Loading...
HomeMy WebLinkAboutBuilding Permit #1348-2016 - 90 MIDDLESEX STREET 6/20/2016 V.. BUILUINU ljt:KMI I o? TOWN OF NORTH ANDOVER f ►- - ,� APPLICATION FOR PLAN EXAMINATION - Permit NO: , Date Received '� y � n e 4A V �•9 °RATED ,PP S S Date Issued: ACHoS� i ORTANT: Applicant must complete all items on this page LOCATION 1 Q' �r—,-L& Print PROPERTY OWNER JrJ Drint MAPNO: W PARCEL:ZONIN ISTRICT: Historic District yes/no o Machine Shop Village yes TYPE OF IMPROVEMENT PROPOSED USE Residential Non- Residential ❑ New Building : One family ❑Addition ❑Two or more family ❑ Industrial ❑Alteration No. of units: ❑ Commercial ❑ Repair, replacement ❑Assessory Bldg ❑ Others: ❑ Demolition ❑ Other ❑ Septic ❑ Well ❑ Floodplain ❑Wetlands ❑ Watershed District ❑ Water/Sewer I Identification Please Type or Print Clearly) OWNER: Name: Phone: 91 - h6- 320 Address: A WfQ r V�AlJ CONTRACTOR Name: IQA Phone: f /l l Address: Supervisor's Construction License: Exp. Date: Home Improvement License: Exp. Date: 10ho til ARCHITECT/ENGINEER Phone: Address: Reg. No. FEE SCHEDULE.BOLDING PERMIT.•$12.00 PER$1000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost: $ 10,000 FEE: $ W� Check No.: =-.L Receipt No.: NOTE: Persons contracting with unregistered contractors do not have access to the guaranty fund _ 1 _ Signature of A ent/OwnerSignature of contractor F w ' e of p10RTy q BUILDING PERMIT �<�� E� ;64�o TOWN OF NORTH ANDOVER � - 0 APPLICATION FOR PLAN EXAMINATION y `- � T e h Permit No#: Date Received �qs R�TEel "�c5 sA c H�s� Date Issued: IMPORTANT: Applicant must complete all items on this page LOCATION Print PROPERTY OWNER Print 100 Year Structure yes no MAP PARCEL: ZONING DISTRICT: Historic District yes no Machine Shop Village yes no TYPE OF IMPROVEMENT PROPOSED USE Residential Non- Residential ❑ New Building ❑ One family [I Addition ❑Two or more family 11 Industrial ❑ Alteration No. of units: ❑ Commercial ❑ Repair, replacement ❑Assessory Bldg ❑ Others: ❑ Depmolition ❑ Otherp 0_ . Se tic ❑Well ❑ Flood Iain D Wetlands Watershed district Water/Sewer DESCRIPTION OF WORK TO BE PERFORMED: Identification- Please Type or Print Clearly OWNER: Name: Phone: Address: Contractor Name: Phone: Email: Address: Supervisor's Construction License: Exp. Date: Home Improvement License: Exp: Date: ARCHITECT/ENGINEER Phone: Address: Reg. No. FEE SCHEDULE.BULDING PERMIT.$12.00 PER$1000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost: $ FEE: $ Check No.: Receipt No.: NOTE: Persons contracting with unregistered contractors do not have access to the guaranty fund owner Signature of contractor �- c. a Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits Building Permit Application Workers Comp Affidavit Photo Copy Of H.I.C. And/Or C.S.L. Licenses Copy of Contract Floor Plan Or Proposed Interior Work Engineering Affidavits for Engineered products OTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit Addition Or Decks 4, Building Permit Application 6 Certified Surveyed Plot Plan L Workers Comp Affidavit Photo Copy of H.I.C. And C.S.L. Licenses Copy Of Contract j Floor/Cross Section/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (If Applicable) Mass check Energy Compliance Report (If Applicable) Engineering Affidavits for Engineered products OTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit New Construction (Single and Two Family) Building Permit Application Certified Proposed Plot Plan Photo of H.I.C. And C.S.L. Licenses Workers Comp Affidavit Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) Copy of Contract 2012 IECC Energy code Engineering Affidavits for Engineered products OTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg. Permit In all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals that the appeal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording must be submitted with the building application Doc:Building Permit Revised 2014 1 f Plans Submitted Ca Plans Waived ❑ Certified Plot Plan ❑ Stamped Plans ❑ TYPE OF SEWERAGE DISPOSAL Public Sewer ❑ Tanning/Massage/Body Art ❑ Svc ening Pools ❑ Well ❑ Tobacco Sales ❑ Food Packaging/Sales ❑ Private(septic tank,etc. ❑ Permanent Dumpster on Site ❑ THE FOLLOWING SECTIONS FOR OFFICE USE ONLY INTERDEPARTMENTAL SIGN OFF m U FORM PLANNING & DEVELOPMENT Reviewed On Signature_ COMMENTS CONSERVATION Reviewed on Signature COMMENTS HEALTH Reviewed on Signature COMMENTS Zoning Board of Appeals: Variance, Petition No: Zoning Decision/receipt submitted yes Planning Board Decision: Comments 1, AL Conservation Decision: Comments Water& Sewer Connection/Signature& Date Driveway Permit DPW Town Engineer: Signature: Located 384 Osgood Street <<FIREDEP,4RaTMENT Temp ®umpster,ontsite'.:;yes , o z -- - 1,Locatedd�ats,1�24tMam�S t et. ire De atment si p $gnature/date s COMMTS Dimension Number of Stories: Total square feet of floor area, based on Exterior dimensions. Total land area, sq. ft.: ELECTRICAL. Movement of Meter location, mast or service drop requires approval of Electrical Inspector yes No DANGER ZONE LITERATURE: yes No MGL Chapter 166 Section 21A—F and G min.$1oo-$1000 fine NOTES and DATA— (For department apse) ® Notified for pickup Call Email f Date Time Contact Name Doe.Building Permit Revised 2014 r� Plans Submitted ❑ F46' aived ❑ Certified Plot Plan ❑ Stamped Plans ❑ TYPE OF SEWERAGE DISPOSAL Public Sewer ❑ Tanning/Massage/Body Art ❑ Swimming Pools ❑ Well ❑ Tobacco Sales ❑ Food Packaging/Sales ❑ Private(septic tank,etc. ❑ Permanent Dumpster on Site ❑ THE FOLLOWING SECTIONS FOR OFFICE USE ONLY INTERDEPARTMENTAL SIGN OFF - U FORM DATE REJECTED DATE APPROVED PLANNING & DEVELOPMENT ❑ ❑ COMENTS CONSERVATION ❑ ❑ COMMENTS QATE REJECTED DATE APPROVED HEALTH ❑ ❑ COMMENTS Zoning Board of Appeals: Variance, Petition No: Zoning Decision/receipt submitted yes Planning Board Decision: Comments Conservation Decision: Comments Water& Sewer Connection/Signature&Date Driveway Permit Located at 384 Osgood Street FIRE DEPARTMENT - Temp Dumpster on site yes no Located at 124 Main Street C Fire Department signature/date �i�� ��� /6 COMMENTS , fir' s Location L � I No. [ l i Date ( A Jt,�, . - TOWN OF NORTH ANDOVER • Certificate of Occupancy $ Building/Frame Permit Fee $ Foundation Permit Fee $ Other Permit Fee $ ~ TOTAL $ Check#0 Building Inspector r 1 V NORTH - W." 1 _ ic ve" . O �A o 24 R�. h ver, Mass �.. i A- C0C"1CKl WICK 1_ S U - BOARD OF HEALTH Food/Kitchen PER Septic System THIS CERTIFIES THAT .............. . .....44.... . t ............... BUILDING INSPECTOR ... .... ........... nnFoundation has permission to erect .......................... buildings on ...... .... d fe Rough to be occupied asAlto.... ...�lC4u Ch mney rovided that the erson acce tins permit shall in eve respect conform to the terms of the application p p accepting p every p pp Final on file in this office, and to the provisions of the Codes and By-Laws relating to the Inspection, Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR Rough T L D VIOLATION of the Zoning or Building Regulations Voids this Permit. Final PERMIT EXPIRES IN 6 MONTHS ELECTRICAL INSPECTOR UNLESS CONSTION Rough Service . ....... ....... .... ..... Final BUILDING I EC OR GAS INSPECTOR Occupancy Permit Required to Occupy Building- Rough Display in a Conspicuous Place on the Premises — Do Not Remove Final No Lathing or Dry Wall To Be Done FIRE DEPARTMENT Until Inspected and Approved by the Building Inspector. Burner Street No. Smoke Det. Y DIAMOND CONSTRUCTION, INC. 1 Worcester St.,Suite 10 Grafton,MA 01519 diamondconstructionma@gmail.com HIC License# 176910 DIAMOND CS Lic.080830 CONSTRUCTION INC. CONSTRUCTION AGREEMENT THIS AGREEMENT is made at On this day—eL of161 of 2016,by and between DIAMOND CONSTRUCTION, INC. (hereinafter the "Contractor") and 6 /14/ 4 &I (hereinafter the "Owner")located at WAj4 s DESCRIPTION OF SERVICES Diamond Construction,Inc.agrees to provide labor,materials,equipment and other facilities required to complete the following work: Scope of work '5�kpp iUAJ— &a 90off at the property located at which owner warrants that it is the owner with full authority to enter into-this agreement. Diamond Construction, Inc. agrees to start this project on f /6 and shall complete the work on / 06. , .If the project passes final inspection and Owner refuses to sign Notice of Completion,then Contractor may sign this Notice of Completion on behalf of Owner as it will be assumed that he is satisfied with the work. PAYMENT t C/2015-This document is binding and has serious legal consequences_Feel free to consult with a qualified attorney prior to signing. SCOPE OF WORK ILL 1] There will be a Project Manager inspecting the project 100% 2) Install Safety equipment before starting working j 100% ✓ I 1 3) Cover house&shrubs with tarpaulins for the protection fiii 1 100% C✓ ` 1 4) Strip 2 layers roof shingle all the way strait to the wood 100% ff 5) (Each additional layer plus$30.00 per layer/per SQ) _ ? 3 ? R If cedar$50/per SQ)(If Slate$90/SQ7JVi { 6) -Re-nail all loose roof boards 3 100% ✓ }' 7) If wood is needed,the extra charge is$47.00 per Yz" ? ? J CDX plywood or$4.00 linear foot of legend Boards _ E � 8) Install Leak Barrier/Ice and Water Shield: 100% GAF Storm Guard 0 Weather Watch 0 OR CertainTeed Winter Guard®:Sand RreGranular❑ High Tack/High Temperature(Film)0on 6 feet on the eaves,6 j 1 feet on the valley,3 feet on rakes and%"Overhang to the fascia I c � 1 � 9) Install Synthetic Underlayment 100% �_ ✓ 0 OR GAF Tiger Paw'"0 Deck-Armor J J I J �L CertainTeed Diamond Deck® �1. i !_ (1 10) Install Drip Edge: — , 100% ✓ 4 8"to the roof deck in 1"Overhang to the fascia aluminum to all ; 1 edges. Color Choice: White ET-Silver 0Brown 0 ! ! 11) Install Attic Exhaust Ventilation: t 100% ✓ j GAF Cobra® Rigid Vent7"11 Cobra® Snow Country"'0 or CertainTeed Ridge Vent 2-1/ I t I � 12) Install Ridge Cap Shingle: - � � 100% . ✓ GAF Timber Tex®0 Seal-A-Ridge®O or CertainTeed Ridge&Hip Cap 0/ 1 1 t 13)Apply Starter Strip Shingles to be aligned next to one t 100% ✓ another with sealant toward the eave. 14) California Cut(If any) J ( 17% I ! i 15) Install New Vent Pipes Of any) 100% DIAMOND CONSTRUCTION,INC. 1 WORCESTER ST,Suite 10,GRAFTON,MA 01519 ❖E-MAIL:diamondconstructionma@gmail com Phone:(508)365-7300-(508)688-4493 16)Install Metal Flashing at every dormers and Wall Areas 100% 17)Install New Aluminum Step Flashing to the Chimney 100% 18)(Lead Flashing Chimney at fair-market price ? ? 19)[dote:If the siding removal is needed,extra cost may apply for ? ? labor and material. 20)Install New Architect Roof Shin le: _�� GAF Timberline 0 Certai a ® Sq.Ft Color Choice: ' `�� 193 6,0 21)Clean all the Gutters on the New Roof 100% ✓ 22) Use 3ft magnet to remove all the nails from around the house 100% 23) Includes H Hurricane Nailing®Permits©Dumpster 100% ✓ 24) Material is supplied by Diamond Construction IN C. 100% ✓ 25) Sky Light X ` 26) Gutters X ? 27) Garage X ? 28) Fascia _X ? 29) Shed House X ? 30) Soffit X ? 31) RED MEANS: THAT IS NOT INCLUDED IN THE PRICE ESTIMATE OR CONTRACT.ADDITIONAL CHARGE WILL APPLY FOR LABOR AND MATERIAL. 32) This Symbol✓means that is included on the estimate or contract price. GRANT TOTAL $ DIAMOND CONSTRUCTION,INC. 1 WORCESTER ST,Suite 10,GRAFTON,MA 01519 ❖E-MAIL:diamondconstructionma@gmail.com Phone:(S08)365-7300-(S08)688-4493 DIAMOND CONSTRUCTIOY,INC. Owner agrees to pay Contractor the amount of$ . 0. (subject to adjustments j such as additions and deductions pursuant to authorized change orders).Owner shall pay for all permits,licenses and easements for permanent structures or permanent changes in existing facilities.In the event Owner obtains their own permits,Owners shall be excluded from Residential Contractor's Guaranty Fund pursuant to Mass.General haws Chapter 142A.City permits and licenses to complete the work shall be paid by Diamond Construction.All payments are due and payable upon receipt. Payments will be made according to the following schedule: 8�( cke c 4 Adtl � .00 Upon the execution of this agreement.$ p s gr ment.Includes material costs, permit costs, pster fee; $ .00(whichever is greater)of the contract sum upon commencement of the work; 1 .00(whichever is greater)of the contract sum upon completion of the work. If material/equipment required were special ordered there will be no exchanges, refunds,credits,or returns. - Payments shall be made in available U.S.funds and payable to"Diamond Construction,Inc."Payments made will be non-refundable once Contractor starts to perform, starts to demobilize in any way,engaged subcontractors,or has ordered materials.All payments will also be subject to deduction for administrative expenses.Owner agrees to pay $50.00 for each and any non-sufficient fund checks.If an invoice is not paid when due, interest will be added to and payable on all overdue amounts at 6%per year.Owner shall pay all costs of collection,including without limitation,court costs and reasonable attorney fees. PLANS/SPECIFICATIONS Prior to the start of the work,Owner shall provide to the Contractor all plans,surveys, specifications, drawings, blueprints, and reports describing the physical characteristics, soil, geological and subsurface conditions,utility locations, and similar documents that may assist Diamond Construction,Inc.in properly evaluating the extent and character of the work at the estimate stage.If any drawing, blueprint,floor plan, or specification violates or is in conflict with local law or/and ordinance, and where any such situation results in any necessary changes in the work, then Diamond Construction, Inc. shall be entitled to a reasonable adjustment to the Contract price and time to correct it. 2 C/2015-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing. DIAMOND CONSTRUCTION,INC. CHANGE ORDERS All change orders shall become part of this contract and incorporated by reference. The Owner shall notify Contractor of any changes in construction or plan and shall provide revised drawings,plans,or specifications followed by a change order. If the changes in the change order pertain to differing site conditions,errors in the plans and specifications, or other circumstances beyond the control of the Contractor (including acts by the government,fire,flood,unusual delay in transportation, abnormal weather conditions, labor disputes, strikes, war, lack of worksite access, acts of God, natural disasters, or acts of third parties),then Contractor shall submit to the Owner an estimate and proper adjustments to the contract price and time.If pricing is inapplicable, cost of the change or the amount of the adjustment shall be determined based on the cost to Diamond Construction plus reasonable amounts for overhead and profit. Contractor shall not be obligated to perform changes in the work or additional work until the Owner has approved,in writing,the changes to the contract price and time. SITE CONDITIONS Owner acknowledges the duty to disclose any and all pertinent and known hazardous condition information to Contractor and subcontractors and may not mislead or conceal any material or property facts such as how many layers of roof or type of roof was originally installed. Where a site owner does not disclose facts that subsequently cause delay or need further cost,then the Contractor will then be entitled to recover damages and a change order shall be allowed for additional costs. After consultation and agreement with the Contractor, Owner must immediately make an adjustment in the contract time and payment by issuing a change order if Contractor discovers and notifies owner of any of the following: (1)Hazardous Materials deemed by any federal, state or local governmental authority to pose a present or potential hazard to health,safety,or the environment; (2)Any Subsurface, visible, nonvisible, or latent physical conditions that are found unexpected or that seem different from the work agreed upon; (3) Unknown physical or other conditions that seem strange or materially different frp�n those encountered by Contractor's during and based on his construction experience. 3 C/2015-This document is binding and has serious legal consequences_Feel free to consult with a qualified attorney prior to signing. DIAMOND CONSTRUCTION,INC Upon discovery of any of the above, Contractor shall immediately stop work at that particular site. Contractor shall have no obligation to perform any corrective or remedial work. TERNUNATION Owner is required to first provide a 5 day advance notification of any alleged breach and allow Contractor 10 days to cure such alleged breach. Owner may terminate the Contract if the Contractor knowingly disregards applicable laws,statutes,ordinances,or local codes,has committed a material breach, if contractor made an assignment for a creditor,or becomes insolvent. Diamond Construction, Inc. may terminate this Contract if. Owner becomes insolvent, will not allow access to the site, Owner commits a material breach or fails to pay an invoice on time;work is suspended for 10 consecutive days through no act or fault of the Contractor or a Subcontractor, Sub-subcontractor or their agents or employees; or there is a stop work order by any court,or any stop work order issued by any town or authority. If any of the above occurs,then Diamond Construction shall send a written termination notice to the Owner and recover from the Owner payment for work performed,including reasonable overhead and profit,costs incurred by reason of such termination,and damages. If the Owner terminates the contract on convenience, he shall communicate of this intention writing to Contractor as soon as possible. Then, on or before the termination date, Contractor shall be paid its actual costs for that portion of the work performed to the date of termination and for all costs of termination, including demobilization and any termination payments already made to vendors and subcontractors, plus 20 percent of all such costs for overhead and lost profit. INSURANCE The Diamond Construction, Inc. shall carry and maintain throughout the project period valid Workers' Compensation and General Liability insurance. Certificates of insurance can be provided to Owner upon request prior to commencement of the work. Contractor ensure that the general liability coverage to includes the Owner as additional insureds for claims caused in whole or in part by the Contractor's negligent acts or omissions during the Contractor's work. 4 C/2015-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing. DIAMOND CONSTRUCTION,INC. The Owner must have and maintain throughout the project and until completion property insurance coverage (Builders Risk Insurance or other suitable cover) at minimum the amount of the contract price. Property insurance including loss or damage shall cover the Owner, Diamond Construction, Inc., Subcontractors and Sub-subcontractors for their interest m the Work and shall insure against the perils of fire with extended coverage and physical loss or damage including coverage for theft, vandalism, malicious mischief, collapse, debris removal. Owner waives all rights of recovery against the Diamond Construction, Inc.for loss of use of the Owner's property,including consequential losses due to fire or other hazards,however caused . If the Owner does not have and will not obtain property insurance,the Owner shall inform Contractor in writing prior to start of the work.If the Diamond Construction,Inc. is damaged by Owner's failure to have or maintain insurance as described above, without notifying the Contractor, then Owner will be responsible for all costs associated to such damage. Owner and Diamond Construction, Inc. waive all rights against each other and against all other Subcontractors and Owner for loss or damage to the extent reimbursed by any property or equipment insurance applicable to the work,except such rights as they may have to the proceeds of such insurance. If any applicable policies of insurance require an endorsement or consent of the insurance company to provide for continued coverage where there is a waiver of subrogation, the owners of such policies will cause them to be so endorsed or obtain such consent.Owner must not use or borrow any tools or ladders owned by Contractor. If Owner, without consent, uses Contractor's tools or ladder,then he shall hold Contractor harmless of any liability whatsoever and will not place any claim on Contractor's insurance. DELAY Diamond Construction,Inc. shall provide to the Owner notice of any delay in work. for changes necessary due to work schedule, suspension of work or any other unforeseen cause beyond Diamond Construction's control and/or where there is no fault by the Contractor, its Subcontractors or supp4ers. The contract time shall then be extended as necessary to accommodate delays via change order. SUSPENSION OF WORK 5 G2015-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing. DIAMOND CONSTRUCTION, INC. Diamond Construction,Inc.,may suspend work for Owner's failure to pay invoice on time, due to differing site conditions, or for changes requested by Owner where Contractor deems it may suffer financial hardship.If work is stopped for a period of 10 consecutive days due to no act or fault of the Contractor or a Subcontractor or their agents or employees; or if because the Owner has repeatedly failed to fulfill the Owner's obligations under the contract then Contractor, at his discretion, may immediately suspend work, terminate the Contract, and recover from the Owner. The Owner may suspend work vath advance notice to the Contractor. The written notice shall specify the date and the estimated duration of the suspension. Any Owner suspension shall not exceed 24 hours. Once the suspension is-removed, the Contractor shall resume performance of the Work as soon as it is possible. Owner will be liable then for all and any damages for suspension of work which may include costs of demobilization, extended overhead costs,jobsite costs,etc. Any suspension of work under this Contract will also suspend the progress and completion dates. FORCE MAJEURE If performance of this agreement or any obligation herein is prevented, restricted, interfered by reason of act of God, fire, flood, or other natural disaster, malicious injury, strikes, lock-outs, or other labor troubles, riots, insurrection, war or other reason of like nature beyond either party's reasonable control then performance of such act or obligation shall be excused for the period of the delay.If any delay under these circumstances exceeds 5 days,then either party shall have the option to terminate this Agreement. INDEMNIFICATION Diamond Construction,Inc. shall indemnify and hold Owner,its employees,officers, directors, and affiliates harmless from any loss, cost, expense, or damage claimed by third parties for property damage and/or bodily injury,including death,to the proportionate extent such loss, cost, expense, or damage arises from the negligence or willful misconduct of Diamond Construction,Inc.,its employees,officers,or directors in connection with the Contract or project.Owner shall indemnify,defend,and hold Diamond Construction,Inc.,its Subcontractors, employees, officers, directors, and affiliates harmless from and against any and all claims, demands,causes of action,liabilities,loss,cost,expense,or damage claimed by third parties for property damage and/or bodily injury, including death, to the proportionate extent such loss,cost,expense,or damage arises from the negligence,fault, or 6 CM15-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing_ DIAMOND CONSTRUCTION,INC. willful misconduct of Owner, architects, designers, its employees, officers, or directors in connection with the Contract or project. WARRANTY Diamond Construction, Inc. warrants that the work will be conducted in good professional workmanlike manner, and warrants that materials furnished will be of good quality and new. If within two years after the date of completion any of the work, it is found not to be in accordance with good craftsmanship, the Contractor shall correct it promptly after receipt of written notice from the Owner. The Owner shall give such notice promptly after discovery of the condition. During the two-year period for correction of Work, if the Owner fails to notify the Contractor then Owner waives the rights to require correction by the Contractor and to make a claim for breach of warranty.In the event that any of the provisions of the warranty shall be held invalid, the remainder of the provisions of the warranty shall remain in full force and effect. Where Contractor's repair warranty work involves the matching of existing finishes or materials,he will use his best efforts to match existing finishes and materials.However, Contractor does not guarantee an exact match due to such factors as discoloration due to the aging process, difference in dye lots,and difficulty of exactly matching certain finishes, colors,and planes.This warranty specifically excludes consequential damages and the following: , 1.Damage on shingles due to ordinary wear and tear,abusive use,normal wear and tear, improper use,misuse,or lack of proper maintenance of the home or its component parts or systems. 2.Defects,or loss or injury not caused by the negligence of Diamond Construction,Inc. or its subcontractors. 3.Defects in items installed by the Owner or anyone other than Diamond Construction,Inc. or its Subcontractors or defects in items supplied by the Owner. 4. Conditions not caused by Diamond Construction,Inc.and or it's Subcontractors resulting from condensation,or contraction of materials. ACCESS The Owner shall provide ample access to the site to Diamond Construction, Inc. throughout the project. Any delay or blocking of access by Owner will entitle Diamond Construction,Inc.to a reasonable adjustment in the contract price and time. 7 C/2015-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing. r , DIAMOND CONSTRUCTION,INC. INDEPENDENT CONTRACTOR STATUS The parties agree that the contractual relationship between Contractor and Owner is of an independent contractor.No documents signed create a partnership,join venture or any other relationship between the parties. ADDITIONAL CLAUSES. • Diamond Construction,Inc.'s suggestions are not a substitute for professional engineering, architectural,or design services,and are not to be relied on as such by Owner. • This agreement represents the entire agreement between the parties regarding the work described above and supersedes any prior written or any oral agreements or communications. This agreement may only be modified or terminated in writing. • No breach of any agreement,warranty or representation shall be deemed waived unless expressly waived in writing by the party who mi ght assert such breach. • If any clause of this Contract is determined to be illegal or unenforceable for any reason,it shall be severed from the Contract and the rest of the Contract shall be given full force and effect. The terms,covenants and conditions of this Contract shall be binding upon and shall inure to the benefit of the successors and permitted assigns of the respective parties to this Contract. • The agreement shall be governed by the laws of the Commonwealth of Massachusetts.The parties hereby agree to submit to the jurisdiction of the courts located within this Commonwealth for any controversies arising out of this agreement. • Owner hereby acknowledges he/she has had ample opportunity to consult with independent legal counsel,has read it,understands it,and is signing it freely and voluntarily. • If Owner is signing this agreement at his home,or at a place other than at the contractor's office or business,then there is a 3-day cancellation right. I as a.Owner of the subject property,hereby authorized DIAMOND CONSTRUCTION INC to-act on my behalf,in wall matters relative to work authorized by any building permit applications. Owner's Name: Vim' A69} Diamond Construction,Inc. Contractor, ivt Manager Owner's Signature: Phone: 9W_ <F6 337) Phon 1(508)365-7300 a v Email: Office:(508)6884493 diamondconstructionma@gmail.com 8 C/2015-This document is binding and has serious legal consequences.Feel free to consult with a qualified attorney prior to signing. DIAMOND CONSTRUCTION,INC. INDEPENDENT CONTRACTOR STATUS The parties agree that the contractual relationship between Contractor and Owner is of an independent contractor.No documents signed create a partnership,join venture or any other relationship between the parties. ADDITIONAL CLAUSES. • Diamond Construction,Inc's suggestions are not a substitute for professional engineering, architectural,or design services,and are not to be relied on as such by Owner. • This agreement represents the entire agreement between the parties regarding the work described above and supersedes any prior written or any oral agreements or communications. This agreement may only be modified or terminated in writing. • No breach of any agreement,warranty or representation shall be deemed waived unless expressly waived in writing by the party who might assert such breach. • If any clause of this Contract is determined to be illegal or unenforceable for any reason,it shall be severed from the Contract and the rest of the Contract shall be given full force and effect.The terms,covenants and conditions of this Contract shall be binding upon and shall inure to the benefit of the successors and permitted assigns of the respective parties to this Contract. • The agreement shall be governed by the laws of the Commonwealth of Massachusetts.The parties hereby agree to submit to the jurisdiction of the courts located within this Commonwealth for any controversies arising out of this agreement. • Owner hereby acknowledges he/she has had ample opportunity to consult with independent legal counsel,.has read it,understands it,and is signing it freely and voluntarily. • If Owner is signing this agreement at his home,or at a place other than at the contractor's office or business,then there is a 3-day cancellation right. I as a-Owner of the subject property,hereby authorized DIAMOND CONSTRUCTION INC to-act on my behalf,in wall matters relative to work authorized by any building permit applications. Owner's Name: VdA Diamond Construction,Inc. Manager Owner's Signature. Conttacto U 0 Phone: Q�c� 3�3 Ph(mV4508)365-7300 Email: Office:(508)688-4493 diamondconstructionmaC)amail.com 8 CR015-This document is binding and has serious legal consequences.Feel flee to consult with a qualified attorney prior to signing. The Commonwealth of Massachusetts Deparonent of IndustrialAccidents I Congress Street,Suite 100 Boston,MA 02114-2017 www mass gov/dia Workers'Compensation Insurance Affidavit:Builders/Contractors/Electricians/Plumbers- To BE FILED WITH THE PERIVUMNG AUTHOPSM Applicant Information PI a Print L 'bl vidName(BusinesslorgartionIni Address: t � S City/State/Zip: a7 7 OYl 5--O, Phone#: 5('�$• VCS L�a Are you an employer?Check the appropriate box Type of project(required): l.E21 am a employer with _employees(full and/orpart-time).* 7. E]New construction 2❑I am a sole proprietor or partnership and have no employees working for me in 8. ❑Remodeling any capacity.[No workers'comp.insurance required.] 9. ❑Demolition 3.Q I am a homeowner doing all work myself[No workers'comp.insurance required.]t 10❑Building addition 4.n I am a homeowner and will be hiring contractors to conduct all work on my property. I will ensure that all contractors either have workers'compensation insurance or are sole I L❑Electrical repairs or additions proprietors with no employees. 12. Plumbing repairs or additions S.Q 1 am a general contractor and I have hired the sub-contractors listed on the attached sheet 13.0 Roof repairs These sub-contractors have employees and have workers'comp.insurance; 14. Other 6.Q We are a corporation and its officers have exercised their right of exemption per MGL c. ° 152,§1(4),and we have no employees.[No workers'comp.insurance required.] *Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information t Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. tContractors that check this box must attached an additional sheet showing the name of the sub-contractors and state whether or not those entities have employees. if the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and job site information.Insurance Company Name:&4�or�Qa� AAAMu0. Policy#or Self-ins.Lic.#: C- ���17 �D�.1.." `1 1Q ExPiraonh = ��r7 Job Site Address: (40 1 Q�Q��P riQ�C � City/State/Zip:lj[ C �1C� � ►�1�� Attach a copy of the workers'compeassation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under MGL c. 152,§25A is a criminal violation punishable by a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of STOP WORK ORDER and a fine of up to$250.00 a day against the violator.A copy of this statement may be forwarded to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certify der the p ' d penalties of perjury that the information provided above is true and correct. Si afore: Date: Phone#: -g [[6. fficial use only. Do not write in this area,to be completed by city or town o fj`iciaL ity or Town- Permit/License# suing Authority(circle one): Board of Health 2.Building Department 3.City/Town Clerk 4.Electrical Inspector 5.Plumbing Inspector Issuing ontact Person• Phone#• THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT -NAME: Grady NEIGHBORHOOD INSURANCE LLC. PHONE 508-476-5535 Oct,No): 9 MAIN ST ADDRESS: jgrady@neighborhoodinsuranceagency.com SUITE 3A1 INSURERS AFFORDING COVERAGE MAIC 8 SUTTON,MA.01590 INSURER A: CATLIN SPECILATY INSURANCE INSURED INSURER B: Mapfre/COMMERCE INSURANCE DIAMOND CONSTRUCTION INC. INSURERC: A.I.M.MUTUAL 1 WORCESTER ST INSURER D: INSURER E: Grafton,MA01519 I INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION_OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR I ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE POLICY NUMBER MMIDD/YYYY) IMMIDDIYYYYJ LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 A CLAIMS-MADE ®OCCUR 20020028 4/06/2016 4/06/2017 DAMAGE (RENTED PREMISESS Ea occurrence) $ 100,000 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY❑PRO- F—] JECT LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ B AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ 1,000,000 X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED — AUTOS X AUTOSULED D32577 3/01/2016 3/01/2017 BODILY INJURY(Per accident) $ HIRED AUTOS NON-OWNED PROPERTY DAMAGE $ AUTOS Per accident $ UMBRELLA LUAB OCCUR EACH OCCURRENCE $ EXCESS LIAR FCLAIMS-MADE AGGREGATE $ DED T7RETENTION$ $ C WORKERS COMPENSATION PEROTH- AND EMPLOYERS'LIABILITY STATUTE ER ANY PROPRIETORIPARTNERIEXECUTIVE Y/N WWC 100 6017419 04/23/2016 /23/2017 E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? a N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYE $ 1,000,000 H yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT 1$ 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space is required) CERTIFICATE HOLDER CANCELLATION Twn of North Andover Building Dept SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 1600 Osgood St, BLD 20,Suite 2035 ACCORDANCE WITH THE POLICY PROVISIONS. North Andover,MA 01845 AUTHORIZED REPRESENTATIVE Jana Grady n ioRR_9niA ArnAn rnRanRATlnm All rinhtc ragpr M Massachusetts Department or ruol,c Qa,c.y + Board of Building Regulations and Standards license:CS-08MB30 Construction Supervisor ,may RYAN K HANNA fA P.O.130X#13372 L 'FAYWUE MA 01745 .. CA Expiration. Commissioner 04/09/2018 Sd(VA0VgWW*M M4 qe UOPIUMjUl Balsam SdO ov@sntpftw �! ►ai yol asneasl apo0 �Y 4110 GUIPIPM aM uoNwtt+auw a ssassod o;amps JO(sja;sw Tgria L86) algrq weds Pasolaue ula3uar y304M dnoj6 asn Aue10 s6ul 000,98 ue#ssel pPO-paiou�mun 1oswedng uoga�lnjgsu� Office of Consumer Affairs 9nd Business Regulation 10 Park Plaza - Suite 5170 Boston, Massachusetts 02116 Home Improvement-Contractor Registration Registration: 176910 Type: Supplement Card DIAMOND CONSTRUCTION INC. Expiration: 10102017 RYAN HANNA 1 WORCESTER ST SUITE 10 WORCESTER, MA 01604 Update Address and return card.Mark reason for change. scat �, 2nnn asr1 ❑ Address ❑ Renewal Employment------- -- ❑ P yment � Lost Card /e�coucurawuueall/a!'C�1ruaC1'irells - - -—- -- - ce of Consumer Affairs&Business Regulation License or registrahun valid for individul use only OME IMPROVEMENT CONTRACTOR before the expiration date_ If found return to: Registration_-y7ggjp= Type: Office of Consumer Affairs and Business Regulation Expiration:;=;1-0%1020.17 Supplement Card 10 Park Plaza-Suite 5170 DIAMOND CONSTRUCTION(NG_ Boston,MA 02116 RYAN HANNA 1 WORCESTER ST SUITE 1.0 WORCESTER,MA 01604 '-�� Undersecretary N va" withOutsignature