed upon in writing and such extras shall become a part of this CONTRACT as if fully set forth herein. Unless otherwise agreed, extra work shall be paid for as performed. Failure of the OWNER to sign a change order shall not preclude recovery for any work performed by CONTRACTOR, and acceptance of said extra work or materials shall be presumed, unless there is written notice to the contrary. b. CONTRACTOR shall advise OWNER, at the time of agreement on an extra, as to any additional time required to perform this CONTRACT. 07/13/2009 Contract Proposal-Page 8 of 18 8. ESCALATION CONTRACTOR reserves the right to pass on additional costs to OWNER resulting from the escalation of the cost of lumber or lumber byproducts. This cost may be passed on only, if after the CONTRACT is signed but before the construction commences, an increase in lumber costs is experienced. The CONTRACTOR must substantiate the change with evidence of the difference between lumber costs at the time of the CONTRACT and lumber costs at the time of construction. Only direct cost differences may be passed on, no allowances for overhead and profit shall be included. Any additional costs will be collected per Work Order(as described in paragraph 7a.). 9. EXCESS MATERIALS ON SITE CONTRACTOR routinely stores extra materials on site to improve efficiency and reduce the likelihood of running out of stock in the middle of a task. Unless otherwise specified in writing all excess materials on site at the end of the project are the PROPERTY of CONTRACTOR. 10. SUBCONTRACTORS a. CONTRACTOR shall select subcontractors as required to complete this CONTRACT. OWNER acknowledges that subcontractors will do various portions of the work. Any subcontractor selected by the CONTRACTOR shall have all requisite licenses for the work to be done by such subcontractor. b. It shall be the duty of the CONTRACTOR to use reasonable care in the selection of subcontractors. Absent objectionable performance by any subcontractor, the selection of subcontractors shall be an exclusive right of the CONTRACTOR. The CONTRACTOR shall require all subcontractors to have workmans compensation and liability insurance in force. c. CONTRACTOR shall pay subcontractors in a timely manner and obtain from subcontractors any necessary documentation required to release their liens, if any, as the work proceeds.. 11. TERMINATION AND CANCELLATION The CONTRACTOR may terminate and cancel this CONTRACT if any payment called for hereunder is not received as scheduled, provided that notice is given to the OWNER as provided below. Upon such termination, the CONTRACTOR shall have all remedies provided by law, including such lien rights as then apply. The OWNER may terminate this CONTRACT upon the following conditions: a. Failure of the CONTRACTOR, or his subcontractors, to pursue the work contracted for, absent excusable delay, as provided in Paragraph 4 above, for a continuous period of fourteen (14) days, without a written agreement permitting same, such agreement may be satisfied by a single notation to this CONTRACT. b. Failure of the CONTRACTOR to rectify any condition for which building code enforcement authority has issued a citation of violation notice, within fourteen (14) days notice of such violation, unless OWNER and CONTRACTOR otherwise agree. c. Any other failure to perform this CONTRACT required by the terms of this CONTRACT. 07/13/2009 Contract Proposal—Page 9 of 18 d. No termination shall be effective unless 10 days notice of OWNER's intent is given as required below, during which time the default may be cured by the CONTRACTOR. e. Deposit monies - Cancellation of this CONTRACT prior to the commencement of work shall result in the forfeiture of any and all deposit monies collected. All deposits are non-refundable. The parties hereby agree that upon such cancellation, the CONTRACTOR shall suffer damages including but not limited to the cost associated with designing and preparing the project for commencement. f. You may cancel this agreement by observing the requirements of The Notice of cancellation you have received. g. If a dispute arises out of or is related to this Contract, or the breach thereof, the parties shall endeavor to settle the dispute first through direct discussions. If the dispute cannot be settled though direct discussions, the parties agree the dispute shall be settled by arbitration administered by the American Arbitration Association under its Construction Industry Arbitration Rules. In the event that arbitration is necessary, the parties agree that arbitration proceedings shall be conducted by a mutually agreed on arbitrator in Rockingham County, New Hampshire. if the parties cannot agree on an arbitrator, either party may file a written demand for arbitration in accordance with the rules of the American Arbitration Association. The arbitration award shall be final and judgment on the award may be entered in any court having jurisdiction thereof. This CONTRACT shall be governed and interpreted in accordance with the laws of the State of New Hampshire. The parties acknowledge that this agreement to arbitrate shall be governed by Chapter 542 of the New Hampshire Revised Statutes Annotated. Either party may, without waiving any remedy under this CONTRACT, seek from any court having jurisdiction any interim or provisional relief that is necessary to protect the rights or PROPERTY of that party, including but not limited to the right to seek liens or attachment. The prevailing party in any dispute arising out of or relating to this CONTRACT or its breach that is resolved by a binding dispute resolution process shall be entitled to recover from other party reasonable attorneys' fees, costs and expenses incurred by the prevailing party in connection with such dispute resolution process. Consumers in Massachusetts shall be required to submit to such arbitration as provided in MGL c. 142A. *YeBarbara Noga6 Brenda Bryan, CKD Vice President Blackdog Builders, Inc. Notice: The signature of the parties above constitutes an acknowledgement of the agreement between the parties to alternative dispute resolution. Massachusetts consumers may have the right to initiate alternative dispute resolution even where this section is not signed by the parties. h. Unless otherwise agreed in writing, CONTRACTOR shall continue the WORK and maintain the agreed work schedule during any dispute resolution proceedings. If CONTRACTOR continues to perform, Owner shall continue to make payments in accordance with this Contract. 07/13/2009 Contract Proposal—Page 10 of 18 12. ENVIRONMENTAL HAZARDS a. The CONTRACTOR is NOT responsible for the inspection, discovery, abatement or removal of any environmental hazard including, but not limited to: asbestos; mold; lead; radon; ground water or environmental pollution at the work site, unless specifically covered in the specifications. b. In the event that any hazardous material is discovered during the course of construction, the testing, abatement and/or removal shall be the sole responsibility of the OWNER. c. Any additional costs incurred on account of suspension of the construction or changes to the specifications due to a hazard or its removal are the responsibility of the OWNER and will be handled by a Work Order. d. In the event that work does not resume within 30 days of the stoppage, OWNER agrees to immediately pay the CONTRACTOR the pro rated amount of the CONTRACT price applicable to work done up to that point pursuant to the Contract. WARRANTY OWNER warrants that as of the date of this CONTRACT: (1)the PROPERTY(including the land, surface water, ground water, and improvements to the land) is, and will continue to be,free of all contamination, including (a) 'oil, petroleum products, and their by-products" (b) any"hazardous waste" as defined by the Resource Conservation and Recovery Act of 1976, as amended from time to time, and regulations promulgated thereunder; (c) any"hazardous substance" as defined by the Comprehensive Environmental Response, Compensation, and Liability Act of 1980, as amended from time to time, and regulations promulgated thereunder, specifically including asbestos and mold; and (d)any other"hazardous substance" (2)the PROPERTY is in compliance with all environmental laws and regulations; and (3) there are no underground tanks on the PROPERTY INDEMNITY OWNER expressly acknowledges and agrees that it will reimburse, defend, indemnify and hold harmless CONTRACTOR, all Sub-contractors, their successors, assigns and employees from and against any and all liabilities, claims, damages, penalties, expenditures, losses or charges(including, but not limited to, all costs of investigation, monitoring, legal fees, remedial response, removal, restoration or permit acquisition)which may, now or in the future, be undertaken, suffered, paid, awarded, assessed, or otherwise incurred as the result of: (a)any contamination, existing in, on, above or under the PROPERTY(including, but not limited to, contaminated soil, mold, buildings, facilities and/or ground water); (b)any investigation, monitoring, clean up, removal, restoration, remedial response or remedial work undertaken on the PROPERTY; and (c)OWNER'S breach of any warranty given herein. 13. WARRANTIES a. The work of the CONTRACTOR, including materials and labor, shall be warranteed for a period of three (3) years, during which period CONTRACTOR shall at its own expense correct any defect arising from its work unless it is a non-warrantable condition as set out in the Blackdog Builders Client Package. That package shall become a part of this CONTRACT as if fully set forth herein. b. Any and all warranties for appliances or mechanical systems shall be delivered to OWNER as the CONTRACTOR receives them. 07/13/2009 Contract Proposal—Page 11 of 18 c. Notwithstanding any manufacturer's warranty of any component, appliance, or system, no action may be brought against the CONTRACTOR on this CONTRACT for the performance of this work, except as provided above. d. The quality of any work in question will be held to the standards issued in the Residential Construction Performance Guidelines—Third Edition published by the NAHB. 14. SEVERABILITY If any portion of this agreement is found invalid or unenforceable by any court, the remaining provisions shall remain in force between the parties. 15. ENTIRE AGREEMENT This CONTRACT consists of the documents defined herein, and constitutes the entire agreement of the parties. It can be modified only by a written document. OWNER acknowledges that he has read and received a legible copy of this agreement signed by CONTRACTOR, before any work was done, and that he has read and received a legible copy of every other document that OWNER has signed during the negotiation of this Contract.. SUBMITTED: DATE Brenda ryan, C 07/13/2009 Vice President Blackdog Builders, Inc. ACCEPTED: DATE: Al Yee DATE: 3 C Barbara Noga 07/13/2009 Contract Proposal-Page 12 of 18 I 264 1/2" 475/811 2111 „4b" 36" 36 18" 36" 24" 4 3/4" 24" 16 7, O18 m 2 3 ry 14 �- — — — — —I — — — D/WO ry CANDLELIGHT CABINETRY $ BAR HARBOR BEAD50ARD (PENINSULA THAMSHAKER(MAIN KITCHEN) 21 � b I _ ULA BACK) I " 1- BDIS-04 box- 22 _ I 2. BERD36-55 m m 13 c� Stide �m 3. BD18.04 O I I O 5. 138.27 5536 uv/UT(TILT DONN TRAY) + S I m 6. BPHOb 7. SD33.03 in _ 8. B FH3012 -- µ in �— — 1 9• BD33.03 O �I} 10. BFH3012 JD 11. N361 8.24 m I O I - w/4 WIRE TRAY DIVIDERS 10 m 12. N 1536 L FE: RIGHT 13. N3018 m 11 d- 14. N2436 R 19 FE: LEFT 36" 15• j"IC4836 L FE: RIGHT `r 1b• N2136 R cn FE: LEFT 24. (4) GM-08 23 17. N3636 0 25. (3) 5M-08 : RIGHT 26. (3) MTK-08 18. TU36 27. (2) 50LID STOCK 06% TRIM TO 16-1/4"HIGH + 20 FURNITURE TOE ON PENINSULA BACK 19. TEP753090 FURNITURE TOE ON PENINSULA 51DETRIM TO 88" HIGH FURNITURE TOE ON FRIDGE 20. PAN4896BD E SIDE APPLY TO TEP ON LEFT 28. (2) 5LBM-OS (LIGHT RAIL) 21. Y48 RA Oc.aO CM/ S 22. SF33 23. PAN48485D -��- + COPYRIGHT RE5I0ENG BY BLACKDOG BUILDERS, INC. 01=. CLIENT NFEAPPROVAL: THESE PLANS MAY NOT BE O��/ 1 VAL: USED IN ANY NAY NITHOUTSUBJECT: FINAL LAYOUT � 5G,4LE: 1PAGE DESIGN 1/2"= ' WRITTEN PERMISSION OF i REMODELTHE COPYRIGHT OWNER DATE: G.H. 89-3/8" 31 ►TE: D7-13-2009 UNDERGABINET LIGHT SWITCHED AT UNIT UNDERGABINET LIGHT SWITCHED AT UNIT � I ------ I i I I d i I I I , TILT-DOWN I I I DRAWER FRONT I I I f SPICE DRAWER TOP TWO DRAWER5 PARTITION TOP DRAWER I I I 51LVERWARE/UTEN51L5 I I I I 4 WIRE TRAY DIVIDERS I a I 1 i I 1 i COPYRIGHT 81=51 . BY BLAGKDOG BUILDERS, INC. D�NG1= OF. THESE PLANS MAY NOT BE NOG /YEGL11=1�T ,4PPROY�4L: USED IN ANY WAY WITHOUTW �,1/ SCALE- D PAGERITTEN PERMISSION OF SUBJECT: PRESENTATION 1/2"= 1 ' REMODEL: THE COPYRIGHT 01^INER DATE: DATE: 07-13-2009 I , a { 1 J opmra mvp COPYRIGHT RE51DEN BYSLACKDOG BUILDERS, INC. CI= O�' GLI�NT ,4PP THESE PLANS MAY NOT BE N OGA/YE E ROVAL: ` U5ED IN ANY YNtAY kNITHOUT �A SG,4L�; PAGE 1/2"=1 ' � 1NRITTEN PERMISSION OF SUBJECT; REMODELTHE COPYRIGHT ONNER AS-$U ALT DATE: 07-13-200q i 1-7/8" X GROPNN z m _ - 5MALL LIGHT BAR MOLDING dJ - mr- GRANITE COUNTER r-- nl Ln i N m COPYRIGHT RE51 BY EILACKDOG BUILDERS, INC. DENCE OF. THESE PLANS MAY NOT BE NOGA/yEE CLIENT APPROVAL: ,8�/ SGA�LE: USED IN ANY YVAY 1NITHOUT PAGE. kNRITTEN PERM155ION OF 5 V B.1ECT: N O N REMODEL THE COPYRIGHT OYVNER DATE: G RO55 SECTION 71'3/p DATE: 07-13-200q F I•�s � l ��'� I�II� _ � '� �ll� li_I�I 'mill.— WA L 111 i��•i u�•i - r DESIGN Li REMODEL �� � �IIIIII�IIIIIII� �IIIIIII�IIUII� � �iiii �iiiii�l I 0 LWJ0 0 0 0 0 0 0 0 O p Go 0 0 0 O OO e ' COPYRIGHT RESIDENCE OF: /Y CLIENT APPROVAL: G�/ s Al 5CA�LE: PAGE BY BLAGKDOG BUILDER5, INC. N OCA/ Y E E NONE THE5E PLAN5 MAY NOT BE U5ED IN ANY WAY WITHOUT 5U$JECT: DATE: ��/3�a DANE: DES I GN4 WRITTEN PERMISSION OF ELEVATIONS 01-13-200q jk THE COPYRIGHT OWNER REMODEL tAORTH T0VM o Andover 0 No. / 7 over, Mass., 2 . 0 COOL KWICK .C:K 0)4A T E 0 ? C) BOARD OF HEALTH Food/Kitchen PERMI T Septic System D BUILDING INSPECTOR THIS CERTIFIES THAT ...... ....................... ........... ............. Foundation has permission to erect.......... ................ ...... buildings on ...... . ..... ....... Rough "U"U", Adalk Chimney ....... ......... to be occupied as.... ...... . ............. A 00�............................................................................. provided that the pe 'accepting this permit shall In every respect conform to the terms of the application on file in Final this office, and to the provisions of the Codes and By-Laws relating to the Inspection, Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR VIOLATION of the Zoning or Building Regulations Voids this Permit. Rough 0 Final PERMIT EXPIRES IN 6 UQ1 THS ,INELECTRICAL INSPECTOR UNLESS CONSTR TS Rough ..... Service BUILDING*.INSPECTOR Final Occupancy Permit Required to Occupy Building GAS INSPECTOR Rough Display in a Conspicuous Place on the Premises .— Do Not Remove Final No Lathing or Dry Wall To Be Done Until Inspected and Approved by the Building Inspector. Burner FIRE DEPARTMENT . Street No. SEE REVERSE SIDE Smoke Det. 264 1/2" 48" 4-15/5" 21" 36" 36" 15" lz 24" i4 3/4" 24" CCA CANDLELIGHT CABINETRY m 2 3 D/WO CHATHAM SHAKER(MAIN KITCHEN) N Sµ BAR HARBOR BEADBOARD (PENIN5ULA BACK) 21 6 1. 5015.04 2. 5ER036-55 bx-c� 22 _ 3. 50 18.04 �, Sidi cm O 13 _ 4. 5536 w/UT(TILT DOWN TRAY) �0 5. 5527 — P '� �i 6. 5PH06 m m 13 7. 5033.03 8. 5FH3012 --(p14 cw �— — j 9. 5033.03 1�4 131 11- N3615-24 Ln 12 O ( _ w/4 WIRE TRAY DIVIDERS m O 10 m 12.W 1536 L FE: RIGHT 13. N3018 14. W2436 R FE: LEFT Co 15. WG4836 L -ccm11 19 I 36" I FE: RIGHT 16. W2136 R FE: LEFT 17. W3636 C6 24. (4) GM-OS 23 FE: RIGHT 25. (3) 5M-OS 18. TU36 0 25. (3) MTK-OS TRIM TO 16-1/4" HIGH 27. (2) 50L10 5TOGK 0696 19. TEP753090 TRIM TO 88" HIGH FURNITURE TOE ON PENIN5ULA BACK 20. PAN4896BD 20 FURNITURE TOE ON PENIN5ULA 51DE APPLY TO TEP ON LEFT FURNITURE TOE ON FRIDGE 51DE 28. (2) 5LBM-08 (LIGHT RAIL) 2i. BF RA 22. 33 '11, 23. PAN4848BD COPYRIGHT RE51DENCE OF: l�/ 1 CLIENT ArPPROVAtL: 5CA�LE: PAGE BY BLACKDOG BUILDERS, INC. NOG /�/EE ��— 1 /2 -1 THE5E PLANS MAY NOT BE U5ED IN ANY WAY WITHOUT SUBJECT: FINL LAYOUT DATE: DANE: DESIGN WRITTEN PERM15SION OF THE COPYRIGHT OWNER �. . Sq-3IS 01-13-200q REMODEL UNDERGABINET LIGHT UNDERGABINET LIGHT 5WITCHED AT UNIT 5WITGHED AT UNIT I ; I D/W TILT-DOWN DRAWER FRONT � ( I I I I SPICE DRAWER TOP TWD DRAWER5 PARTITION TOP DRAWER 51LVER4NARE/UTEN51L5 i I I ( I I I 4 WIRE TRAY DIVIDERS COPYRIGHT RESIDENCE OF: /�/ CLIENT A�PPROVA�L: (� �� SCALE: � PAGE BY BLACKDO6 BUILDERS, INC. NOG 1 EE THE5E PLANS MAY NOT BE U5ED IN ANY WAY WITHOUT SUBJECT: PRESENTATION DATE: DATE:WRITTEN PERM155ION OF THE COPYRIGHT OWNER �. . 89-3/S 01-13-2009 REMODEL s ' COPYRIGHT RE5IDENCE OF: � CLIENT APPROVAL: 5CALE: PAGE BY BLACKDOG BUILDER5, INC. N OGAV/ � E E Z�A 1 /2 =1 THE5E PLAN5 MAY NOT BE U5ED IN ANY WAY WITHOUT 5U$JECT: DATE: DATE: DESIGN WRITTEN PERM155ION OF A5-BUILT -7/t 3`09 THE COPYRIGHT OWNER 01-13-2009 REMODEL 1 -?/5" X 1 -?/5" CRONN m 5MALL LIGHT BAR MOLDING m GRANITE COUNTER d' N Ln C11 m COPYRIGHT RESIDENCE OF: CLIENT APPROVAL: g,v SCALE: PAGE BYBLACKDOG BUILDER5, INC. NOGA/ I/�/EE NONE THESE PLANS MAY NOT BE U5ED IN ANY WAYINITHOUT 5UBJECT: DATE: -7//-3 o 9 DATE: WRITTEN PERMISSION OF OR055 SECTION 01-13-200q THE COPYRIGHT OWNER REMODEL � rlot �IIIIII�IIIIIII �IIIIII��IIIIII� Iiiiii� �iiiii� ni O O O O QD(D ®® al)® O O O O O O O WIWI -1 o 0 0 00 00 0 COPYRIGHT RE5IDENGE OP: /�/ CLIENT APPROVAL: G�/ s Al 5CA�LE: PAGE BY BLAGKDOG BUILDERS, INC. NOGA/ I EF. NONE THE5E PLAN5 MAY NOT BE USED IN ANY WAY WITHOUT 5 U BJ ECT: DATE: ��/3/r� DANE: DESIGN WRITTEN PERM15510N OF ELEVATIONS 0l-13-2009 THE COPYRIGHT OWNER REMODEL The Commonwealth ofMassaclzusetts Department of Iiidustrial Accidents Office Of Investigations '•.�� 600 Washington Street �f Boston,MA 02.711 www.mass gov/dia Workers' Compensation Insurance Affidavit: Builders/Contractors/Electricians/Plumbers Applicant Information Please Print Legibly Naine(Business/Organization/individual): 1 V Id�,�f• Address: City/State/Zip: , /JN D30#�Y Phone#: 603 89$' 0868 Are you an employer? Check the appropriate box: . I. I am a employer with 4. El am a general contractor and I Type of project(required): employees (full and/or part-time).* have hired the sub-contractors 6. ❑New construction 2.❑ lam a sole proprietor or partner- listed on the attached sheet 7. ❑Remodeling ship and have no employees These sub-contractors have g, ❑Demolition working for mein any capacity. employees and have workers' [No workers' comp.insurance comp. insurance.; 9. ❑Building addition required.] 5. ❑ We are a corporation and its 10.❑Electrical repairs or additions 3.❑ I am a homeowner doingall work officers have exercised their 11.[1 Plumbing repairs or additions myself. [No workers' comp. right of exemption per MGL 12.❑Roof repairs insurance required.] t C. 152, §I(4), and we have no employees. [No workers' 13.❑ Other comp.insurance required.] Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information. t Homeowners who submit this affidavit indicating they ere doing all work and then hire outside contractors must submit a new affidavit indicating such. tContractors that check this box must attached an additional sheet showing the name of the sub-contractors and state wbether or not those entities have employees. If the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing worlrers'compensation insurance for my employees. Below is the policy and job site information. Insurance Company Name: b0eI,64 Policy#or Self-ins.Lic.#: wC-A 90 9 a 4 0 Expiration Date:_ 1/1//0 Job Site Address: Jr' 526r^{' RVh.) City/State/Zip: N"i An1Q0VN" M . Attach a copy of the workers' compensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under Section 25A of MGL c. 152 can lead to the imposition of criminal penalties of a fine up to$1,500.00 and/or one-year imprisonment, as well as civil penalties in the form of a STOP WORD ORDER and a fine of up to$250.00 a day against the violator. Be advised that a copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certify under the in pen Ides ofperjrcry that the information provided above is true and correct Sisrtatu Date: Phone#: Official use only. Do not write in this area, to be completed by city or town official City or Town: Permit(License# Issuing Authority (circle one): 1.Board of Health 2.Building Department 3. City/Town Cleric 4.Electrical Inspector 5.Plumbing Inspector 6.Other Contact Person- Phone#: ACORD CERTIFICATE OF LIABILITY INSURANCE DAT 070912009 M. T PRODUCER Phone: (978)562-5652 Fax: 978-562-7120 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION WELSH&PARKER INSURANCE AGENCY,INC. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 131 COOLIDGE STREET,SUITE 100 HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR HUDSON MA 01749 ALTER THE INSURERS AFFORDING COVERAGE NAIC# INSURED INSURER A: Merchants Insurance Group BLACKDOG BUILDERS,INC. INSURER 8: Merchants Insurance Group BLACKDOG BUILDERS INVESTMENT HOLDINGS LLC INSURER C: Merchants Insurance Group 7 RED ROOF LANE#1 SALEM NH 03079 INSURER D: Merchants Insurance Group INSURER E: Merchants Insurance Group COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADD'L TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS LTR INSR DATE MM/DD DATE MM/DD GENERAL LIABILITY CMP9149773 07/01/09 07101/10 EACH OCCURRENCE $ 1,000,000 X COMMERCIAL GENERAL LIABILITY DAMAGE TO RENTED $ 100,000 PREMISES(Ea occurence) CLAIMS MADE F_X] OCCUR MED.EXP(Any one person) $ 5,000 B PERSONAL&ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG. $ 2,000,000 X POLICY PRD LOC JECT AUTOMOBILE LIABILITY CAP9265878 07/01109 07/01/10 COMBINED SINGLE LIMIT X ANY AUTO (Ea accident) $ 1,000,000 ALL OWNED AUTOS BODILY INJURY (Per person) $ SCHEDULED AUTOS C HIRED AUTOS BODILY INJURY NON-OWNED AUTOS (Per accident) $ PROPERTY DAMAGE $ (Per accident) GARAGE LIABILITY AUTO ONLY-EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY: AGG $ EXCESS/UM I EIRELLA LIABILITY CUP9139768 07101109 07101/10 EACH OCCURRENCE $ 1,000,000 OCCUR F CLAIMS MADE AGGREGATE $ 1,000,000 D $ DEDUCTIBLE $ x RETENTION $ 10,000 $ VAC STAT WORKERS COMPENSATION AND WCA9095570 07/01109 07/01110 roRY LILL MITS OTHER EMPLOYERS'LIABILITY E.L.EACH ACCIDENT $ 100,000 E ANY PROPRIETOR/PARTNERIEXECUTIVE OFFICERIMEMBER EXCLUDED? E.L.DISEASE-EA EMPLOYEE $ 100,000 It yes,describe under E.L.DISEASE-POLICY LIMIT $ 500,000 SPECIAL PROVISIONS below OTHER: DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLESIEXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS CERTIFICATE HOLDER CANCELLATION BLACKDOG BUILDERS,INC. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS BLACKDOG BUILDERS INVESTMENT HOLDINGS LLC WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO 7 RED ROOF LANE#1 DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER,ITS SALEM NH 03079 AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE Attention: Karen Gedenberg ACORD 25(2001/08) Certificate# 30250 ©ACORD CORPORATION 1988 BOARD OF BUILDING REGULATIONS License: CONSTRUCTION SUPERVISOR z Number: CS 094513 Birthdate: 08i28/1964 Expires: 0123/2009 Tr. no: 94513 Restricted: 00 TIMOTHY S WILLIAMS 272 CHESTNUT HILL ROAD ROCHESTER, NH 03867 _L Commissioner / "/A7 L.`C•AFltff•Xlt J'ftltJl f•�t {:et.:.,ttr'i[t::+.'f�.' Board of Building Regulations and Standards HOME IMPROVEMENT CONTRACTOR Registration: 106877 - � Expiration: 7/28/2010.. p Type: Supplement Card BLACKDOG BUILDERS, INC TIMOTHY WILLIAMS 7 RED ROOF LN.#1 Salem, NH 03079 Administrator License or registration valid for individul use only before the expiration date. If found return to: Board of Building Regulations and Standards One Ashburton Place Rm 1301 Boston,Ma.02108 I lid wi out signature