Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Building Permit #724-13 - 91 WOODSTOCK STREET 5/1/2018
TOWN OF NORTH ANDOVER APPLICATION FOR PLAN EXAMINATION Permit N0: Date Received Date Issued: IMPORTANT: Applicant must complete all items on this page LOCATION: Print PROPERTY OW ER � LwvA 4 Print 100 Year Old Structure yesno MAP NO. elf PARCEL: ZONING DISTRICT: Historic District yes no Machine Shop Village yes no TYPE OF IMPROVEMENT PROPOSED USE Residential Non- Residential ❑ New Building )(One family ❑Addition ❑Two or more family ❑ Industrial Alteration No. of units: ❑ Commercial Repair, replacement ❑Assessory Bldg ❑ Others: 1S Demolition ❑ Other ❑ Septic D Well ❑ Floodplain D Wetlands ❑ Watershed District Water/Sewer DESCRIPTION OF WORK TO BE PERFORMED: �&LA� "Wy-rJ ( Me (, G-e- 5 S C4C-4— — No �truG � p C rc�c-�IA� I5E ���' �1� ��'1►lU�"l �mc��r-e. �"vb � �,y�-all T-I�..� �hn� �' ivy Ti{k ���.s-► �� Identification Please Type or Print Clearly) OWNER: Name: Cv--aict 4 A A I I Phone: 916 - Z,08-���� Address: 91 LA)ooJ s 0 CONTRACTOR Name: kC'(.P 1/&'�rPhone: 603--896 -U86b Address:��P cw Supervisor's.Construction License: 9q S 1.3 Exp. Date: 8228//'3 d Home Improvement License: v(, Exp. Date: Ze) /4/ ARCHITECT/ENGINEER P/A Phone: N/1a Address: PLA Reg. No. N/A FEE SCHEDULE.BULDING PERMIT:$12.00 PER$1000.00 OF THE TOTAL ESTIMATED COST BASED ON$125.00 PER S.F. Total Project Cost: $ SIZ - 09 FEE: $ � Check No.: 2�2�' Receipt No.: NOTE: Persons contracting with unregistered contractors do not have access to the guaranty fund Si nafure of A ent/Owner sec Ca . Signature of contract%9amp;etdAPlans � . Plans Submitted 1K Plans Waived ❑ Certified Plot Plan ❑ ❑ i i Plans Submitted ❑ Plans Waived ❑ Certified Plot Plan ❑ Stamped Plans ❑ TYPE OF SEWERAGE DISPOSAL Public Sewer ❑ Tanning/MassageBody Art ❑ Swimming Pools ❑ Well ❑ Tobacco Sales ❑ Food Packaging/Sales ❑ Private(septic tank, etc. ❑ permanent Dumpster on Site ❑ THE FOLLOWING SECTIONS FOR OFFICE USE ONLY INTERDEPARTMENTAL SIGN OFF - U FORM DATE REJECTED DATE APPROVED PLANNING & DEVELOPMENT ❑ ❑ COMMENTS I I � i CONSERVATION Reviewed on Signature i COMMENTS HEALTH Reviewed on Signature COMMENTS � I i Zoning Board of Appeals: Variance, Petition No: Zoning Decision/receipt submitted yes f� .. I r Planning Board Decision: . Comments Conservation Decision: Comments Water & Sewer Connection/Signature Date Driveway Permit DPW TowL Engineer: Signature: Located 384 Osgood Street FIRE Dt' ' RTMENT - Temp Dumpster on site yes no Located at'124 MainStreet Fire Departi Teff,§ignature/date COMMENTS } Dimension Number of Stories: Total square feet of floor area, based on Exterior dimensions. Total land area, sq. ft.: ELECTRICAL: Movement of Meter location, mast or service drop requires approval of Electrical Inspector Yes No DANGER ZONE LITERATURE: Yes No MGL Chapter 166 Section 21A—F and G min.$100-$1000 fine NOTES and DATA— For department use i i El Notified for pickup - Date I I F Doc.Building Permit Revised 2010 Building Department The following is a list of the required forms to be filled out for the appropriate permit to be obtained. Roofing, Siding, Interior Rehabilitation Permits r� Building Permit Application Workers Comp Affidavit Photo Copy Of H.I.C. And/Or C.S.L. Licenses Copy of Contract Floor Plan Or Proposed Interior Work N ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit Addition Or Decks ❑ Building Permit Application ❑ Certified Surveyed Plot Plan ❑ Workers Comp Affidavit ❑ Photo Copy of H.I.C. And C.S.L. Licenses ❑ Copy Of Contract ❑ Floor/Crossection/Elevation Plan Of Proposed Work With Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Mass check Energy Compliance Report (If Applicable) ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit New Construction (Single and Two Family) ❑ Building Permit Application ❑ Certified Proposed Plot Plan ❑ Photo of H.I.C. And C.S.L. Licenses ❑ Workers Comp Affidavit ❑ Two Sets of Building Plans (One To Be Returned) to Include Sprinkler Plan And Hydraulic Calculations (If Applicable) ❑ Copy of Contract ❑ Mass check Energy Compliance Report ❑ Engineering Affidavits for Engineered products NOTE: All dumpster permits require sign off from Fire Department prior to issuance of Bldg Permit In all cases if a variance or special permit was required the Town Clerks office must stamp the decision from the Board of Appeals that the appal period is over. The applicant must then get this recorded at the Registry of Deeds. One copy and proof of recording must be submAted with the building application Doc: Doc.Building Permit Revised 2012 Location No. Date t • - TOWN OF NORTH ANDOVER Certificate of Occupancy $ Building/Frame Permit Fee $ " Foundation Permit Fee $ Other Permit Fee $ TOTAL $ :k F ' Check# ,;� Z T/ y 26346 Buil'dirig Inspector ' Enter construction cost for fee cal - North Andover Fee Cad ulation Construction Cost $ 45,312.00 m $ - $ 543.74 Plumbing Fee $ 67.97 Gas Fee 100 comm. $ 100.00 Electrical Fee $ 67.97 Total fees collected $ 779.68 91 Woodstock Street 724-13 on 5/2/2013 Partial Basement Remodel Storage Only Partial Remodel of First Floor Bathroom i i i NORTH own of ndover o .-KIP 10i zy CA_ 2 ?� ►� o h ver, Mass, COC NIC«l WIC« y�• �a p�R�TED ►'Pa,��y 7S u BOARD OF HEALTH Food/Kitchen PERM IT T D Septic System THIS CERTIFIES THAT ....v N.. `- 4 ""`m_.....0&tr-511qr'-11 BUILDING INSPECTOR ................... ........................................................................... �0 e� Foundation p ......... buildings on ....`�..�... has permission to erect ................. ........�0.............................:...................... l Q p n Rough to be occupied as � :!.� �. j�nyerha�- '\eMoc�rp ©�1� RP�no� Chimney ...............:........................... ......... ...... .Ue himne provided that the person accepting this permit shall in every respect conform to terms of the application Final on file in this office, and to the provisions of the Codes and By-Laws relating to the Inspection, Alteration and Construction of Buildings in the Town of North Andover. PLUMBING INSPECTOR VIOLATION of the Zoning or Building Regulations Voids this Permit. Rough Final PERMIT EXPIRES IN 6 MONTHS ELECTRICAL INSPECTOR UNLESS CONSTRUCTIO STARTS Rough Service ......... ..... .. � wyr�............................... Final BUILDING INSPECTOR GAS INSPECTOR Occupancy Permit Required to Occupy Building Rough Display in 'a Conspicuous Place on the Premises — Do Not Remove Final No Lathing or Dry Wall To Be Done .FIRE DEPARTMENT Until Inspected and Approved by the Building Inspector. Burner Street No. Smoke Det. SEE REVERSE SIDE Section of the uontract/ Proposal for Craig and Laura Marshall Business Cond 'Itions 04/11/2013 Contract Proposal—Page 3 of 22 • i BUSINESS CONDITIONS TO THIS CONSTRUCTION CONTRACT This Contract, dated 04/11/2013 is by and between: Craig and Laura Marshall 91 Woodstock Road North Andover, MA 01845 Blackdog project code MARSH-10979 (Hereafter referred to as OWNER), and Blackdog Builders, Inc. 7 Redroof Lane, Unit#1 Salem, NH 03079 (603) 898-0868 (Hereafter referred to as CONTRACTOR). Work will be performed at. 91 Woodstock Road, North Andover, MA 01845 (Hereafter referred to as PROPERTY) 1. GENERAL This CONTRACT is for the following work and materials to be performed by the CONTRACTOR on the PROPERTY address shown above. The project is generally described as follows: Bathroom and Basement (Hereafter referred to as WORK) The CONTRACT consists of this document, any plans, the specifications, the Blackdog client package and the Construction Contract. (Hereafter collectively referred to as the"CONTRACT') 2. PRICE The total price for the WORK agreed upon is $45,312.09. Payment terms are set out below in Paragraph 6. This proposal may be withdrawn by us if not accepted within thirty (30) days. 3. STARTING AND SUBSTANTIAL COMPLETION PROVISIONS The WORK will begin on approximately Mid May, 2013 and will be substantially completed, July, 2013, absent unusual or unforeseen circumstances beyond the control of the CONTRACTOR, and providing this CONTRACT and any related CONTRACT documents are accepted when presented. Projects requiring two contracts (one for construction work and one for bath or kitchen product) will not be slotted into the schedule until both agreements have been executed. The aforementioned dates reflect our present workload. Projects are assigned a slot in our work schedule as they are accepted, on a first come first served basis. These dates may move based on the completion time of the project that immediately preceded yours. 4. PERMITS AND APPLICABLE CODES• COMPLIANCE WITH LOCAL LAW All work to be done under this CONTRACT will be in accordance with local, state and county building code. The CONTRACTOR shall obtain all necessary permits and pay all required permit and plan fees from the CONTRACT sum, unless otherwise agreed. The CONTRACT price does not include any fees, which may be incurred to obtain a variance, if required. The CONTRACT price does not include any unbid items required by any local building official to bring the project into compliance with any relevant local, state and county building code. 5. SPECIFIC REQUIREMENTS FOR MATERIALS AND WORKMANSHIP 04/11/2013 Contract Proposal—Page 4 of 22 d. The CONTRACTOR may cease operations if any payment is not made by the OWNER as required herein, and proceed to collect any balance due through any remedy provided by law. Payments are due when the aforementioned progress milestones have been reached. It is understood that minor adjustments to the payments schedule may be necessary due to the flow of work or delays beyond the control of the CONTRACTOR. e. Delays in payment in excess of thirty (30) days shall be subject to interest charges of 18% per annum, and no event higher than the maximum interest rate provided by law. If the CONTRACTOR is required to engage the services of a collection agency or an attorney, the OWNER agrees to reimburse the CONTRACTOR for any reasonable attorney's fees and expenses expended in order to collect the unpaid balance. I f. DEFINITIONS Substantially complete -The space or project is substantially complete when the space or project can be used for its intended purpose and only punch list items remain. Punch list-Work or product that has not been performed or provided. Warranty item -A product or service that has been provided or performed that does not meet or exceed industry j standards. THESE CONDITIONS MUST BE ACCOMPANIED BY THE CONSTRUCTION CONTRACT I i 04/11/2013 Contract Proposal—Page 6 of 22 Section I I Construction of the Contract/ Proposal for Craig and Laura Marshall 04/11/2013 Contract Proposal—Page 7 of 22 CONSTRUCTION CONTRACT This Contract is by and between: Craig and Laura Marshall hereafter referred to as "OWNER", and Blackdog Builders, Inc hereafter referred to as "CONTRACTOR" for work at 91 Woodstock Road, North Andover, MA 01845 dated 05/15/2013. This CONTRACT consists of this document, any plans, the Specifications and Business Terms that are enclosed and the Blackdog Builders Client Package. (Hereafter collectively referred to as the "CONTRACT") 1. CONTRACTOR'S DUTIES --GENERAL a. To direct and control the work contracted for in accordance with the terms of this CONTRACT and all applicable codes, laws, and regulations, and as the building permits issued for this project, if any, require. b. To inspect the site, examine the plans and specifications, if any, and supervise all of CONTRACTOR's employees, and to direct the work of all subcontractors selected by CONTRACTOR. c. To maintain the work site in a safe and clean condition, to the extent consistent with the CONTRACT. d. To advise the OWNER promptly if concealed conditions are ascertained which require additional or different work, and to proceed in such event in accordance with this CONTRACT. e. To provide locked storage for any equipment, tools, or other PROPERTY used in the performance of this CONTRACT, unless otherwise agreed in writing. 2. OWNER'S DUTIES --GENERAL a. To provide adequate utilities for the work agreed upon. b. To advise the CONTRACTOR of any condition of the PROPERTY which affects CONTRACTOR's ability to perform. c. To provide secure storage areas for materials delivered to the work site. d. OWNER shall be entitled to make periodic inspections of the work site, provided such inspections do not interfere with the work and can, in the judgment of the CONTRACTOR, be made safely. Any other entry onto the construction site shall be at OWNER's risk. e. OWNER shall notify his insurance agent of the execution of this agreement and obtain any necessary riders to his current coverage or any locally customary forms of coverage, such as builders risk, to cover OWNER's interests and liabilities during the construction process. f. To perform no work on the project without a written agreement with the CONTRACTOR. g. To make no agreements with any trades person, subcontractor, or CONTRACTOR'S employees outside the scope of this CONTRACT without the written consent of the CONTRACTOR. 3. MATERIAL SUBSTITUTION CONTRACTOR reserves the right to substitute other materials, products and/or labor of equal or superior quality, utility, or similar color. 4. DELAY CONTRACTOR shall not be responsible for delays caused by events beyond the control of the CONTRACTOR, including but not limited to: strikes, war, acts of God, riots, governmental regulations and restrictions. Delays caused by OWNER's failure to make allowance materials selections or caused by the performance by CONTRACTOR of extras or necessary work (as described in Paragraph 6) shall likewise be excusable delays. S. INSURANCE CONTRACTOR agrees to maintain all necessary forms of insurance to protect the OWNER from liability for any occurrence arising from the performance of this Contract. CONTRACTOR agrees that he shall cover his own employees for worker's compensation and carry general liability insurance, and that all forms of insurance referenced herein shall be with reputable companies licensed to do business in the state where the project is located. 6. HIDDEN CONCEALED and UNFORESEEN CONDITIONS 04/11 i2013 contract Proposal—Page 3 of 22 a. The parties agree that in the event CONTRACTOR discovers a hidden, concealed or unforeseen condition requiring an extra cost that they shall proceed as follows: The CONTRACTOR shall notify the OWNER verbally to expedite agreement as to any charge necessary to correct or cure such condition, and provide a written Work Order (as described in paragraph 7a) as soon as practicable. The parties must agree to such extra charges, or agree to a resolution method, or this CONTRACT may be cancelled by either of them. b. For purposes of this section, a "hidden, concealed and unforeseeable condition" shall mean a condition not readily observable to a prudent CONTRACTOR inspecting the subject PROPERTY for the purpose of performing this Contract. Examples of such conditions can include, but are not limited to; rot under siding, ledge below grade; pre-existing plumbing or electrical work not performed to code and pre-existing mold. c. Any 9 q Y change in the WORK required b building officials assigned to this project, including structural and/or any environmental hazards will be billed as an EXTRA charge to this CONTRACT and paid for by the OWNER as a Work Order. CONTRACTOR may cease operations if OWNER refuses to pay. 7. EXTRAS a. Any extra work or materials desired by the OWNER shall be agreed upon in writing and such extras shall become a part of this CONTRACT as if fully set forth herein. Unless otherwise agreed, extra work shall be paid for as performed. Failure of the OWNER to sign a Work Order shall not preclude recovery for any work performed by CONTRACTOR, and acceptance of said extra work or materials shall be presumed, unless there is written notice to the contrary. b. CONTRACTOR shall advise OWNER, at the time of agreement on an extra, as to any additional time required to perform this CONTRACT. CONTRACTOR may cease operations if OWNER refuses to pay. 8. ESCALATION CONTRACTOR reserves the right to pass on additional costs to OWNER resulting from the escalation of the cost of lumber or lumber byproducts. This cost may be passed on only, if after the CONTRACT is signed but before the construction commences, an increase in lumber costs is experienced. The CONTRACTOR must substantiate the change with evidence of the difference between lumber costs at the time of the CONTRACT and lumber costs at the time of construction. Only direct cost differences may be passed on, no allowances for overhead and profit shall be included. Any additional costs will be collected per Work Order(as described in paragraph 7a.). 9. EXCESS MATERIALS ON SITE CONTRACTOR routinely stores extra materials on site to improve efficiency and reduce the likelihood of running out of stock in the middle of a task. Unless otherwise specified in writing all excess materials on site at the end of the project are the PROPERTY of CONTRACTOR. 10. SUBCONTRACTORS a. CONTRACTOR shall select subcontractors as required to complete this CONTRACT. OWNER acknowledges that subcontractors will do various portions of the work. Any subcontractor selected by the CONTRACTOR shall have all requisite licenses for the work to be done by such subcontractor. b. It shall be the duty of the CONTRACTOR to use reasonable care in the selection of subcontractors. Absent objectionable performance by any subcontractor, the selection of subcontractors shall be an exclusive right of the CONTRACTOR. The CONTRACTOR shall require all subcontractors to have workmans compensation and liability insurance in force. c. CONTRACTOR agrees to be solely responsible for the completion of the work described herein regardless of the actions of any third party/subcontractor utilized by the CONTRACTOR. The CONTRACTOR further agrees to be solely responsible for all payments to all subcontractors for materials and labor under this agreement. 11. TERMINATION AND CANCELLATION The CONTRACTOR may terminate and cancel this CONTRACT if any payment called for hereunder is not received as scheduled, provided that notice is given to the OWNER as provided below. Upon such termination, the CONTRACTOR shall have all remedies provided by law, including such lien rights as then apply. The OWNER may terminate this CONTRACT upon the following conditions: a. Failure of the CONTRACTOR, or his subcontractors, to pursue the work contracted for, absent excusable delay, as provided in Paragraph 4 above, for a continuous period of fourteen (14) days, without a written agreement permitting same, such agreement may be satisfied by a single notation to this CONTRACT. b. Failure of the CONTRACTOR to rectify any condition for which building code enforcement authority has issued a citation, of violation notice, within fourteen (14) days notice of such violation, unless OWNER and 04/11/2013 Contract Proposal—Page 9 of 22 CONTRACTOR otherwise agree. C. Any other failure to perform this CONTRACT required by the terms of this CONTRACT. d. No termination shall be effective unless 10 days written notice of OWNER'S intent is given as required below, during which time the default may be cured by the CONTRACTOR. e. Deposit monies - Cancellation of this CONTRACT prior to the commencement of work shall result in the forfeiture of any and all deposit monies collected. All deposits are non-refundable. The parties hereby agree that upon such cancellation, the CONTRACTOR shall suffer damages including but not limited to the cost associated with designing and preparing the project for commencement. f Th Notice of Cancellation attached hereto. f. You may cancel this agreement b observing the requirements o e Y g Y 9 q 12. DISPUTE RESOLUTION If a dispute arises out of or is related to this Contract, or the breach thereof, the parties shall endeavor to settle the dispute first through direct discussions. If the dispute cannot be settled though direct discussions, the parties agree the dispute shall be settled by arbitration as follows: New Hampshire Consumers: If the dispute with a New Hampshire customer cannot be settled through direct discussions, the parties agree the dispute shall be settled by arbitration administered by the American Arbitration Association under its Construction Industry Arbitration Rules. In the event that arbitration is necessary, the parties agree that arbitration proceedings shall be conducted by a mutually agreed upon arbitrator in Rockingham County, New Hampshire. If the parties cannot agree on an arbitrator, either party may file a written demand for arbitration in accordance with the rules of the American Arbitration Association. The arbitration award shall be final and judgment on the award may be entered in any court having jurisdiction thereof. This CONTRACT shall be governed and interpreted in The parties acknowledge that this agreement to accordance with the laws of the State of New Hampshire. p g g arbitrate shall be governed by Chapter 542 of the New Hampshire Revised Statutes Annotated. Either party may, without waiving any remedy under this CONTRACT, seek from any court having jurisdiction any interim or provisional relief that is necessary to protect the rights or PROPERTY of that party, including but not limited to the right to seek liens or attachment. The prevailing party in any dispute arising out of or relating to this CONTRACT or its breach that is resolved by a binding dispute resolution process shall be entitled to recover from the other party reasonable attorneys' fees, costs and expenses incurred by the prevailing party in connection with such dispute resolution process. Massachusetts Consumers: If a dispute with a Massachusetts customer cannot be settled through direct discussions, the parties agree the dispute shall be settled by arbitration administered by the Massachusetts Home Improvement Contractor Law ( MGL.c142A). This law provides homeowners with the right to initiate an arbitration action (as an alternative to court action) if they have a dispute with a contractor. The same right is not automatically afforded to a contractor. The contractor would have to resolve any dispute it has with a homeowner in court unless both parties agree to the following optional provision. This provision gives the contractor the same rights to arbitration as is afforded to the homeowner by the Home Improvement Contractor Law. The CONTRACTOR and OWNER, residing in Massachusetts, hereby mutually agree in advance that in the event the CONTRACTOR has a dispute concerning this CONTRACT, the CONTRACTOR may submit the dispute to a private arbitration firm approved by the Secretary of the Executive Office of Consumer Affairs and Business Regulation and the OWNER shall be required to submit to such arbitration as provided in Massachusetts Laws, chapter, 142A. Either party may, without waiving any remedy under this CONTRACT, seek from any court having jurisdiction any interim or provisional relief that is necessary to protect the rights or PROPERTY of that party, including but not limited to the right to seek liens or attachment. The prevailing party in any dispute arising out of or relating to this CONTRACT or its br `ch that is resolved by a binding dispute resolu on process shall be entitled to recover from the o hs arty re ' ble attorneys' fees, costs and expenses incurted by the prevailing party in C r a iJ-V6,r Wa I Jo n'N'ch6lson � ,J Laura Marshall Blackdog Builders, Inc. 04/11/2013 contract Proposal—Page 10 of 22 Notice: The signature of the parties above constitutes an acknowledgement of the agreement between the parties to alternative dispute resolution. Massachusetts consumers may have the right to initiate alternative dispute resolution even where this section is not signed by the parties. h. Unless otherwise agreed in writing, CONTRACTOR shall continue the WORK and maintain the agreed work schedule during any dispute resolution proceedings. CONTRACTOR's obligation to continue to perform is conditioned upon OWNER's timely payments in accordance with terms of this Contract. 13. ENVIRONMENTAL HAZARDS a. The CONTRACTOR is NOT responsible for the inspection, discovery; abatement or removal of any environmental hazard including, but not limited to: asbestos; mold; lead; radon; ground water or environmental pollution at the work site, unless specifically covered in the specifications. b. In the event that any hazardous material is discovered during the course of construction, the testing, abatement and/or removal shall be the sole responsibility of the OWNER. c. Any additional costs incurred on account of suspension of the construction or changes to the specifications due to a hazard or its removal are the responsibility of the OWNER and will be handled by a Work Order. d. In the event that work does not resume within 30 days of the stoppage, OWNER agrees to immediately pay the CONTRACTOR the pro rated amount of the CONTRACT price applicable to work done up to that point pursuant to the Contract. e. WARRANTY OWNER warrants that as of the date of this CONTRACT: (1)the PROPERTY (including the land, surface water, ground water, and improvements to the land) is, and will continue to be,free of all contamination, including (a) "oil, petroleum products, and their by-products" (b)any "hazardous waste" as defined by the Resource Conservation and Recovery Act of 1976, as amended from time to time, and regulations promulgated thereunder; (c) any "hazardous substance" as defined by the Comprehensive Environmental Response, Compensation, and Liability Act of 1980, as amended from time to time, and regulations promulgated thereunder, specifically including asbestos and mold; and (d) any other"hazardous substance" (2) the PROPERTY is in compliance with all environmental laws and regulations; and (3)there are no underground tanks on the PROPERTY INDEMNITY OWNER expressly acknowledges and agrees that it will reimburse, defend, indemnify and hold harmless CONTRACTOR, all Sub-contractors, their successors, assigns and employees from and against any and all liabilities, claims, damages, penalties, expenditures, losses or charges (including, but not limited to, all costs of investigation, monitoring, legal fees, remedial response, removal, restoration or permit acquisition) which may, now or in the future, be undertaken, suffered, paid, awarded, assessed, or otherwise incurred as the result of: (a) any contamination, existing in, on, above or under the PROPERTY (including, but not limited to, contaminated soil, mold, buildings, facilities and/or ground water); (b) any investigation, monitoring, clean up, removal, restoration, remedial response or remedial work undertaken on the PROPERTY; and (c) OWNER'S breach of any warranty given herein. 14. WARRANTIES a. The work of the CONTRACTOR, including materials and labor, shall be warranteed for a period of three (3) years, during which period CONTRACTOR shall at its own expense correct any defect arising from its work unless it is a non-warrantable condition as set out in the Blackdog Builders Client Package. That package shall become a part of this CONTRACT as if fully set forth herein. b. Any and all warranties for appliances or mechanical systems shall be delivered to OWNER as the CONTRACTOR receives them. Owner agrees to hold manufacturers solely responsible for all warranties for appliances or mechanical systems and agrees that no action may be brought against the CONTRACTOR on this Contract as a result of manufactures warranties. c. The quality of any work in question will be held to the standards issued in the Residential Construction Performance Guidelines—Third Edition published by the NAHB. 15. SEVERABILITY If any portion of this agreement is found invalid or unenforceable by any court, the remaining provisions shall remain in force between the parties. 04/11/2013 Contract Proposal—Page 11 of 22 ' I 16. ENTIRE AGREEMENT Upon signing this document becomes a binding CONTRACT under law. Unless otherwise noted within this document, this contract shall not imply that any lien or other security interest has been placed on the residence. This CONTRACT consists of the documents defined herein, and constitutes the entire agreement of the parties. It can be modified only by a written document. OWNER acknowledges that he has read and received a legible copy of this agreement signed by CONTRACTOR, before any work was done, and that he has read and received a legible copy of every other document that OWNER has signed during the negotiation of this Contract.. 17.THREE DAY RIGHT TO CANCEL THIS CONTRACT You may cancel this agreement if it has been signed at a place other that the CONTRACTOR'S normal place of business, provided you notify the CONTRACTOR in writing by not later than midnight of the third business day following your signing of this agreement. See the notice of cancellation form attached hereto for an explanation of this right. 18 Massachusetts Home Improvement Contractor Law ( MGL.c142A) All home improvement contractors/subcontractors working in the Commonwealth of Massachusetts must be licensed and registered by the Office of Consumer Affairs and Business Regulations. All inquiries concerning the CONTRACTOR should be transmitted to those offices. In Massachusetts Blackdog Builders, Inc. operates under License number CSO48847 and Registration number 106877. Federal Tax ID. Number 02-0477778. a. Massachusetts homeowners securing their own permits will be excluded from the Guaranty Fund provisions of MGL c. 142A. b. In Massachusetts the deposit shall not exceed 1/3 of the total contract price, or the cost of any special equipment or custom made material which must be special ordered in advance to meet the completion schedule, whichever is greater. PLEASE DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES Two identical copies of this contract must be completed and signed. One copy shall go to the OWNER. with the second copy being retained by the CONTRACTOR. NO WORK shall commence until this contract is fully executed. SUBMITTED- DATE f John` v icha Isom 0111/2013 Blackdog Builders, Inc. ACCEPTED: I DATE: Craig M,aishall ,J DATE: Laura Marshall 04/1112013 Contract Proposal—Page 12 of 22 / IT C)03trucficn 3uc•=r 130( Lr nae 94513 - - — TIMOTHY S WILLIAMS 272 CHESTNUT HILL ROAD ROCHESTER, NH 03867 F„-vt 8/28/2013 6377 : Office of Consumer Affairs&Business s Re ulati on6ME IMPROVEMENT CONTRACTOR •�) �� set,e arvu- lcaanam .' t-Re istration 9 106877 -• Type: This caltachlot.IaJExpiration: 7/28/2014 al al Ih&r-_iplenhaw curcz;;iullymaBLACKDOG BUILDERS INC Supplement c 10-hour Oa^upatlonal S'9;9iy and Wealth Training CGLII5s?in 0011--stFu CtiOn Safety and Health TIMOTHY WILLIAMS Tirlic thy Willianis 7 RED ROOF LN.#1 _ Salem, NH 03079 Undersecretary '4; ;gat: ,�PS��•3i`!i-��li)1q�);j_-ij t-1-�,Y�,-)Il,..,li�!1 I'nu•..I Cn i i?— l-1111 a)Y i)l�. - '---- --•-. p .._.. __.. ... . 0 ® 0 University0 0 (CDccuPati0flaR HeaRth & Safety Continuing Education Program (C®-Sponsored by Environment aR ' 'raining Institute, LLC TIMOTHY WYLLII S 7 Red,00FLn. Salem,NH 03079 r Has Successfully Completed the Lead Safety for Renovation, Repair and Painting E nitial course P'rggram DirrSp ----- Course Principal Instructor R-I-18459-10-01387 C3 8 Certificate Number P0. Continuing Education Units April 28,2010 April 14,2010 Issue Date Language—English Course Date Occupational Health&Safety Continuing Education,UC Reading Campus,2180 E.Galbraith Rd.,ML 0510,Cincinnati,OH 45237-1625,(513)558-1730, The Commonwealth oflMlassaehitsetts A Department of Industrial Accidents Office of Investigations 600 Washington Street Boston, MA 02111 www.mass.gov/dia Workers' Compensation Insurance Affidavit: Builders/Contractors/Electricians/Plum ers A licant Information Please Print Leib Name(Business/Organization/Individual):` �u. (fid limo Address: o City/State/Zip: - IM ozo-0 __ Phone#: 663 - 829- Are y63 - $98^Are you an employer? Check the appropriate box: Type of project(required): I.VII am a ernployer with 72 4. [� 1 am a general contractor and I 6 �New construction employees(full and/or part-time).* have hired the sub-contractors listed on the attached sheet. 7. [K Remodeling 2.❑ I am a sole proprietor or partner- These sub-contractors have ship and have no employees 8. ❑Demolition working forme in any capacity. employees and have workers' 9. Building addition [No workers' comp.insurance comp.insurance.$ . E]5We are a corporation and its 10.❑Electrical repairs or additions required.] 3.❑ I am a homeowner doing all work officers have exercised their 11.❑Plumbing repairs or additions myself. [No workers' comp. right of exemption per MGL 12.E] Roof repairs insurance required.]t c. 152, §1(4),and we have no 13.[] Other employees. [No workers' comp. insurance required.] *Any applicant that checks box#1 must also fill out the section below showing their workers'compensation policy information. I Homeowners who submit this affidavit indicating they are doing all work and then hire outside contractors must submit a new affidavit indicating such. (Contractors that check this box must attached an additional sheet showing the name of the sub-contractors and state whether or not those entities have employees. If the sub-contractors have employees,they must provide their workers'comp.policy number. I am an employer that is providing workers'compensation insurance for my employees. Below is the policy and job site information. `` r Insurance Company Name: (4U40_rJ Policy#or Self-ins.L'c. #: WCA 909 91 Z Expiration Date: 7c /fi Job Site Address: 91 lwl 60d,S Lt< �`' City/State/Zip: AtiJo04- ro Attach a copy of the workerscompensation policy declaration page(showing the policy number and expiration date). Failure to secure coverage as required under Section 25A of MGL c. 152 can lead to the imposition cf criminal penalties of a fine up to$1,500.00 and/or one-year imprisonment,as well as civil penalties in the form of a.STOP WORK ORDER and a fine of up to$250.00 a day against the violator. Be advised that a copy of this statement may be forwarded-to the Office of Investigations of the DIA for insurance coverage verification. I do hereby certify under the 'ns an n ties o Jury that the information provided above is true and correct. Si na Date: Phone S6 3' 898— d M8 Official use only. Do not write in this area, to be completed by city or town officiaL City or Town: Permit/License# Issuing Authority(circle one): 1.Board of Health 2.Building Department 3. City/Town Clerk 4.Electrical Inspector 5.Plumbing Inspector 6. Other Contact Person: Phone#: BLACK-1 OP ID: MS ACRO" CERTIFICATE 4F LIABILITY INSURANCE 1 DAT07/26DlYYYY) 07!26!12 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACT PRODUCER 603-424-9901 NAME: Brown&Brown(Merrimack) 603-424203 PHONE FAX 309 Daniel Webster Highway AIc No Ext: A/C No: Merrimack,NH 03054 ADDRESS: Chris McPhail INSURER(S)AFFORDING COVERAGE NAIC# INSURERA:Merchants Preferred Ins Co 12901 INSURED Black Dog Builders, Inc. -INSURER B:Merchants Mutual Insurance Co 23329 7 Red Roof Lane Unit#1 Salem,NH 03079-2984 INSURER C: INSURER 0: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONSAND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAYHAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE POLICY EFF POLICY EXP LIMITS LTR INSR WVD POLICY NUMBER MMIDDIYYY MMIDDIYYYY GENERAL LIABILITY EACH OCCURRENCE $ 100,00 A X COMMERCIAL GENERAL LIABILITY CM P9152639 07!01112 07/01113 DAMAGE TO RENTED PREMISES Ea occurrence $ 100,00 CLAIMS-MADE I X1 OCCUR MED EXP(Any one person) $ 5,00 PERSONAL&ADV INJURY $ 1,000,00 GENERAL AGGREGATE $ 2,000,00 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $ 2,000,00 POLICY PE LOC $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 Ea accident $ A X ANY AUTO CAP9267558 07101112 07101/13 BODILY INJURY(Per person) $ ALL OWNED X AUTOS SCHEDULED AUTOS BODILY INJURY(Per accident) $ X HIRED AUTOS X NON-OWNED PROPERTY DAMAGE $ AUTOS Per accident X UMBRELLA LIAB I OCCUR EACH OCCURRENCE $ 1,000,00 X B EXCESS LIAB CLAIMS-MADE CUP9143953 07/01112 07/01/13 AGGREGATE $ DED I X I RETENTION$ 10000 $ WORKERS COMPENSATION WCSTATU- OTH- AND EMPLOYERS'LIABILITYTORYLIMIT S ER B ANY PROPRIETOR/PARTNER/EXECUTIVE Y 1 N CA9097912 07/01112 07/01/13 E.L.EACH ACCIDENT $ 100,000 OFFICER/MEMBER EXCLUDED? N I A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $ 100,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT 1$ 500,00 DESCRIPTION OF OPERATIONS 1 LOCATIONS I VEHICLES (Attach ACORD 101,Addltlonal Remarks Schedule,If more space Is required) David Bryan is excluded from Worker's Compensation coverage. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE For Insured's Reference THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD f REScheck Software Version 4.4.3 Compliance Certificate Project Title: Marshall Basement Expansion Energy Code: 2009 IECC Location: North Andover, Massachusetts Construction Type: Single Family Project Type: Addition/Alteration Heating Degree Days: 6322 Climate Zone: 5 Construction Site: Owner/Agent: Designer/Contractor: 91 Woodstock road Craig Marshall Tim Williams/Project Manager North Andover,MA 01845 Tim Williams/Project Manager/ Blackdog Builders Inc Balckdog Builders Inc 7 Redroof Lane 91 Woodstock Rd/North Andover Salem,NH 03079 7 Redroof Lane 603-234-0652/cell# Salem,NH 030709 603-898-0868 twilliams@blackdogbuilders.com Compliance:40.0%Better Than Code Maximum UA:15 Your UA:9 The%Better or Worse Than Code index reflects how close to compliance the house is based on code trade-off rules. It DOES NOT provide an estimate of energy use or cost relative to a minimum-code home. Wall 1:Wood Frame, 16"D.C. 152 21.0 0.0 8 Door 1:Solid 20 0.060 1 Ceiling 1: Flat Ceiling or Scissor Truss --- --- --- --- --- Exemption:Framing cavity filled with insulation. Compliance Statement: The proposed building design described here is consistent with the building plans,specifications,and other calculations submitted with the permit application.The proposed building has been designed to meet the 2009 IECC requirements in REScheck Version 4.4.3 and to comply with the mandatory requirements listed in the REScheck Inspection Checklist. Name-Title Signature Date Project Title: Marshall Basement Expansion Report date: 04/24/13 Data filename: Untitled.rck Page 1 of 4 REScheck Software Version 4.4.3 Inspection Checklist Energy Code: 2009 IECC Location: North Andover, Massachusetts Construction Type: Single Family Project Type: Addition/Alteration Heating Degree Days: 6322 Climate Zone: 5 Ceilings: ❑ Ceiling 1:Flat Ceiling or Scissor Truss Exemption:Framing cavity filled with insulation. Comments: Above-Grade Walls: ❑ Wall 1:Wood Frame, 16"o.c.,R-21.0 cavity insulation Comments: Doors: ❑ Door 1:Solid,U-factor:0.060 Comments: Air Leakage: ❑ Joints(including rim joist junctions),attic access openings,penetrations,and all other such openings in the building envelope that are sources of air leakage are sealed with caulk,gasketed,weatherstripped or otherwise sealed with an air barrier material,suitable film or solid material. ❑ Air barrier and sealing exists on common walls between dwelling units,on exterior walls behind tubs/showers,and in openings between window/doorjambs and framing. ❑ Recessed lights in the building thermal envelope are 1)type IC rated and ASTM E283 labeled and 2)sealed with a gasket or caulk between the housing and the interior wall or ceiling covering. ❑ Access doors separating conditioned from unconditioned space are weather-stripped and insulated(without insulation compression or damage)to at least the level of insulation on the surrounding surfaces.Where loose fill insulation exists,a baffle or retainer is installed to maintain insulation application. ❑ Wood-burning fireplaces have gasketed doors and outdoor combustion air. ❑ Automatic or gravity dampers are installed on all outdoor air intakes and exhausts. Air Sealing and Insulation: ❑ Building envelope air tightness and insulation installation complies by either 1)a post rough-in blower door test result of less than 7 ACH at 50 pascals OR 2)the following items have been satisfied: (a)Air barriers and thermal barrier:Installed on outside of air-permeable insulation and breaks or joints in the air barrier are filled or repaired. (b)Ceiling/attic:Air barrier in any dropped ceiling/soffit is substantially aligned with insulation and any gaps are sealed. (c)Above-grade walls:Insulation is installed in substantial contact and continuous alignment with the building envelope air barrier. (d)Floors:Air barrier is installed at any exposed edge of insulation. (e)Plumbing and wiring:Insulation is placed between outside and pipes.Batt insulation is cut to fit around wiring and plumbing,or sprayed/blown insulation extends behind piping and wiring. (f) Corners,headers,narrow framing cavities,and rim joists are insulated. (9)Shower/tub on exterior wall:Insulation exists between showers/tubs and exterior wall. Sunrooms: ❑ Sunrooms that are thermally isolated from the building envelope have a maximum fenestration U-factor of 0.50 and the maximum skylight U-factor of 0.75.New windows and doors separating the sunroom from conditioned space meet the building thermal envelope requirements. Project Title: Marshall Basement Expansion Report date: 04/24/13 Data filename: Untitled.rck Page 2 of 4 Materials Identification and Installation: ❑ Materials and equipment are installed in accordance with the manufacturer's installation instructions. L] Materials and equipment are identified so that compliance can be determined. Li Manufacturer manuals for all installed heating and cooling equipment and service water heating equipment have been provided. ❑ Insulation R-values and glazing U-factors are clearly marked on the building plans or specifications. Duct Insulation: L] Supply ducts in attics are insulated to a minimum of R-8.All other ducts in unconditioned spaces or outside the building envelope are insulated to at least R-6. Duct Construction and Testing: F1 Building framing cavities are not used as supply ducts. L] All joints and seams of air ducts,air handlers,filter boxes,and building cavities used as return ducts are substantially airtight by means of tapes,mastics,liquid sealants,gasketing or other approved closure systems.Tapes,mastics,and fasteners are rated UL 181A or UL 181 B and are labeled according to the duct construction.Metal duct connections with equipment and/or fittings are mechanically fastened.Crimp joints for round metal ducts have a contact lap of at least 1 1/2 inches and are fastened with a minimum of three equally spaced sheet-metal screws. Exceptions: Joint and seams covered with spray polyurethane foam. Where a partially inaccessible duct connection exists,mechanical fasteners can be equally spaced on the exposed portion of the joint so as to prevent a hinge effect. Continuously welded and locking-type longitudinal joints and seams on ducts operating at less than 2 in.w.g.(500 Pa). F1 Duct tightness test has been performed and meets one of the following test criteria: (1)Postconstruction leakage to outdoors test:Less than or equal to 8 cfm per 100 ft2 of conditioned floor area. (2)Postconstruction total leakage test(including air handler enclosure):Less than or equal to 12 cfm per 100 ft2. (3)Rough-in total leakage test with air handler installed:Less than or equal to 6 cfm per 100 ft2 of conditioned floor area. (4)Rough-in total leakage test without air handler installed:Less than or equal to 4 cfm per 100 ft2 of conditioned floor area. Temperature Controls: LI Where the primary heating system is a forced air-furnace,at least one programmable thermostat is installed to control the primary heating system and has set-points initialized at 70 degree F for the heating cycle and 78 degree F for the cooling cycle. F1 Heat pumps having supplementary electric-resistance heat have controls that prevent supplemental heat operation when the compressor can meet the heating load. Heating and Cooling Equipment Sizing: ❑ Additional requirements for equipment sizing are included by an inspection for compliance with the International Residential Code. F1 For systems serving multiple dwelling units documentation has been submitted demonstrating compliance with 2009 IECC Commercial Building Mechanical and/or Service Water Heating(Sections 503 and 504). Circulating Service Hot Water Systems: Circulating service hot water pipes are insulated to R-2. ❑ Circulating service hot water systems include an automatic or accessible manual switch to turn off the circulating pump when the system is not in use. Heating and Cooling Piping Insulation: I] HVAC piping conveying fluids above 105 degrees F or chilled fluids below 55 degrees F are insulated to R-3. Swimming Pools: ❑ Heated swimming pools have an on/off heater switch. ❑ Pool heaters operating on natural gas or LPG have an electronic pilot light. Timer switches on pool heaters and pumps are present. Exceptions: Where public health standards require continuous pump operation. Where pumps operate within solar-and/or waste-heat-recovery systems. Ll Heated swimming pools have a cover on or at the water surface. For pools heated over 90 degrees F(32 degrees C)the cover has a minimum insulation value of R-12. Exceptions: Covers are not required when 60%of the heating energy is from site-recovered energy or solar energy source. Lighting Requirements: Project Title: Marshall Basement Expansion Report date: 04/24/13 Data filename: Untitled.rck Page 3 of 4 i A minimum of 50 percent of the lamps in permanently installed lighting fixtures can be categorized as one of the following: (a)Compact fluorescent (b)T-8 or smaller diameter linear fluorescent (c)40 lumens per watt for lamp wattage—15 (d)50 lumens per watt for lamp wattage>15 and—40 (e)60 lumens per watt for lamp wattage>40 Other Requirements: Snow-and ice-melting systems with energy supplied from the service to a building shall include automatic controls capable of shutting off the system when a)the pavement temperature is above 50 degrees F,b)no precipitation is falling,and c)the outdoor temperature is above 40 degrees F(a manual shutoff control is also permitted to satisfy requirement's'). Certificate: ❑ A permanent certificate is provided on or in the electrical distribution panel listing the predominant insulation R-values;window U-factors;type and efficiency of space-conditioning and water heating equipment.The certificate does not cover or obstruct the visibility of the circuit directory label,service disconnect label or other required labels. NOTES TO FIELD:(Building Department Use Only) Project Title: Marshall Basement Expansion Report date: 04/24/13 j Data filename: Untitled.rck Page 4 of 4 20fl91CC Energy Efficiency Certificate Ceiling/Roof 0.00 Wall 21.00 Floor/Foundation 0.00 Ductwork(unconditioned spaces): Window Door 0.06 NA Heating System: Cooling System: Water Heater: Name: Date: Comments: i rI ITR II II�1�' i 21 1-q li II i cy II L ' FINISHED BA5EMENT i. GARACa E UP UTILITY/LAUNDRY II - o 1st FL. BATH In b'-q 1 /2" ISLACAP U _ PAG E I INC. SUBJECT: - -- LIENT APPROVAL: — GALE: O BLAGKDOG BUILDERS, "MAR5HALL RE51fl?EN�ETHESE PLANS MAY NOT ! BE USED IN ANY WAY q1 NOOD5TOGK ROAD ✓` � i�� WITHOUT WRITTEN �(. NDO�(ER 01 u45 DATE: ANTE: DESIGN PERM155ION OF THE 04/1 q/2013 COPYRIGHT OWNER ,Oman" FIN15HED BA5EMENT i NOTE5. 1 . REMOVE HATCHED NALL BETNEEN � FIN15HED BA5EMENT AND CARACE j 2. REMOVE ENTRY DOOR AND NALL UP TO EX15TINC LALLY COLUMN 3. REMOVE 51NOLE PANE NINDON "All li 4. FLOORING AND LONER PART OF � DRYNALL IN FIN15HED BA5EMENT �- GARA6 E HAVE ALREADY BEEN REMOVED. / UTILITY/LAUNDRY UP NOTE5. 1 . REMOVE AND 5ALVAGE VANITY 2. REMOVE BATHROOM FLOOR AND UNDERLAYMENT 3. REMOVE FIBEROLA55 TUB 1 st FL. BATH 4. REMOVE BA5EBOARD 5. REMOVE AND 5ALVAC TOILET © BLAGKDOG BUILDERS, INC. ----- 5UBJECT: CLIENT ,APPROVAL: C�'`L5: '°= 1 PAGE i THE5E PLANS MAY NOT ' MAR5HALL RE5IDENCE BE U5ED IN ANYNlAY q1 NOOD5TOCK ROAD ' DEMOLITION . Y41THOUT kNRITTEN N. ANDOVER 01 545 I DATE. ATE: FERM1551N OF THE 04/111/2013 EMODEL, GOPYRIG HT OkNNER HARVEY VICON VINYL j BASEMENT HOPPER YtiINDOIIN kNHITE KRE CLOSET SYSTEM #BW2813 FOUR ROW5 OF SHELVES ON UNIT 51ZE: 2' b" x 1' 3" TNO INDICATED VNALL5 R.O. (USE EXISTING OPENING) -- --- — DOOR SCHEDULE: FINISHED 8A5EMENT - 1 . 2'-6" x 6-8" 51X PANEL 50LID PINE DOOR, SPLIT JAMB ! t i � POL15HED BRASS HINGE AND PA55AGE SET 2. 2'-6" x 6-8" CASED OPENING j IIS m VERIFY WITH CLIENT THAT CLOSET THERE WILL BE NO DOOR CL05ET = ALL DIMENSIONS TO FRAMING - - 2-5 1 /2" 02 - - -- -- - -- ---_ _- 5-2 3/4" * ADJUST ANY a'-q 3/4" DIMENSIONS NEEDED TO CAPTURE LALLY POLUMN IN WALLS Up- UTILITY/LAUNDRY GARAGE SUBJECT: iCLIENT APPROI/ SCALE: °°= 1 ° IPAGE © BLAGi:DOG BUILDERS, INC. MARSHALL RESIDENCE j - THE5E PLAN5 MAY NOT BE U5ED IN ANY WAY q 1 WOO DSTOCK ROAD j CDATE: ®N 5T U CT I O N !DATE. WITHOUT WRITTEN ! N. ANDOVER 01 545 PERM15510N OF THE j 04-/. 1 gi201 .. COPYRIGHT OWNER i BATHROOM PRODUGT5: -BEE ELEVATIONB ON PAGES 5,6 FOR NALL TILE LAYOUTS 1 . STERLING "ALL PRO BATHTUB 5. DALTILE "NATURAL STONE" '—i i SERIES 6104, 60" x 30" LIMESTONE 12x12 FLOOR TILE �\ _ RIGHT HAND DRAIN; NHITE CHIFFON CREME HOMED 2. KOHLER "PUR15T" 5HOVgER HEAD q. DALTILE "NATURAL STONE" K-q65-CP; POLISHED CHROME \_- MARBLE 12x12 !^TALL TILE �� ,� ` ! _�\� � 13. KOHLER THERMOSTATIC VALVE � CREME MARFIL POLISHED A I� L� ; KITH INTEGRATED VOLUME CONTROL 10. DALTILE "STONE RADIANCE" 44) \\ ! K-2ql3-K5-NA 5/8°' x 5/8" MOSAIC �6__—_ - 4. KOHLER "PURIST" STACKED VALVE TRIM VgHl5PER GREEN BLEND i �j i K-T1445q-4-CP; POLI5HED CHROME (INSTALL INSIDE NIGH=) 5. 5TERLING "FINESSE" FRAMELE55 11 . DALTILE "STONE RADIANCE" BY-PASS 5HONER DOOR ��� # 5405-5q5-G05; SILVER, CLEAR GLA55 5/� RANDOM BLEND �1\ \ NHI5PER GREEN BLEND \� \ � b. RE-INSTALL SALVAGED VANITY (INSTALL AS ACCENT BAND) --- — - ---- - �1. RE-INSTALL SALVAGED TOILET _ _ _------_- -- -- --- — - 1 st FL. BATH O BLACKDOG BUILDERS, INC. 1 /2 5UBJEGT: LSENT APPROVAL: GALE: P1�GE ': MAR5HA.LL RE51DENCE i THESE PLAN5 MANY NOT ; BATHROOM BE U5ED IN ANY VgAY q1 V10005TOCK ROAD % 4 NITHouT Y�RITTEN N. AN DOVER 01545 P R0 D U CT DATE• DATE: . PERMI55ION OF THE ! ! ' 04/1 q/ 01 COPYRIGHT OJNNER .i' -VERIFY LOGATION5 Y14IT CLIENT [FIN, o o _ Ln _ � a o 0 — LIENT APPROVABUBJEGT: L: SCALE: � �� � PAGE © BLAGKDOG BUILDERS, INC. I MAR5HALL RE5II0E'�GE THESE PLANS MAY NOT T I L EP P L U M B I C BE U5ED IN ANY V4AY j q 1 0005T®GIG ROD WITHOUT VNRITTENlyD®BAER 41845Y�►UT IDATE: ATE: PER M155ION OF THE I � 04/1 q/201 3 . COPYRIGHT ONNER - n r I i I L� 0 BL GKDOG BUILDERS, 5UBJEGT: LIENT APPROVAL: GALE: 1 _ 1 Pf�GE l�AR5HALL RE51 DENCE g !� THESE PLf�NS MAY NOT TILE E L "(O U T BE U5ED IN ANY YiAY q1 N0005TOCK ROAD ; 'DATE: ATE: Y�IITHOUT YgRITTEN D PERI�Il55ION OF THE N. ANDOVER 01 b45 ! ! 04/1 812013 ., COPYRIGHT OWNER ! ! • R _ — — -- — -- = i — — r �F it --- --- FINISHED BASEMENT I ! E I 3 ! ! CL05 ET ! GF ! rub CL05ET � I FCI ALL 0IMEN51ON5 TO FRAMING UTILITY/LAUNDRY UP &ARA67 E — ! SUBJECT: 'CLIENT APPROY L: G LE: 1 / �e_ 1 a P,4GE © BLP:GKDOG BUILDERS, ING. MARSHALL RE51Y�EGE — THESE PLAN5 MAY NOT BE U5ED IN ANY AY q1 N0005TOOK ROAD � ELECTRICAL � ! WITHOUT WRITTEN N. ANDOVER 01545 IDATE. FATE. ! DESIGN PERMI55ION 01= THE 04/1 q/2013 .o COPYRIGHT OWNER