HomeMy WebLinkAboutContract #: 004088 - From: To: - Exception - ExceptionSchool Department Administration Building
North Andover, MA
FORM OF GENERAL BID
Kang Associates, Inc.
January 2, 2014
To the Awarding Authority:
A. The undersigned proposes to furnish all labor and materials required for the School Department
Administration Building, North Andover, Massachusetts, in accordance with the accompanying
plans and specifications prepared by Kang Associates, Inc. for the contract price specified below,
subject to additions and deductions according to the terms of the specifications.
B. This bid includes addenda numbered 1 , 2 and 3
C. The proposed contract price is:
Two Million Four Hundred dollars ($
2,435,400
)
Thirty Five THousand Four Hundred
For Alternate #1:
Deduct $ Eleven Thousand Five dollars ($
-11,500
)
Hundred
For Alternate #2:
Deduct $ Forteen Thousand dollars ($
—14,000
)
For Alternate #3:
Deduct $ Two Thousand dollars ($
—2,000
)
For Alternate #4:
Deduct $ Seventy Fnur Thnusancl dollars ($
—74,500
)•
Four Hundred
For Alternate #5:
Deduct $ Seventeen Thousand dollars ($
—17,000
)
D. The subdivision of the proposed contract price is as follows:
Item 1. The work of the general contractor, being all work other than that covered by Item 2:
$
1,518,467
Item 2. Sub -bids as follows:
Bond req'd
Sub -trade Name of Sub -Bidder
Amount
Yes/No
Masonry:
04.21.13 Brick Masonry LAL Masonry
04.72.00 Cast Stone Masonry
99,800
$
NO
Roofing:
07.31.13 Asphalt Shingles MDM En
07.53.00 Elastomeric Membrane Roofing g
$ 74,000
NO
09.51.23 Acoustical Tile Ceilings K&K Acxoustical
$ 16,57n
NO
FORM OF GENERAL BID - 1
A
School Department Administration Building
North Andover, MA
09.90.00 Painting and Coating
14.42.16 Vertical Wheelchair Lifts
Division 21 Fire Protection
Division 22 Plumbing
Division 23 HVAC
Division 26 Electrical
Division 28 Fire Alarm
O'Byrne Paint.
Kang Associates, Inc.
January 2, 2014
$ 28,700 NO
Ebacher Plumb. $ 74,000 NO
Thomas Snowden
Jupiter Electric
$ 324,000 NO
$ 214,900 NO
Total of Item 2: $ 91 6 , 9 -3
E. The undersigned agrees that, if he is selected as general contractor, he will within five days,
Saturdays, Sundays and legal holidays excluded, after presentation thereof by the awarding
authority, execute a contract in accordance with the terms of this bid and furnish a performance
bond and also a labor and materials or payment bond, each of a surety company qualified to do
business under the laws of the commonwealth and satisfactory to the awarding authority and each
in the sum of the contract price, the premiums for which are to be paid by the general contractor and
are included in the contract price; provided, however, that if there is more than 1 surety company,
the surety companies shall be jointly and severally liable.
The undersigned hereby certifies that he is able to furnish labor that can work in harmony with all
other elements of labor employed or to be employed on the work; that all employees to be employed
at the worksite will have successfully completed a course in construction safety and health approved
by the United States Occupational Safety and Health Administration that is at least 10 hours in
duration at the time the employee begins work and who shall furnish documentation of successful
completion of said course with the first certified payroll report for each employee; and that he will
comply fully with all laws and regulations applicable to awards made subject to section 44A.
The undersigned further certifies under the penalties of perjury that this bid is in all respects bona
fide, fair and made without collusion or fraud with any other person. As used in this subsection the
word "person" shall mean any natural person, joint venture, partnership, corporation or other
business or legal entity. The undersigned further certifies under penalty of perjury that the said
undersigned is not presently debarred from doing public construction work in the commonwealth
under the provisions of section twenty-nine F of chapter twenty-nine, or any other applicable
debarment provisions of any other chapter of the General Laws or any rule or regulation
promulgated thereunder.
01/30/14
Date
MASS CORP
M. O'Connor Contracting, Inc.
(Name of General Bidder)
By:
J-Vae-,N
Signature and Title of Person Signing Bid
President
19 Ledge Hill Road
Business Address
West Roxbury, MA 02132
City and State
FORM OF GENERAL BID - 2
ft
CERTIFICATION
LABOR HARMONY AND OSHA TRAINING REQUIREMENTS
The undersigned certifies under penalties of perjury that he is able to furnish labor that can work
in harmony with all other elements of labor employed or to be employed at the work
and
that all employees to be employed at the worksite and in the work will have completed an
OSHA -approved construction safety and health course lasting at least ten (10) hours.
F' " I " J� /
Signa
Michael O'COnnor - President
Print Name & Title
Date_ _
01/30/14
M. O'COnnor Contracting, Inc.
Company Name
CERTIFICATIONS
CERTIFICATE OF NON -COLLUSION
The undersigned certifies under penalties of perjury that this bid or proposal has been made and
submitted in good faith and without collusion or fraud with any other person. As used in this
certification, the word "person" shall mean natural person, business, partnership, corporation,
committee, union, club or other organization, entity, or group of individuals.
Signature;/d�Date 01/30/14
Michael O'COnnor - President
M.O'Connor Contracting, InQ,
Print Name & Title Company Name
CERTIFICATE OF TAX COMPLIANCE
Pursuant to Chapter 62C of the Massachusetts General Laws, Section 49A (b), I
Michael O'Connor , authorized signatory for M. O' Connor Contracting,"InO2 .
Name of individual Name of contractor
do hereby certify under the pains and penalties of perjury that said contractor has complied with
all laws of the Commonwealth of Massachusetts, and the Town of North Andover, relating to
taxes, permit or other fees, reporting of employees and contractors, and withholding and
remitting child support.
ilU a 01/30/14
Signature Date
School Department Administration Building Kang Associates, Inc.
North Andover, MA January 2, 2014
CERTIFICATE OF CORPORATE BIDDER
Elizabeth O'Connor certify that I am the
Corp Clerk of the corporation named as Bidder in the
Bid Form, and that Michael O'Connor who signed the Bid Form on
behalf of the Bidder was then the President of said
corporation and that I know his signature; that his signature thereto is genuine and that the Bid Form was
duly signed, sealed and executed for and in behalf of said corporation by authority of its governing body.
Corporate Sea!
r
Qn-
�e-cretary-)C-IerF
01/30/14
Date
CORPORATE BIDDER, - 1
DEVAL L. PATRICK
GOVERNOR
TIMOTHY P. MURRAY
LIEUTENANT GOVERNOR
The Commonwealth c�� f'11�lassachusetts
Executive Office^ for Administration and Finance
Division of Capital Asset Man(lgelnenl and Maintenance
One kliburtolzPlace
Boston, Massachuselis 02108
nd1 (617) 727-4050
£'(t'`: (617) 727-5363
Prime/General
GLEN SHOR
SECRETARY, ADMINISTRATION &
FINANCE
CAROLE CORNELISON
COMMISSIONER
Certificate of Contractor Eligibility
CONTRACTOR IDENTIFICATION NUMBER: 0942
This Certificate Shall Tae Tjsed for Submittin Prime/General Bids Only
1. CERTIFICATION PERIOD: 'I`llis Certificate is valid from 8/1.2/2013 to 8/12/2014
2. CONTRACTOR'S NAME: M. O'Connor Contractittg, 1116.
3. CONTRACTOR'S ADDRESS: 19 Ledge Hill Road, P.O. Box 320277, West Roxbury, MA 02132
4. WORK CATEGORIES: This Contractor is certified to rile bids under Massachusetts General l.,mvs Chapter 149,
Chapter 149A and Chapter 25A in the following checked Categories of $Fork:
Alann Systems
Asbestos Removal
Deleading
Demolition
Doors & Windows
Electrical
Electronic Security Systems
S. EVALUATIONS:
Elevators
Energy Management Systems
Exterior Siding
Fire Protection Sprinkler Systems
Floor Covering
-�% General Building Construction
Historical Building Restoration
Ilistorical Masorny
_ Historical Painting
Historical Roofing
HVAC
Masonry
Mechanical Systems
Modular Construction/Prelab
Number of Projects Evaluated: 12
Average Project Evaluation Rating: 90
Number of Projects Below Passing Score: 1
6. PROJECT LIMITS: single Project Limit (SPL):
Aggregate Work Limit (AWL):
General .Building Construction Limit:
7. SUPPL15R DIVERSITY OFFICE C TIFICATION: NIA
Freya S. BernsteM, Deputy General Counsel,
for Carole J. Cornelison, Commissioner
Painting
Plumbing
Pumping Stations
Roofing
Sewage B:Water Treatment Plants
Telecommunication Systems
Waterproofing
$6,000,000.00
$12,000,000,00
$6,000,000.00
Approval Date
NOTE TO CONTRACTORS: Complete Applications for Renewal of Contractor Eligibility are due no later than three months
PRIOR to the Expiration mate of the Certification Period shown above. Failure to submit Completed Applications timely may
result in a gap in Certification or a lapse in Certification altogether for your company.
Reviewer's Initials tis
Document A31OTM - 2010
Conforms with The American Institute of Architects AIA Document 310
CONTRACTOR:
(Name, legal status and address)
M.O'Connor Contracting, Inc.
PO Box 320277,
West Roxbury, MA 02132-0003
OWNER:
(Name, legal status and address)
Town of North Andover
MA
BOND AMOUNT: $
SURETY:
(Name, legal status and principal place of business)
Travelers Casualty and Surety
Company of America
350 Granite Street - Suite 1201
Braintree, MA 02169
Five Percent of the Attached bid (5%)
This document has important
legal consequences. Consultation
with an attorney is encouraged
with respect to its completion or
modification.
Any singular reference to
Contractor, Surety, Owner or
other party shall be considered
plural where applicable.
PROJECT:
(Name, location oraddress, and Project number, ifany) School Department Administration Building -New
Construction
The Contractor and Surety are bound to the Owner in the amount set forth above, for the payment of which the Contractor and Surety bind
themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, as provided herein. The conditions of this
Bond are such Ilia if the Owner accepts the bid of the Contractor within the time specified in the bid documents, or within such time period
as may be d to by the Owner and Contractor, and the Contractor either (1) enters into a contract with the Owner in accordance with
the terms of such bid, and gives such bond or bonds as may be specked in the bidding or Contract Documents, with a surety admitted in
the jurisdiction of the Project and otherwise acceptable to the Owner, for the faithful performance of such Contract and for the prompt
payment of labor and material furnished in the prosecution thereof; or (2) pays to the Owner the difference, not to exceed the amount of
this Bond, between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another
party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. The
Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the
bid. Waiver of notice by the Surety shall not apply to any extension exceeding sixty (60) days in the aggregate beyond the time for
acceptance of bids specified in the bid documents, and the Owner and Contractor shall obtain die Surety's consent for an extension beyond
sixty (60) days.
If this Bond is issued in connection with a subcontractor's bid to a Contractor, the term Contractor in this Bond shall be deemed to be
Subcontractor and the term Owner shall be deemed to be Contractor.
When this Bond has been fumishcd to comply with a statutory or other legal requirement in the location of the Project, any provision in
this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions confonning to such
statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed
as a statutory bond and not as a common law bond.
Signed and sealed this 30th day of January, 2014
M.O'Connor Contracting, Inc.
(Principal (Seal)
(Witness) N
D
(Title)
Travelers Casualty and a>=e Company of America
aAA (Surety) (Seal)
(Wetness)
(Title) . aures J. on, Attorney -in -Fact
WARNING: THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER
POWER OF ATTORNEY
TRAVELERSFarmington Casualty Company St. Paul Mercury Insurance Company
Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company
Fidelity and Guaranty Insurance Underwriters, Inc. Travelers Casualty and Surety Company of America
St. Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company
St. Paul Guardian Insurance Company
Attorney -In Fact No. 223844
Certificate No. 005522387
KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance
Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States
Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a
corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc., is a corporation duly organized under the
laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint
Adam W. DeSanctis, Gregory D. Juwa, Bryan F. Juwa, James J. Axon, Michael F. Carney, Wilder Parks Jr., Michael T. Gilbert, Christine B.
Gallagher, David A. Boutiette, Paul A. Patalano, Richard F. Caruso, and Rebecca Shanley
of the City of Woburn , State of Massachusetts , their true and lawful Attomey(s)-in-Fact,
each in their separate capacity if more than one is named above, to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and
other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of
contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
IN WITNESS WHEREOF, the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this
day of June 2013
7th
Farmington Casualty Company St. Paul Mercury Insurance Company
Fidelity and GuarantyInsurance Company Travelers Casualty and Surety Company
Fidelity and Guaranty Insurance Underwriters, Inc. Travelers Casualty and Surety Company of America
St. Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company
St. Paul Guardian Insurance Company
GASU,F�1 Jy Fl0.E 6 *W INSGP,w.NS.JP�fY ANps p Y ..1TYI4_
�' ppPQq� L P . � •r QO: ; -.........9 J :.........
�
Z 1982' O 191! BCdIPpRgtED 6� = - m•€ �. f•�y 1�u +pGRPORATp'.1
0: a N/1RTFORD� i J HARIf6RD.
eSs; O 1951 .�AGoi NN.
; SEALjD COr' OONN. in 1896
o SE > �O
�y � tid �� � s�xANcec y..........�L a.••.. e s �a /w,. �Q
�^nuuninm,� ISN.A� \.ts....�..: �d bf n,� • VM 'i/�ti(p'
State of Connecticut
City of Hartford ss.
By: '44a�
Robert L. Raney, enior Vice President
On this the 7th day of June 2013 before me personally appeared Robert L. Raney, who acknowledged himself to
be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul
Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers
Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so to do, executed the foregoing
instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer.
00t4t#zA
In Witness Whereof, I hereunto set my hand and official seal.My Commission expires the 30th day of June, 2016.
58440-8-12 Printed in U.S.A.
WARNING: THIS POWER OF ATTORNEY IS
Marie C. Tetreault, Notary Public
WARNING: THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER
This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Farmington Casualty Company, Fidelity
and Guaranty Insurance Company, Fidelity and Guaranty Insurance, Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance
Company, St. Paul Mercury Insurance Company, Travelers Casualty and Suiety Company, Travelers Casualty and Surety Company of America, and United States
Fidelity and Guaranty Company, which resolutions are now in full force and effect, reading as follows:
RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice
President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf
of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the
Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any
of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her; and it is
FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may
delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy
thereof is filed in the office of the Secretary; and it is
FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking
shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice
President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the
Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required) by one or more Attorneys-in-Fact and Agents pursuant to the power
prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is
FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President,
any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any
certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds
and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal
shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on
the Company in the future with respect to any bond or understanding to which it is attached.
I, Kevin E. Hughes, the undersigned, Assistant Secretary, of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance
Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and
Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company do hereby certify that the above and foregoing
is a true and correct copy of the Power of Attorney executed by said Companies, which is in full force and effect and has not been revoked.
IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this day of 20 L
dy. •X f ^ .�T •Y
Kevin E. Hughes, Assistant Seciftary
GI.SUA�r J '0.E p4� ..N INSG��,, ••'P•f �NSy'q ,,,�
ZO%Nbr y19�c8t�S2� rN a�s;'o S1dpp°asfo H�1,,9p�5�,.1. aA��s'nhu xMY„"�`E c�o p ��Q`Od�'•S1.g.•E,P••ItiRlAdAL/d):F ailon / l
j"oqd�J:J1,s•.P,•B_PO.AR_A �9'ay °;k t 1v A
:;........
0R
9�jRD
S
a............ 0.”
1\p
18Y9
'�641
0ED
4N'1 AMtd�
Nq�
To verify the authenticity of this Power of Attorney, call 1-800-421-3880 or contact us at www.travelersbond.com. Please refer to the Attorney-In-Fact number, the
above-named individuals and the details of the bond to which the power is attached.
WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUTTHE RED BORDER
EFFECTIVE MARCH 30, 2010
Commonwealth of Massachusetts
Division of Capital Asset Management
PRIME/GENERAL CONTRACTOR
UPDATE STATEMENT
TO ALL BIDDERS AND AWARDING AUTHORITIES
A COMPLETED AND SIGNED PRIME/GENERAL CONTRACTOR UPDATE
STATEMENT MUST BE SUBMITTED WITH EVERY PRIME/GENERAL BID FOR A
CONTRACT PURSUANT TO M.G.L. c.149, §44A AND M.G.L. c. 149A. ANY
PRIME/GENERAL BID SUBMITTED WITHOUT AN APPROPRIATE UPDATE
STATEMENT IS INVALID AND MUST BE REJECTED.
Caution: This form is to be used for submitting Prime/General Contract bids. It is
not to be used for submitting Filed Sub -Bids or Trade Sub -Bids.
AWARDING AUTHORITIES
If the Awarding Authority determines that the bidder does not demonstrably possess
the skill, ability, and integrity necessary to perform the work on the project, it must
reject the bid.
BIDDER'S AFFIDAVIT
I swear under the pains and penalties of perjury that I am duly authorized by the bidder
named below to sign and submit this Prime/General Contractor Update Statement on behalf
of the bidder named below, that I have read this Prime/General Contractor Update Statement,
and that all of the information provided by the bidder in this Prime/General Contractor Update
Statement is true, accurate, and complete as of the bid date.
01/30/2014 M O'Connor Contracting, Inc.
Bid Date Print Name of Prime/General Contractor
19 Ledge Hill Road, West Roxbury, MA 02132
Project Number (or Business Address
name if no number)
Town of No Andover 617-327-3070
Awarding Authority Telephone Number
SIGNATUREa Z". . A�
Bidder's Authorized Representative
Division of Capital Asset Management Page 1 of 10
INSTRUCTIONS
INSTRUCTIONS TO BIDDERS
This form must be completed and submitted by all
Prime/General contractors bidding on projects pursuant
to M.G.L. c. 149, §44A and M.G.L. c. 149A.
You must give complete and accurate answers to all
questions and provide all of the information requested.
MAKING A MATERIALLY FALSE STATEMENT IN THIS
UPDATE STATEMENT IS GROUNDS FOR
REJECTING YOUR BID AND FOR DEBARRING YOU
FROM ALL PUBLIC CONTRACTING.
This Update Statement must include all requested
information that was not previously reported on the
Application used for your firm's most recently
issued (not extended or amended) Prime/General
Contractor Certificate of Eligibility. The Update
Statement must cover the entire period since the
date of your Application, NOT since the date of your
Certification.
You must use this official form of Update Statement.
Copies of this form may be obtained from the awarding
authority and from the Asset Management Web Site:
www.mass.qov/dcam.
If additional space is needed, please copy the
appropriate page of this Update Statement and attach it
as an additional sheet.
See the section entitled "Bidding Limits" in the
Instructions to Awarding Authorities for important
information concerning your bidding limits.
INSTRUCTIONS TO AWARDING AUTHORITIES
Determination of Bidder Qualifications
It is the awarding authority's responsibility to determine
who is the lowest eligible and responsible bidder. You
must consider all of the information in the low bidder's
Update Statement in making this determination.
Remember: this information was not available to the
Division of Capital Asset Management at the time of
certification.
The bidder's performance on the projects listed in Parts
1 and 2 must be part of your review. Contact the project
references.
AWARDING AUTHORITIES ARE STRONGLY
ENCOURAGED TO REVIEW THE LOW BIDDER'S
ENTIRE CERTIFICATION FILE AT THE DIVISION OF
CAPITAL ASSET MANAGEMENT. Telephone (617)
727-9320 for an appointment.
Bidding Limits
Single Proiect Limit: The total amount of the bid, including
all alternates, may not exceed the bidder's Single Project
Limit.
Aggregate Work Limit: The annual value of the work to be
performed on the contract for which the bid is submitted,
when added to the annual cost to complete the bidder's
other currently held contracts, may not exceed the bidder's
Aggregate Work Limit. Use the following procedure to
determine whether the low bidder is within its Aggregate
Work Limit:
Step 1 Review Update Statement Question #2 to
make sure that all requested information is
provided and that the bidder has accurately
calculated and totaled the annualized value of
all incomplete work on its currently held
contracts (column 9).
SteD 2 Determine the annual dollar value of the work
to be performed on your project. This is done
as follows:
(i) If the project is to be completed in less
than 12 months, the annual dollar value of
the work is equal to the full amount of the
bid.
(ii) If the project will take more than 12 months
to complete, calculate the number of years
given to complete the project by dividing
the total number of months in the project
schedule by 12 (calculate to 3 decimal
places), then divide the amount of the bid
by the calculated number of years to find
the annual dollar value of the work.
Step 3 Add the annualized value of all of the bidder's
incomplete contract work (the total of column
9 on page 5) to the annual dollar value of the
work to be performed on your project. The
total may not exceed the bidder's
Aggregate Work Limit.
Correction of Errors and Omissions in Update
Statements
Matters of Form: An awarding authority shall not reject a
contractor's bid because there are mistakes or omissions of
form in the Update Statement submitted with the bid,
provided the contractor promptly corrects those mistakes or
omissions upon request of the awarding authority. [810 CMR
8.05(1)].
Correction of Other Defects: An awarding authority may, in
its discretion, give a contractor notice of defects, other than
mistakes or omissions of form, in the contractor's Update
Statement, and an opportunity to correct such defects,
provided the correction of such defects is not prejudicial to
fair competition. An awarding authority may reject a
corrected Update Statement if it contains unfavorable
information about the contractor that was omitted from the
Update Statement filed with the contractor's bid. [810 CMR
8.05(2)].
LL
L
a�
0 f—
W<
O
Y
L
Q~
W
j
M
M
o
F-
LL
Q
u
�JN
N
F-
W LI
0Q 0 '
r
_M
4-
N
LLI
LLIrn
0'
O
O
Q.
U W
U
o
w 20
v
UQa
°
U�
Z W
W W U)
NC
(D
LO
O N
L
F- D
0
Q
N
CP
O
L O
O
LLI Z
H
W
0 a0
N o
F-
O
QRZ
W`
a
L °'
° T a
2
�Z
-C
2 z 0
U :�
6
04-
LLI F-
M
LL Q
Z
-C V -
w w
o<;;--
o a
O}ZLL
z
° c°n
-°
U) ,-
a (D
Wui W
'.v
o
,.
v o
o O
fn U)
0 LU
ce(A
O.
m `
m `
Q N
LLQ
m n
m
o
o 4)cn
U
O
OCA
U
O O
O U
L L
LLJ
ZZw
C7
V co
m E
LU J
J U
� Lu <
CL °
m =
W��
° Q- N
i—
0O a
Z
Q
o
.° m E
4 i
O
.0
L p
N N m (D u)
CL
N C C N
Q
J
L L
O U
O
O
C i
N N ts
�O
U 0 0
N a
O J
h
J�}Q
OO Z U
!-'
m
t w
O N
-0Q
N to m Q C
m
�0 J
.-U m
z
c
�Q��
o
Q
o
oc
J U Q
Q m
Z
m L O a�
O v ON
J
E- EL
> E
U) (L
Q m o a-
71 < w 0
W
L2
r
z
0
0
W
U)
J
U
W
0
a
0
w
w
J
CL
0
Q
W
w
0
0
Q
0
Z
W
Z
W
w
LL
W
CD
z_
0
J
0w
WQ
Fa
010
OW
w
as
O
0 O Q 0 Q
O r O 11) O M
(.0 O M 1,- O
N N O N
I� N
co O O CO
ti co co Lf) LO
u
z
(i) a) a) c a) a) c
O ° O O° O O 0 O 0 0 0 0 0
a. c c c= t s 0 = s= t
til, 0 c c a 4) a c .2C Q a) a N c a)
� CL
O N
LU O U E Nb I—
U a) I-
N N S E
I - H H -
2 N Y a)
Z N N U
,OY �' �Y
OG
C C C o C 0 0 0
d o o o o 0 o 0
(n (ti N (n L L L L L L
o a) a) m a) a) m n. a s a s
U ° cn a s as a as
+. �, �, •r ....
v m m c°a m c�°o
Z. C O U N ++ c C c c c c c0 0 0 O O
C) `o c°n `-' c°n " O ° °° U U U U U U U 0
U � E Ua Q UU U UU
N U) o O O O
L
I tJ U °� C 0 co c a) `m
m 0
O O U +O+ U LOI N p) N m N Lm
Q c N 0 Q 0 C .N c m C co c to
Z 3 a) ° 10;
° �z°Y �p CD0 0 C90 00 o C7
Z
Q ..
Z z w z w Z Z
W w w Z
2 Z U Z Z Z� Z U Z U
0� w U� w U� w U� w U� w U� w U
('50 0 OO 0 CDO b (go 0 CDO C (90 0 (9
W J
J ? m
F- a U
)
F- -2 U)
O
wn 0
pt a
U Q
d
z
M
L
c
0
a)
c
O)
.N
a)
L-
Q)
c
O
a
c
m0
-Cz
a)
0 w
c }
c
m
O_
U Q
L L
0 N
O c
o
o �
c
U
O
NL
O O
C N
td
E
N �
C
3 �
.OS -
0 :
3 0
Co
N
.>_
c_O`
O 0
`0 0
�D
C (D
Q C
0 0
U U
°, c
N o
U
O
2
c
O
U
O
N
a)
O
c
m
E
U)
c
3
O
00
.cz
�®
0
C Lu
A❑
c
m
L
O
T
c
0
0
U.
0
Q.
N
() c
o
cu
� T
0 E
� o
a� 0
Eca
c �
0-0
co
a� 0
Q i
rr 0)
U O
O O
c�
U
a) �
o
C a3
ca 0.
0 0
Q U
O
FD
N
o
8
N
m
p
r)
C
U
ca
Q
�
()
>_
U
O
W
N
m
0
c
a,
a
E
a)
L-
cB
E�
N
N
O
ca a
N
cc
c�
G L
W
N U
N
N
Q c
N
c o
rU
N
C
cc �a
U
o
(�
N a)
L
E
0
0
o a.
it
W
0
Z
Q
2 LL
of
D
O
Cl) LIJ
W LLI
O
2
02
C
ZU
OY
UO
LLI
Z Of
OW
U=
Zw
0�
m0
ZZ
0=
0�
Z ti
QO
Zw
0 J
m Q
UJW
> W
a. 0
0
U)_
Q
U�
m0
aU
J
J
Q
HZ
TO
-j (.)
O
LO
O
O
LO
M
rn
c
7
0
O
cc
O N
F
c
E
4-
E E
C .
m
F- , w
Z (D
0 °
U'- OL
'a-
4)
W 3 '�
-jCL 75
ai v
N N. N
O °Y
U vim, o 0
Z a
N @
J p p
Q ° c m
LL r at
0 04
W 2
°
Q�c�
j, E L
W c ��
N_ 0 c
J N Z ARO
4- N Q
Z N ° t
Z E-
Q v- —
O
C
O
U
0
w
0
LO
O
rn
m
a-
0 0
co
s
m
N
U
W
C
N
N
E�
a�
my
�j
0
O U
y
Q m
C
�p O
00
o (D
o0
.2'6
> E
0 C
W LLLLI
F- co
NOSY -c.0
0
Ln
O
Wd+ m
0
00
zQUO 'so),Z > o.
Z
Q .
O
LLU?::
O < z c„o
OOwQ�a�
zrW;��
CL}-Wt�D
OO E-``-
o
W O
LO
M
Q2.
O a
csi
z
co
a
�O '
U
F-
Qw
O
o
LO
Zw
a
M
0
.;
cN
60,
w
0
`tpWN
Z��',
N
2 a�
}
U�
c�
F--
M
O� `W LU
>H � Q
LO T-
zz
'Q_
p O
}
YO”
0OO
c
rn
c_ v
N
c °
U
U
06
Ha)
m Q
O Y
p
VU
N T
= c O 3
Q �
m
CN
Wcu
H
O
LO
O
O
LO
M
rn
c
7
0
O
cc
O N
F
c
E
4-
E E
C .
m
F- , w
Z (D
0 °
U'- OL
'a-
4)
W 3 '�
-jCL 75
ai v
N N. N
O °Y
U vim, o 0
Z a
N @
J p p
Q ° c m
LL r at
0 04
W 2
°
Q�c�
j, E L
W c ��
N_ 0 c
J N Z ARO
4- N Q
Z N ° t
Z E-
Q v- —
O
C
O
U
0
w
0
LO
O
rn
m
a-
0 0
co
s
m
N
U
W
C
N
N
E�
a�
my
�j
0
O U
y
Q m
C
�p O
00
o (D
o0
.2'6
> E
0 C
LW
r
0
0
LU
T)
J
U
LU
�NN
1w
LL
W
LU
J
CL
0
Z
U
W
0
LL
0
Q
0
Z
LLI
Z
W
w
LL
LU
I.L
>Z
0
J
LL 0C
H-
LUU
0C
Ou
w 0
CL c
c
r
LO
C)
o
()
O
0)
+L+
L
M
O
L
U
I-
0 0
0)
N
N
p
N
N
04
N
N
0)
c
L
(4
E
0
N
3
C
m0
0
00
�+ Z
�
�
m
"0®
®
C)
N
O
%W
o
o
W
rn
m
�}
L11'
c
a
m
L
V
Cl,
3
Q
J
-C
N 0
O
Q-'
LO
c
L
L=
0
L
L=
o
L
c
L
c
L
C:
C
L
L
04 cc
0
L
M
t
0
0
M
m
X
M N
E c
,`��
M
CL
LAJO
c.0
21
o
C
Q
0
O
Q
N
O
Q
C
O
C.
0
O
Q-
O
a)
Ltl"
c3
(j
a0i
4)
(1)
5
4)
Q)
a0i
(1)
T
a0i
Q)
H
a6i
a)
(1)
O.
}
V
C
t5
O
10
N
0 L
Q)
Q C
0'0
p +-CL'
a)
3
«6 U
c.
N
Cm E
U
t
c
_
U
0
0
a�
r
O.0
Z�
a)
m
oaci
0 LO
o A
>
o�
0
a
V E
'-
o
m
E
0
0
0
�a
c
m
N U
Q U
`~
o
W
O
C
O
c
O
CC
O
O
C
O
C
O
C
O
C
O
C
O
O
O
O
O
O
L
U)
L
L
L
N
L
L
U
a)
a
a)
s
a)
as
a)
N
a
a)
as
a)
O
a
a)
as
a)
N
a
a)
as
a)
a)
a
N
s
�:.0
N
c�0
f�0
t�0
cid
m
Z:
O
O
O
O
O
O
O
O
C
O
C
O
C
O
C
O
C
O
C
O
C
O
C
O
U;
o
U
U
O
U
U
U
U
U
U
U
U
U
U
U
U
�
�
U
(Dc
C
N
N
N
N
N
<O
L
Q
U
O
C
p)
'm
C
O)
'm
c
0)
'cn
a)
C
Lm
m
C
3
m
c
c
c
c
c
m
i=
0
p
U
0
0
(9
p
0
0p
0
(9
0
0
(D
Z
w
w
w
w
.am
IAS
w
Z'^
/y
w
w
Z
N
w
Z
/�
N
w
Z'n
Of
ui
Z
'n
N
of
Z'^
.G
Z
V
ui
Z
/�
V
ui
Z
V
Z
V
Z
V
Z
V
3:
W
U�
W
U�
Fn
w
U�
w
U
�:
w
i'.
W
/0 .0
0
0
00
0
(D0
0
(70
0
(D0
0
/U�
(D0
0
/(7V�
J
ca
a3
C
o
U
7� Cl
>+
a.
J
L
c
L
o
()
O
0)
+L+
L
O
L
U
I-
0 0
0)
N
N
0)
c
L
(4
E
0
N
3
C
m0
0
00
�+ Z
'C Z
"0®
®
C)
N
O
%W
o
o
W
rn
m
�}
a
c
a
m
L
V
Cl,
3
Q
J
-C
N 0
U
0
o
o
O E
04 cc
0
M
0) O
0
0
M
m
X
M N
E c
,`��
M
a)
y
c.0
21
o
o
5
w
f
:.
w
o �°
c�a
a
c
0 0)
L
O
0
Ql
E
0
Eow
c3
0_
E
L
O
0
rn
>0-0
+,,
C
O
+�
C/)
c0 0
c a
>
O.
}
V
C
t5
O
10
N
0 L
Q)
Q C
0'0
p +-CL'
a)
3
«6 U
c.
N
Cm E
U
t
c
_
U
a)
(D
O.0
Z�
a)
m
oaci
0 LO
o A
>
o�
0
a
V E
'-
o
m
E
0
0
0
oa
c
a)
N U
Q U
`~
PART 3 - PROJECT PERFORMANCE
For Parts 3 and 4, if you answer YES to any question, please provide on a separate page a
complete explanation. Information you provide herein must supplement the Application for
your most recently issued (not extended or amended) DCAM Certificate of Eligibility. You must
report all requested information not previously reported on that DCAM Application for
Prime/General Certificate of Eligibility. Include all details (project name(s) and location(s),
names of all parties involved, relevant dates, etc.].
YES NO
1.
Has your firm been terminated on any contract prior to completing a project or has
any officer, partner or principal of your firm been an officer, partner or principal of
another firm that was terminated or failed to complete aproject?
2.
Has your firm failed or refused either to perform or complete any of its work under
❑ ,
any contract prior to substantial completion?
3.
Has your firm failed or refused to complete any punch list work under any contract?
4.
Has your firm filed for bankruptcy, or has any officer, principal or individual with a
❑
financial interest in your current firm been an officer, principal or individual with a
financial interest in another firm that filed for bankruptcy?
5.
Has your surety taken over or been asked to complete any of your work under any
❑
contract?
6.
Has a payment or performance bond been invoked against your current firm, or has
❑
any officer, principal or individual with a financial interest in your current firm been
an officer, principal or individual with a financial interest in another firm that had a
payment or performance bond invoked?
❑
7.
Has your surety made payment to a materials supplier or other party under your
payment bond on any contract?
8.
Has any subcontractor filed a demand for direct payment with an awarding authority
fora public project on any of your contracts?
9.
Have any of your subcontractors or suppliers filed litigation to enforce a mechanic's
❑
lien against property in connection with work performed or materials supplied
under any of your contracts?
❑
10. Have there been any deaths of an employee or others occurring in connection with
any of yourprojects?
11. Has any employee or other person suffered an injury in connection with any of your
❑ 1z
projects resulting in their inability to return to work for a period in excess of one
Yea'?
Division of Capital Asset Management Page 7 of 10
.,---__ 1 i... -4- ca.,a.,., -m C: f—fivc hAnrrh 3n gn1n
PART 4 - Legal or Administrative Proceedings; Compliance with Laws
Please answer the following questions. Information must supplement all judicial and
administrative proceedings involving bidder's firm, which were instituted or concluded
(adversely or otherwise) since your firm's Application for your most recently issued (not
extended or amended) Certificate of Eligibility. You must report all requested information
not previously reported on that DCAM Application for Prime/General Certificate of
Eligibility.
The term "administrative proceeding" as used in this Prime/General Contractor
Update Statement includes (i) any action taken or proceeding brought by a
governmental agency, department or officer to enforce any law, regulation, code,
legal, or contractual requirement, except for those brought in state or federal courts, or
(ii) any action taken by a governmental agency, department or officer imposing
penalties, fines or other sanctions for failure to comply with any such legal or
contractual requirement.
The term "anyone with a financial interest in your firm" as used in this Section "I",
shall mean any person and/or entity with a 5% or greater ownership interest in the
applicant's firm.
If you answer YES to any question, on a separate page provide a complete
explanation of each proceeding or action and any judgment, decision, fine or
other sanction or result. Include all details (name of court or administrative
agency, title of case or proceeding, case number, date action was commenced,
date judgment or decision was entered, fines or penalties imposed, etc.).
YES NO
1. Have any civil, judicial or administrative proceedings involving your firm or a
principal or officer or anyone with a financial interest in your firm been brought,
concluded, or settled relating to the procurement or performance of any construction
contract, including but not limited to actions to obtain payment brought by
subcontractors, suppliers or others?
2. Have any criminal proceedings involving your firm or a principal or officer or
[]
anyone with a financial interest in your firm been brought, concluded, or settled
relating to the procurement or performance of any construction contract including,
but not limited to, any of the following offenses: fraud, graft, embezzlement,
forgery, bribery, falsification or destruction of records, or receipt of stolen property?
3. Have any judicial or administrative proceedings involving your firm or a principal
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state's or federal procurement laws arising
out of the submission of bids orproposals?
4. Have any judicial or administrative proceedings involving your firm or a principal
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of M.G.L. Chapter 268A, the State Ethics Law?
Division of Capital Asset Management Page 8 of 10
PART 4 - Legal or Administrative Proceedings; Compliance with Laws (continued)
YES NO
5. Have any judicial or administrative proceedings involving your firm or a principal
Q
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state or federal law regulating hours of labor,
unemployment compensation, minimum wages, prevailing wages, overtime pay,
equal pay, child labor or worker's compensation?
❑,
6. Have any judicial or administrative proceedings involving your firm or a principal
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state or federal law prohibiting
discrimination in employment?
7. Have any judicial or administrative proceedings involving your firm or a principal
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a claim of repeated or aggravated violation of any state or
federal law regulating labor relations?
brought,
❑
8. Have any proceedings by a municipal, state, or federal agency been
concluded, or settled relating to decertification, debarment, or suspension of your
firm or any principal or officer or anyone with a financial interest in your firm from
public contracting?
9. Have any judicial or administrative proceedings involving your firm or a principal or
El_
officer or anyone with a financial interest in your firm been brought, concluded, or
settled relating to a violation of state or federal law regulating the environment?
10. Has your firm been fined by OSHA or any other state or federal agency for
({
violations of any laws or regulations related to occupational health or safety? Note:
this information may be obtained from OSHA's Web Site at www.osha.gov
11. Has your firm been sanctioned for failure to achieve DBE/MBE/WBE goals,
Q
workforce goals, or failure to file certified payrolls on any publicprojects?
12. Other than previously reported in the above paragraphs of this Section I, have any
D
administrative proceedings or investigations involving your firm or a principal or
officer or anyone with a financial interest in your firm been brought, concluded, or
settled by any local, state or federal agency relating to the procurement or
performance of any construction contract?
firm's
Q
13. Are there any other issues that you are aware which may affect your
responsibility and integrity as a building contractor?
Division of Capital Asset Management Page 9 of 10
— -- `.__.-__•__ i i. j-4 oa .+ CK ti..e KA—h W) 9010
PART 5 - SUPERVISORY PERSONNEL
List all supervisory personnel, such as project managers and superintendents, who will be assigned
to the project if your firm is awarded the contract. Attach the resume of each person listed below.
NAME
TITLE OR FUNCTION
Eddie O'Connor Project Superintendent
I Joseph O'Connor I Project Superintendent I
Michael O'Connor Jr
Project Manager
I Krystal Burrows I Project Manager I
PART 6 - CHANGES IN BUSINESS ORGANIZATION OR FINANCIAL CONDITION
Have there been any changes in your firm's business organization, financial condition or bonding
capacity since the date your current Certificate of Eligibility was issued? ❑ Yes ® No
If YES, attach a separate page providing complete details.
PART 7 - LIST OF COMPLETED CONSTRUCTION PROJECTS SUBMITTED TO
THE DIVISION OF CAPITAL ASSET MANAGEMENT.
Attach here a copy of the list of completed construction projects which was
submitted with your firm's DCAM Application for your most recently issued
(not extended or amended) DCAM Certificate of Eligibility. The Attachment
must include a complete copy of the entire Section G - "Completed Projects"
and the final page - "Certification" (Section J) containing the signature and
date that the Completed Projects list (Section G) was submitted to the
Division of Capital Asset Management.
Division of Capital Asset Management Page 10 of 10
MICHAEL F. O'CONNOR — Project Manager
M. O'Connor Contracting, Inc. — since 2000
Residence: 79 Bonad Road
Brookline, MA 02467
Education; Boston College, Class of 2000, B.A. Economics
Construction
Experience: 2000 — Present — Project Manager for M. O'Connor Contracting, Inc.
1994 — 2000 — Worked Summers and Vacations M. O'Connor Contracting.
Projects: Thayer Homestead Project
Owner: Town of Medway
Description: Renovation and Addition to Community Hall
Project Cost: $2,379,000
Current Project
Chelmsford DPW
Owner: Town of Chelmsford
Description: Renovation to two Historical Town Halls.
Project Cost: $2,645,000
Completion Date: August 2013
Center and North Town Halls, Chelmsford, MA
Owner: Town of Chelmsford
Description: Renovation to two Historical Town Halls.
Project Cost: $4,600,915
Completion Date: August 2012
Rockport Community House, Rockport, MA
Owner: Town of Rockport, MA
Description: Renovation to Historical Community House.
Project Cost: $1,875,000
Completion Date: January 2011
Bolton Public Library, Bolton, MA
Owner: Town of Bolton, MA
Description: Renovation & Addition to Historical Public Library
Project Cost: $5,700,000
Completion Date: February 2010
KRYSTAL BURROWS - Project Manager
M. O'Connor Contracting, Inc. since 2006
Residence: 6 Fuller Street
Plainville, MA 02762
Education: Northeastern University Construction Management — Non -Degree
Construction
Experience: 2006 -Present
M. O'Connor Contracting, Inc.
Estimator - Project Manager
Projects: North Attleboro High School Science Lab
Owner: Town of No. Attleboro — School Department
Description: Upgrade and Modernization of Science Department
Project Cost: $4,850,000
Completion Date: 09/30/2013
Winter Gardens Apartments
Owner: Neighborhood Housing of South Shore
Description: New Construction of 23 Units of Housing
Project Cost: $4,788,440
Completion Date: October 2012
Center and North Town Halls
Owner: Town of Chelmsford
Description: Upgrade of Two Historical Town Halls
Project Cost: $4,600,915
Completion Date: August 2012
Hillcrest Oaks Apartments
Owner: Attleboro Housing Authority
Description: Exterior Modernization.
Project Cost: $5.5 M
Completed: June 2012
EDWARD G. O'CONNOR — Project Supervisor
M. O'Connor Contracting, Inc. since 1987
Residence: 26 Rock Street
Woburn, MA 01801
Education: Local Schools, Kerry, Ireland
Apprenticed Carpentry, Ireland
Construction
Experience: 1987 -Present
M. O'Connor Contracting, Inc.
Project Supervisor — Field Representative for Firm
Licenses: Commonwealth of Massachusetts, Construction Supervisor
Projects: Thayer Homestead Project
Owner: Town of Medway
Description: Renovation & Addition to Community Hall
Project Cost: $2,379,000
Current Project
Chelmsford DPW
Owner: Town of Chelmsford
Description: Renovation to two Historical Town Halls.
Project Cost: $2,645,000
Completion Date: June 2013
Center and North Town Halls, Chelmsford, MA
Owner: Town of Chelmsford
Description: Renovation to two Historical Town Halls.
Project Cost: $4,600,915
Completion Date: August 2012
Salem State College — Trade Shop Fit Up, MA and IT/Facilities Fit Up
Owner: Salem State College
Description: Interior Fit Up to existing brick building for office use.
Project Cost: $1,372,500 and $1,427.500
Completion Date: January 2011
Rockport Community House, Rockport, MA
Owner: Town of Rockport, MA
Description: Renovation to Historical Community House.
Project Cost: $1,875,000
Completion Date: January 2011
Bolton Public Library, Bolton, MA
Owner: Town of Bolton, MA
Description: Renovation to Historical Public Library and complete 11, 000 SF Addition.
Project Cost: $S,700,000
Completion Date: February 2010
Please Enter Your
Firm's Name Here:
Section G.
Highest Value
Completed
Projects &
Completed
Projects
M. O'CONNOR CONTRACTING, INC.
Do Not Convert This Form to PDF
GA
V0 �4
oac �o �a
Caa �o, k �
9� # o'
```0 °t ok�4��
a ?
o
oel
.4D 0 c
�JS
CPc
4ig
aa�
�P
Sample Project
Boston City Hall Renovation
General Building
;1,200,000.00
Roofing
;400,000.00
Masonry
;200,000.00
;4,000,000.00
1/15/2008
5/15/2010
City of Boston
Mr.
John
Smith
(617) 111-1111
123 Main Street
Boston
Construction
Highest Value
Single Project
AHA Hillcrest Modernization
General Building
Attleboro Housing
Phase II
Construction
$5,776,716.00
$5,776,716.00
6/15/2010
6/6/2012
Authority
Mr.
John
Zambarano
508 222-0151
80 South Ave
Attleboro
Second Highest
Value Single
General Building
Historical Building
Project
Bolton Public Library
Construction
$5,711,779.00
Restoration
$5,711,779.00
$5,711,779.00
10/16/2008
1/16/2010
Town of Bolton
Mr.
Robert
White
617 451-2717
112 South Street
Boston
General Building
1
Winter Garden Apartments
Construction
$4,788,440.00
Painting
$76,500.00
Roofing
$73,500.00
$4,788,440.00
8/15/2011
10/12/2012
NHS of the South Shore
Mr.
Robert
Corley
61 770-2227
422 Washington St
Quincy
Chelmsford North and Center
General Building
Historical Building
2
Town Halls
Construction
$4,407,231.00
Restoration
$4,407,231.00
Roofing
$118,000.00
$4,407,231.00
7/1/2011
9/1/2012
Town of Chelmsford
Mr.
Gary
Persichetti
978 244-3379
50 Billerica Road
Chelmsford
General Building
Historical Building
3
Lexington Town Hall
Construction
$1,343,611.00
Restoration
$1,343,611.00
$52,000.00
$1,343,611.00
2/1/2011
9/24/2012
Town of Lexington
Mr.
Mark
Barrett
781-274-8990
201 Bedford Street
Lexington
Salem State University Trade
General Building
--Painting
4
Shop Fit Up
Construction
$1,390,486.00
Painting
$32,000.00
Roofing
$20,000.00
$1,390,486.00
8/3/2010
12/30/2010
Salem State College
Mr.
Phil
Merkle
978 542-7700
70 Loring Ave
Salem
Salem State University IT
General Building
5
Facilities Fit Up
Construction
$1,486,117.00
Roofing
$45,000.00
Painting
$32,000.00
$1,486,117.00
8/12/2010
12/30/2010
Salem State College
Mr.
Phil
Merkle
978-542-7700
70 Loring Ave
Salem
General Building
6
Rockport Community House
Construction
$1,986,500.00
Painting
$90,000.00
$1,986,500.00
12/10/2009
12/27/2010
Town of Rock ort
Mr.
Joseph
Parisi
978 546-3525
34 Broadway
Rockport
General Building
New Bedford Housing
7
Brickenwood Family Housing
Construction
$1,343,800.00
$1,343,800.00
10/16/2009
11/15/2010
Authority
Ms.
Anne
Shoemaker
508 997-4825
725 Pleasant Street
New Bedford
General Building
8
Oxford Police Headquarters
Construction
$3,694,270.00
$3,697,270.00
5/23/2008
7/31/2009
Town of Oxford
Mr.
Richard
Donais
508 987-6030
325 Main Street
Oxford
Chelmsford High Stair
General Building
9
Enclosure
Construction
$686,922.00
$686,922.00
7/7/2008
11/1/2008
Town of Chelmsford
Mr.
I Gary
Persichetti
978 2443379
50 Billerica Road
Chelmsford
General Building
Historical Building
10
Fairbanks Town Hall
Construction
$2,247,700.00
Restoration
$2,247,700.00
$2,247,700.00
4/7/2007
4/1/2008
Town of Ashburnham
Mr.
Don
Bucchianeri
978 621-1595
32 Main Street
Ashbumham
Southeast Rehab & Skilled
General Building
11
Care Center
Construction
$1,500,000.00
Masonry
$150,000.00
$1,500,000.00
6/27/2007
4/1/2008
Easton Health Group
Mr.
John
Struccuzzi
508 295-1040
184 Lincoln Street
No Easton
General Building
Boyes-Watson
12
Hancock Street Condos
Construction
$1,451,382.00
Painting
$36,000.00
Masonry
$20,000.00
$1,451,382.00
8/1/2009
4/1/2010
Architects
Mr.
Mark
Bo es -Watson
617 629-8200
Thirty Bow Street
Somerville
13
14
15
16
17
18
19
20
a° Important: If Applying for
General Building
, 0 ay ok y�cm �,�� yea tiQ Construction, list the
�ar�aLk°Qti� �o� 0 p0� y�t�c a p0� yw c0� p°� c0� three largest sub -trades
$A g° $�0 ems°' $�� you subbed out and/or
O° O° p° self -performed and
GG (� �° GO pP AGI &I vG' Include contract costs for
yea �Q G°cC�°c G* G� G+1 G� G1+1 G�1 each. Sub -trade 1
Sub -trade 1 Contract S
Amount
Sub -trade 2
Category
Sub -trade 2 Contract $
Amount
Sub -Trade 3
Category
Sub -trade 3 Contract S
Amount
MA
01234
ABC Construction
Management, Inc.
Ms.
Jane
Jones
(781) 000-0000
466 Elm Street
Anytown
MA
01567
Plumbing
$400,000.00
Electrical
$300,000.00
HVAC
$250,000.00
MA
02703
Helene -Karl Architects, Inc
Mr.
Greoa
Yanchenko
978 449-0470
61 Skyfields Dr
Groton
MA
01450
Roofing
$290,940.00
Electrical
$269,201.00
Painting
$226,272.00
MA
02111
Lerner Ladds & Bartels Inc
Mr.
Drayton
Fair
401-421-7715
2360 Hope Street
Providence
RI
02906
HVAC
$598,000.00
Electrical
$590,000.00
Structural Steel
$408,000.00
MA
02169
Elton + Hampton Architects
Mr.
William
Barrett
617 708-1071
103 Terrance Street
Roxbury
MA
02120
Electrical
$336,000.00
Plumbing
$265,000.00
HVAC
$234,600.00
MA
01824
BH+A
Mr.
Thomas
Scarlataa
617 350-0450
300A Street
Boston
MA
02210
Electrical
$476,799.00
HVAC
$450,000.00
Elevators
$259,000.00
MA
02420
BH+A
Mr.
Jack
Glassman
617 350-0450
300A Street
Boston
MA
02210
Electrical
$82,000.00
Plumbing
$59,700.00
HVAC
$55,000.00
MA
01970
Winter Street Architects
Mr.
Paul
Durand
978 744-7379
209 Essex St, Suite 300
Salem
MA
01970
HVAC
$183,310.00
Electrical
$120,300.00
MAsonry
$78,000.00
MA
01970
Winter Street Architects
Mr.
Paul
Durand
978 744-7379
209 Essex St, Suite 300
Salem
MA
01970
HVAC
$338,500.00
Electrical
$168,900.00
Plumbing
$60,800.00
MA
01966
McGinley Kalsow &
Associates Inc
Mr.
Wendall
Kalsow
617 625-8901
324 Broadway
Somerville
MA
02145
HVAC
$210,000.00
Electrical
$154,000.00
Elevators
$99,369.00
MA
02740
Arnold Jacobsen Associates
Inc
Mr.
Charles
Hiller
781 935-2500
12 Walnut Hill Park
Woburn
MA
01801
Electrical
$151,000.00
Plumbing
$142,500.00
Fire Protection
Sprinkler Systems
$126,000.00
MA
01540
Reinhardt Associates
Mr.
Mike
Lizee
413 789-9600
430 Main Street
Agawam
MA
01001
Electrical
$488,000.00
Masonry
$225,000.00
HVAC
$288,000.00
MA
01824
Flansbur h Architects
Mr.
Jay
Williams
617 367-3970
77 No Washington
Street
Boston
MA
02114
Masonry
$99,300.00
Roofing
$57,700.00
Electrical
$37,289.00
MA
01430
Kang Associates Inc.
Ms.
Jennifer
Pinkus
978 443-6383
410 Boston Post Road
Sudbury
MA
01776
HVAC
$241,000.00
Electrical
$179,000.00
Masonry
$169,100.00
MA
02356
Donahue Associates
Architects
Mr.
Brian
Donahue
617 479-4122
21 McGrath Highway
Quincy
MA
02169
HVAC
$100,000.00
Plumbing
$95,000.00
Structural Steel
$58,000.00
MA
02143
Bo es -Watson Architects
Mr.
Mark
Bo es -Watson
617 629-8200
Thirty Bow Street
Somerville
MA
02143
HVAC
$82,000.00
Plumbing
$55,000.00
Electrical
$52,000.00
�
�'
�m
��
w
J
a�
�«
L
o c
H
O
�
�
J
L
i
�
a
j
.�
a
a
L
Y
�
J
m
�
m
Z
J
�
o
Y
�
m
E
2
�
�
e
0
V
Certification (notarization required)
The undersigned, Michael O'Connor hereby certifies:
(type name)
That I am an owner or principal of M. O'Connor Contracting, Inc,
(company name)
and that all answers and all statements contained in the attached application (including Sections F
and G) for certificate of eligibility are complete, true and correct. Providing false or misleading
information or failure to provide all required information will be considered grounds for denial,
decertification and/or debarment, I attest to the accuracy of all information contained in this
application and verify that the information submitted is in fact complete, accurate and true, under
oath.
Signed and Sworn under the Pains and Penalties of Perjury.
Dated at 9:00 am
This 11th day of March , 2013.
By (signature): , la -ad
Type name: Michael O'Connor
Title or position: President
k ss.
(county)�tt^ (state)
Before me, �J i 1 \personally appeared and
n tory public
known to me to be & &Ak- --..--,based
(name of officer)
on satisfactory evidence which was his/her driver's license and acknowledged that he/she is
authorized to execute the foregoing and that its execution is his/her free act and deed and the free
ar,t,and deed of the firm.
�--�, My commis n expires:
(notary public signature) H A. 0'C
h COMMtiNyYE11CCN OF
rent name MY'
2017
"Upon completion of this Application and the two corresponding Excel spreadsheets; s7ve and
email them to CertificationAnnlication.dcamfa,state. ma us xx
Page 16 of 16
Prime/General Revised March 2011
f mmnkstar
i�