HomeMy WebLinkAboutContract #: 004144 - From: To: - Exception - ExceptionSchool Department Administration Bdilding
North Andover, MA .
FORM OF GENERAL BID
Kang Associates, Inc.
January 2, 2014
To the Awarding Authority:
A. The undersigned proposes to furnish all labor and materials required for the School Department
Administration Building, North Andover, Massachusetts, in accordance with the accompanying
plans and specifications prepared by Kang Associates, Inc. for the contract price specified below,
subject to additions and deductions according to the terms of the specifications.
B. This bid includes addenda numbered 1,43
C.
M
The proposed contract price is:
%wo �J//ion Fiy�h/u�a'/�a�for,�5i r - dollars ($ 'Z 5��. �v� oo )
For Alternate #1: /
Deduct $
/'ve % housaod
dollars ($ -61 DIOL2. oo )
For Alternate #2:
Deduct dollars ($ 1-61000-00 )
For Alternate #3:
Deduct $ dollars ($
For Alternate #4:
Deduct $ Severn 6w JCiX ousgnq� dollars ($
For Alternate #5: /
Deduct $ van peen IZouS4r/q dollars ($ 7 7 004 • o a )
The subdivision of the proposed contract price is as follows:
Item 1. The work of the general contractor, being all work other than that covered by Item 2:
$ .1.572, o. oa
Item 2. Sub -bids as follows:
Sub -trade
Mason :
04.21 .1 Brick Masonry
04.72.00 Cast Stone Masonry
Name of Sub -Bidder
Bond req'd
Amount; Yes/No
l
AL /Ylosor�r y $ 800. oo e5
Roofingg
07.31.'13 Asphalt Shingles
07.53.00 Elastomeric Membrane Roofing aL'- r Wood 12742 .sfyi2 $ 77 777 00 A1.0
09.51.23 Acoustical Tile Ceilings �V-K Acous�ica/ Cei/��s $ / 570. oo —A16
FORM OF GENERAL BID - 1
School Department Administration Building Kang Associates, Inc.
North Andover, MA January 2, 2014
09.90.00 Painting and Coating O $ 28, 700. oo No
14.42.16 Vertical Wheelchair Lifts E4Q/e /c✓ofo/ $ 26, 96-5. oo /Vo
Division 21 Fire Protection EbacAer &760- 00 AIQ
Division 22 Plumbing Xal0aO /r%ecAq*/ al /$ X8000. oo Ale
Division 23 HVAC Thomas 3;wwden $ 32- DOO. oo A10
Division 26 Electrical
Division 28 Fire Alarm Dya/e Exe,-I Gal ry4sl $ 2d8goD. oo �/1�
Total of Item 2: $ 97h; (0/0.00
E. The undersigned agrees that, if he is selected as general contractor, he will within five days,
Saturdays, Sundays and legal holidays excluded, after presentation thereof by the awarding
authority, execute a contract in accordance with the terms of this bid and furnish a performance
bond and also a labor and materials or payment bond, each of a surety company qualified to do
business under the laws of the commonwealth and satisfactory to the awarding authority and each
in the sum of the contract price, the premiums for which are to be paid by the general contractor and
are included in the contract price; provided, however, that if there is more than 1 surety company,
the surety companies shall be jointly and severally liable.
The undersigned hereby certifies that he is able to furnish labor that can work in harmony with all
other elements of labor employed or to be employed on the work; that all employees to be employed
at the worksite will have successfully completed a course in construction safety and health approved
by the United States Occupational Safety and Health Administration that is at least 10 hours in
duration at the time the employee begins work and who shall furnish documentation of successful
completion of said course with the first certified payroll report for each employee; and that he will
comply fully with all laws and regulations applicable to awards made subject to section 44A.
The undersigned further certifies under the penalties of perjury that this bid is in all respects bona
fide, fair and made without collusion or fraud with any other person. As used in this subsection the
word "person" shall mean any natural person, joint venture, partnership, corporation or other
business or legal entity. The undersigned further certifies under penalty of perjury that the said
undersigned is not presently debarred from doing public construction work in the commonwealth
under the provisions of section twenty-nine F of chapter twenty-nine, or any other applicable
debarment provisions of any other chapter of the General Laws or any rule or regulation
promulgated thereunder.
Date (Name of General Bidder)
Signature and Title of ter n Signing Bid
DD. Boa- 7609132
Business Address
_AZ, ", -9 02i Z&
City and State
FORM OF GENERAL BID - 2
School Department Administration Building
North Andover, MA
GENERAL BIDDER'S CHECKLIST:
— Z Addenda Recognized
Bid Deposit
Certificate of Corporate Bidder
—� DCAM Eligibility
/ Update Statement
Certificate of Non -Collusion and Certificate of Tax Compliance
/ Certification of Labor Harmony and OSHA Training Requirements
FORM OF GENERAL BID - 3
Kang Associates; Inc.
January2, 2014
School Department Administration Building Kang Associates; Inc.
North Andover, MA January 2, 2014
CERTIFICATE OF CORPORATE BIDDER
1, �/f aureer� �C7G��C certify that I am the
C of the corporation named as Bidder in the
Bid Form, and that /1,C1U/'�°P./J Dam/P_ who signed the Bid Form on
behalf of the Bidder was then the f of said
corporation and that I know his signature; that his signature thereto is genuine and that the Bid Form was
duly signed, sealed and executed for and in behalf of said corporation by authority of its governing body.
.0401e ZX�7�7LO�l �d25�i-/JC�7O� co xa
Corporate Seal
Secretary -Clerk
/3o�2o/y�
Date
CORPORATE BIDDER - 1
CERTIFICATIONS
CERTIFICATE OF NON -COLLUSION
The undersigned certifies under penalties of perjury that this bid or proposal has been made and
submitted in good faith and without collusion or fraud with any other person. As used in this
certification, the word "person" shall mean natural person, business, partnership, corporation,
committee, union, club or other organization, entity, or group of individuals.
�faurc�n P. Dle
Print Name & Title
Date
Da9/c 41 KA'42 1 LD/IST�UL7/®n ('orro
Company Name
CERTIFICATE OF TAX COMPLIANCE
Pursuant to Chapter 62C of the Massachusetts General Laws, Section 49A (b), I
�t�lQure�n P. DaAl� , authorized signatory for o�/�
Name of individual Name of contractor
do hereby certify under the pains and penalties of perjury that said contractor has complied with
all laws of the Commonwealth of Massachusetts, and the Town of North Andover, relating to
taxes, permit or other fees, reporting of employees and contractors, and withholding and
remitting child support.
//_0,0
Date
CERTIFICATION
LABOR HARMONY AND OSHA TRAINING REQUIREMENTS
The undersigned certifies under penalties of perjury that he is able to furnish labor that can work
in harmony with all other elements of labor employed or to be employed at the work
and
that all employees to be employed at the worksite and in the work will have completed an
OSHA -approved construction safety and health course lasting at least ten (10) hours.
42W—&,�n iv 19'a/ -
Print Name & Title
DateX30 20/it
D/� Elect/ C'ons��cfon oral
Company Name
The Commonwealth of Massachusetts
Executive Office for Administration and Finance
Division of Capital Asset Management and Maintenance
One Ashburton Place
DEVAL L. PATRICK Boston, Massachusetts 02108
GLEN SHOR
GOVERNOR Tel: (617) 727-4050 SECRETARY, ADMINISTRATION &
TIMOTHY P. MURRAY Fax: (617) 727-5363 FINANCE
LIEUTENANT GOVERNOR CAROLE CORNELISON
COMMISSIONER
Second Amended and Restated
Prime/General Certificate of Contractor Eligibility
CONTRACTOR IDENTIFICATION NUMBER: 1441
This Amended and Restated Certificate Shall be Used for Submittin Prime/General Bids Onl
The prior Certificate of Contractor Eligibility with an Approval Date of 4/25/2013 is hereby superseded, amended
and restated by this Certificate with changes to the information contained in the following Section(s): 6
1. CERTIFICATION PERIOD: This Certificate is valid from 4/25/2013 to 4/25/2014
2. CONTRACTOR'S NAME: Dagle Electrical Construction Corp.
3. CONTRACTOR'S ADDRESS: 285 Salem Street, Woburn, MA 01801
4. WORK CATEGORIES: This Contractor is certified to file bids under Massachusetts General Laws Chapter 149,
Chapter 149A and Chapter 25A in the following checked Categories of Work:
°V Alarm Systems
❑ Asbestos Removal
❑ Deleading
❑ Demolition
❑ Doors & Windows
EVi Electrical
❑ Electronic Security Systems
S. EVALUATIONS:
6. PROJECT LIMITS:
[] Elevators
❑ Energy Management Systems
Exterior Siding
El Fire Protection Sprinkler Systems
❑ Floorcovering
General Building Construction
❑ Historical Building Restoration
❑ Historical Masonry
❑ Historical Painting
❑ Historical Roofing
❑ HVAC
❑ Masonry
❑ Mechanical Systems
❑ Modular Construction/Prefab
Number of Projects Evaluated: 25
Average Project Evaluation Rating: 94
Number of Projects Below Passing Score: 0
❑ Painting
❑ Plumbing
❑ Pumping Stations
❑ Roofing
❑ Sewage & Water Treatment Plants
G Telecommunication Systems
❑ Waterproofing
Single Project Limit (SPL): $13,626,176.00
Aggregate Work Limit (AWL): $51,459,000.00
General Building Construction Limit: $13,626,176.00
7. SUPPLIER DIVERSITY OFFICE CERTIFICATION: Woman Owned Business Enterprise
George M. Matthe4s, Deputy General Counsel,
for Carole J. Cornelison, Commissioner
A prov Date
NOTE TO CONTRACTORS: Complete Applications for Renewal of Contractor Eligibility are due no later than three months
PRIOR to the Expiration Date of the Certification Period shown above. Failure to submit Completed Applications timely may
result in a gap in Certification or a lapse in Certification altogether for your company.
Reviewer's Initials _ K S
OPERATIONAL SERVICES DIVISION
--_ SUPPLIER DIVERSITY OFFICE
Reginald Nunnally
Executive Director
April 25, 2012
Ms. Maureen Dagle
Dagle Electrical Construction Corp.
P 0 Box 760982
Melrose, MA 02176
Dear Ms. Dagle:
THE COMMONWEALTH OF MASSACHUSETTS
Executive Office for Administration and Finance
OPERATIONAL SERVICES DIVISION
One Ashburton Place, Suite 1017
Boston, MA 02108-1552
Deval L. Patrick
Governor
Timothy-P.-Marray-
Lieutenant Governor
Jay Gonzalez
Secretary
Gary J. Lambert
Assistant Secretary for
Operational Services
The Supplier Diversity Office (SDO) is in receipt of your certification renewal information (application). This
consists of your request to renew the certification of Dagle Electrical Construction Corp. and the required
certification renewal information and documentation. Accordingly, SDO has updated your file with this
information and documentation. No substantive review of your company was done at this time. This letter
serves as sole and exclusive proof 'of your firm's -SDO certification.
Based on .your certification renewal information (application), the certification of Dagle Electrical Construction
Corp. as a woman-owned,business enterprise (WBE) with the business description of COMMUNICATION
LINE AND RELATED STRUCTURES" CONSTRUCTION INCLUDING: SUBSTATIONS, POWER PLANTS
AND SOLAR -POWER; TRAFFIC SIGNAL INSTALLATION AND MAINTENANCE; ELECTRICAL AND
GENERAL CONTRACTOR WORK AS IT RELATES TO TRANSPORTATION INCLUDING: TRAFFIC SIGNAL
SYSTEMS; HIGHWAY AND STREET LIGHTING; INTERSECTION IMPROVEMENTS; AND"INTELLIGENT
TRANSPORTATION SYSTEMS has been renewed effective the date of this letter. The company will remain
listed in the SDO Directory of certified businesses and The Massachusetts Central Register, which is published
by the Office of the Secretary of State unless its certification is revoked. Unless revoked, this certification will
last for a period of two years_ and will automatically expire as of May 2, 2014, unless by that date, the
certification of the company is renewed again or the company is recertified.
To renew the company's certification at that time, you will need to submit the following information to SDO no
later than 30 business days prior to May 2, 2014.
1) All company financial statements since the date of the company's then most recent SDO certification;
2) A signed copy of all U.S. Tax Retums and Schedules since the date of the company's then most recent
SDO renewal;
3) Corporations must submit all Annual Reports/Letters of Good Standing filed with the Secretary of (YOUR)
State since the date of the company's then most recent renewal; and
PLEASE NOTE THAT.THE FOLLOWING ITEMS 4-6 CAN BE COMBINED ON ONE NOTARIZED
STATEMENT
4) A notarized statement that indicates:
"I certify under the pains and penalties of perjury that no significant changes affecting eligibility as a
certified Minority/Minority-Women/Woman business enterprise have occurred since the date of the
Tel: (617) 720-3300 TDD: (617) 727-2716 Fax: (617) 727.4527
www.Mass.gov/osd n Follow us on Twitter: @Mass_OSD
Page 2
company's then most recent date of SDO certification as defined in State regulations 425 CMR 2.00
The Massachusetts Supplier Diversity Office."
5) A notarized statement that indicates either "A or B" as referenced below.
A. "I certify under the pains and penalties of perjury that (Insert your Company Name) has not
received any contract(s) as a result of having been SDO certified."
B. "I certify under the pains and penalties of perjury that: (insert your Company Name) has
received a contract(s) as a result of having been SDO certified." List all contract names,
contract amounts and the names of the agencies with which you have contracted from the.date
of your last SDO renewal."
6) A notarized statement that indicates:
"I certify under the pains and penalties of perjury that (Insert your Company Name) has (number) of
employees for each year end given; include owner(s)."
Furthermore, you have a continuing duty to notify SDO of a change in any information that is relevant to the
firm's certification eligibility and to ensure that the information and documentation relied upon by SDO to certify
or to maintain the certification of the business enterprise is accurate, complete and not misleading. You are
required to notify SDO in writing of any change of such information or documentation within thirty calendar
days. By way of example and not limitation, any change in ownership, control, investment, ongoing or
independence may be considered material. Failure to abide by the continuing duty requirements shall
constitute grounds for the business entity's decertification.
Additionally, every six years, certified companies that wish to remain certified must undergo a substantive
review of their certification status with a SDO certification specialist who will re-evaluate the company to
determine whether it continues to meet the applicable certification criteria. If you wish to recertify your
company when it becomes due for substantive review, you will need to submit the.applicable recertification
application and all required information and documentation to SDO no later than forty-five (45) business days
prior to the date of certification expiration (i.e., the recertification date). At that time, a certification specialist
will be assigned to evaluate your company and will make a report and recommendation to the Certification
Committee. (CQ) .on whether or not the company continues to meet the applicable certification criteria.
As provided above in 425 CMR 2.00, if your company has a change of address or telephone number, please
send a signed letter within thirty days of the change on company letterhead to notify SDO of the new address
or telephone number.
During the period of your certification, if you have any further questions regarding your certification renewal,
please direct them to Ms. Nedra D. White, Certification Specialist, at (617) 502-8852.
Very truly yours,
Reginald A. Nunnally
Executive Director
GREAT,ERICAN. GREAT AMERICAN INSURANCE COMPANY
INSURANCE GROUP OHIO uIO
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR:
(Name, legal status and address)
Dagle Electrical Construction Corp.
285 Salem Street
Woburn, MA 01801
OWNER:
(Name, legal status and address)
Town of North Andover
120 Main Street
North Andover, MA 01845
BOND AMOUNT: $ 5%
SURETY:
(Name, legal status and principal place of business):
Great American Insurance Company
301 East Fourth Street
Cincinnati, OH 45202
Five Percent of Amount Bid
PROJECT:
(Name, location or address, and Project number, if any)
School Department Administration Building
The Contractor and Surety are bound to the Owner in the amount set forth above, for the payment of which the Contractor
and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, as
provided herein. The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the time
specified in the bid documents, or within such time period as may be agreed to by the Owner and Contractor, and the
Contractor either (1) enters into a contract with the Owner in accordance with the terms of such bid, and gives such bond or
bonds as may be specified in the bidding or Contract Documents, with a Surety admitted in the jurisdiction of the Project
and otherwise acceptable to the Owner, for the faithful performance of such Contract and for the prompt payment of labor
and material furnished in the prosecution thereof; or (2) pays to the Owner the difference, not to exceed the amount of this
Bond, between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with
another parry to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full
force and effect. The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the
time in which the Owner may accept the bid. Waiver of notice by the Surety shall not apply to any extension exceeding sixty
(60) days in the aggregate beyond the time for acceptance of bids specified in the bid documents, and the Owner and
Contractor shall obtain the Surety's consent for an extension beyond sixty (60) days.
If this Bond is issued in connection with a subcontractor's bid to a Contractor, the term Contractor in this Bond shall be
deemed to be Subcontractor and the term Owner shall be deemed to be Contractor.
When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project, any
provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions
conforming to such statutory or other legal requirements shall be deemed incorporated herein. When so furnished, the
intent is that this Bond shall be construed as a statutory bond and not as a common law bond.
Signed and sealed this 23rd day of January 72014
Dagle Electrical Construction Corp.
A/, (Principal) (Sea!)
(Witness) 4i �........ B
. E+'
Title) /"Iqurecrj D /� - Pres�dci> f'
REAT AMERICAN INSURANCE COMPANY
�` ''••.... (sur®ty}; j (seal)
Vit ess) Jean Fanelli By:
(Attorney -in -Fact) Kathl&dn M Flanagan
The Company executing this bond vouches that this document conforms to American Institute of Architects Document A310.2010 Edition
GREAT AMERICAN INSURANCE COMPANY®
Administrative Office: 301 E 4th STREET - CINCINNATI, OHIO 45202.513.369-5000 - FAX 513-723-2740
The number of persons authorized by
this power of attorney is not more than 1 No. 0
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and existing under
and by virtue of the laws of the State of Ohio, does hereby nominate, constitute and appoint the person or persons named below, each individually if more than one is
named, its true and lawful attorney-in-fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds,
undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond,
undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below.
Name Address Limit of Power
Kathleen M Flanagan Boston MA $75,000,000.00
Surety Bond No.: Bid Bond
Principal: Dagle Electrical Construction Corp.
Obligee: Town of North Andover
This Power of Attorney revokes all previous powers issued on behalf of the attomey(s)-in-fact named above.
IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its
appropriate officers and its corporate seal hereunto affixed this 23rd day of January , 2014 -
Attest GREAT AMERICAN INSURANCE COMPANY
404 (- •''•.:..r • �• •
0 A4
Assistant Secretary Divisional Senior rice President
STATE OF OHIO, COUNTY OF HAMILTON - ss: DAVID C. x1TCHIN (513.4124602)
On this 23rd day of January 2014 , before me personally appeared DAVID C. KITCHIN, to me known, being
duly sworn, deposes and says that he resides in Cincinnati, Ohio, that he is the Divisional Senior Vice President of the Bond Division of Great
American Insurance Company, the Company described in and which executed the above instrument; that he knows the seal of the said Company;
that the seal affixed to the said instrument is such corporate seal; that it was so affixed by authority of his office under the By -Laws of said
Company, and that he signed his name thereto by like authority.
KAR811 L GROSHEIM •
NOTARY PUBLIC, STALE OF ONO
••''�•+ WCOMMINAION IM1,11802-*18
This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance
Company by unanimous written consent dated June 9, 2008.
RESOLVED: That the Divisional President, the several Divisional Senior Vice Presidents, Divisional Vice Presidents and Divisional
Assistant Vice Presidents, or any one of them, be and hereby is authorized, from time to time, to appoint one or more Attorneys -in -Fact to execute
on behalf of the Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof- to
prescribe their respective duties and the respective limits of their authority, and to revoke any such appointment at any time.
RESOLVED FURTHER: That the Company seal and the signature of any of the aforesaid officers and any Secretary or Assistant Secretary
ofthe Company may be affixed by facsimile to any power of attorney or certificate of either given for the execution of any bond, undertaking, contract
of suretyship, or other written obligation in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the
original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with the same force and effect as
though manually affixed.
CERTIFICATION
I, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company, do hereby certify that the foregoing Power of Attorney and the
Resolutions of the Board of Directors of June 9, 2008 have not been revoked and are now in full force and effect.
Signed and sealed this
0
S 1029AC (04f i 1)
23rd day of January , 2014
Assistant Secretary ~~�
EFFECTIVE MARCH 2010
Commonwealth of Massachusetts
Division of Capital Asset Management
PRIME/GENERAL CONTRACTOR
UPDATE STATEMENT
TO ALL BIDDERS AND AWARDING AUTHORITIES
A COMPLETED AND SIGNED PRIME/GENERAL CONTRACTOR UPDATE
STATEMENT MUST BE SUBMITTED WITH EVERY PRIME/GENERAL BID FOR A
CONTRACT PURSUANT TO M.G.L. c.149, §44A AND M.G.L. c. 149A. ANY
PRIME/GENERAL BID SUBMITTED WITHOUT AN APPROPRIATE UPDATE
STATEMENT IS INVALID AND MUST BE REJECTED.
Caution: This form is to be used for submitting Prime/General Contract bids. It is
not to be used for submitting Filed Sub -Bids or Trade Sub -Bids.
AWARDING AUTHORITIES
If the Awarding Authority determines that the bidder does not demonstrably possess
the skill, ability, and integrity necessary to perform the work on the project, it must
reject the bid.
BIDDER'S AFFIDAVIT
I swear under the pains and penalties of perjury that I am duly authorized by the bidder
named below to sign and submit this Prime/General Contractor Update Statement on behalf
of the bidder named below, that I have read this Prime/General Contractor Update Statement,
and that all of the information provided by the bidder in this Prime/General Contractor Update
Statement is true, accurate, and complete as of the bid date.
01/30/2014 Dagle Electrical Construction Corp.
Bid Date Print Name of Prime/General Contractor
Administration Blda. P.O. Box 760982, Melrose. MA 02176
Project Number (or Business Address
name if no number)
Town of North Andover 781-937-7676
Awarding Authority Telephone Number
SIGNATURE*
Bidder's Authorized Ref!:aslntative
INSTRUCTIONS
Division of Capital Asset Management
INSTRUCTIONS TO BIDDERS
` This form must be .completed and submitted by all`
Prime/General contractors bidding on projects pursuant
to M.G.L. c. 149, §44A and M.G.L. c. 149A.
• You must give complete and accurate answers to all
questions and provide all of the information requested.
MAKING A MATERIALLY FALSE STATEMENT IN THIS
UPDATE STATEMENT IS GROUNDS FOR
REJECTING YOUR BID AND FOR DEBARRING YOU
FROM ALL PUBLIC CONTRACTING.
• This Update Statement must include all requested
information that was not previously reported on the
Application used for your firm's most recently
issued (not extended or amended) Prime/General
Contractor Certificate of Eligibility. The Update
Statement must cover the entire period since the
date of your Application, NOT since the date of your
Certification.
• You must use this official form of Update Statement.
Copies of this form may be obtained from the awarding
authority and from the Asset Management Web Site:
www.mass.gov/dcam.
• If additional space is needed, please copy the
appropriate page of this Update Statement and attach it
as an additional sheet.
• See the section entitled "Bidding Limits" in the
Instructions to Awarding Authorities for important
information concerning your bidding limits.
INSTRUCTIONS TO AWARDING AUTHORITIES
Determination of Bidder Qualirications
It is the awarding authority's responsibility to determine
who is the lowest eligible and responsible bidder. You
must consider all of the information in the low bidder's
Update Statement in making this determination.
Remember: this information was not available to the
Division of Capital Asset Management at the time of
certification.
The bidder's performance on the projects listed in Parts
1 and 2 must be part of your review. Contact the project
references.
AWARDING AUTHORITIES ARE STRONGLY
ENCOURAGED TO REVIEW THE LOW BIDDER'S
ENTIRE CERTIFICATION FILE AT THE DIVISION OF
CAPITAL ASSET MANAGEMENT. Telephone (617)
727-9320 for an appointment.
Bidding Limits
Single Project Limit: The total amount of the bid, including
all alternates, may not exceed the bidder's Single Project
Limit.
Aggregate Work Limit: The annual value of the work to be
performed on the contract for which the bid is submitted,
when added to the annual cost to complete the bidder's
other currently held coniracts, may; nd'exceed the bidder`s
Aggregate Work Limit. Use".the foifOwirig procedure to. `
determine whether the 1ow�bidder is within its aggregate .,
Work Limit:
Step 1 Review Update Statement Question #2 to `
make sure that all requested information is
provided and that the bidder has accurately
calculated and totaled the annualized value of
all incomplete work on its currently held
contracts (column 9).
Step 2 Determine the annual dollar value of the work
to be performed on your project. This is done
as follows:
(i) If the project is to be completed in less
than 12 months, the annual dollar value of
the work is equal to the full amount of the
bid.
(ii) If the project will take more than 12 months
to complete, calculate the number of years
given to complete the project by dividing
the total number of months in the project
schedule by 12 (calculate to 3 decimal
places), then divide the amount of the bid
by the calculated number of years to find
the annual dollar value of the work.
Step 3 Add the annualized value of all of the bidder's
incomplete contract work (the total of column
9 on page 5) to the annual dollar value of the
work to be performed on your project. The
total may not exceed the bidder's
Aggregate Work Limit.
Correction of Errors and Omissions in Update
Statements
Matters of Form: An awarding authority shall not reject a
contractor's bid because there are mistakes or omissions of
form in the Update Statement submitted with the bid,
provided the contractor promptly corrects those mistakes or
omissions upon request of the awarding authority. [810 CMR
8.05(1)].
Correction of Other Defects: An awarding authority may, in
its discretion, give a contractor notice of defects, other than
mistakes or omissions of form, in the contractor's Update
Statement, and an opportunity to correct such defects,
provided the correction of such defects is not prejudicial to
fair competition. An awarding authority may reject a
corrected Update Statement if it contains unfavorable
information about the contractor that was omitted from the
Update Statement filed with the contractor's bid. [810 CMR
8.05(2)].
Division of Capital Asset Management P a o P 12
Prime/General Contractor Update Statement Effective December, 2013
LL
O�
W W Q
wv~
QLL O
W W o
~UO
UQa
_Z Q w
Fn
I>-
J
W Wo D
wz0
J W 2<w
0jra
X00
Q0Z
W
0 z
2z0
Wwp
LL x Q
DW af
0 0 0
UZZ
Uwo
W W
0 U) w
cy
V w
?ZW
E- �w<
W W 6L
O < 0 a
�
�w
D a��
~ Z D Z
J QO
CL U00F-
M LL Q
O MZ
VD0>:
a
r J Q J a
F- J (7 <
Q Baa,. -,U
CL -iQwo
L-
a) a)
C
Y
U
w
N
CL
0
U
O
N
co
c
m C�C
L G
O O
0 cu
s a
O Z)
o
3 0
L M
O co
c
O
m�
CL -�
U 'j
02
L 0-
.0 O
L
Q
U N
N c
•O C
Q C
O
U r.+
cu
C
C c
C
o a
'~ x
-0 (D
� c
, c
CU
E
L (U
C
c
CO
E
L
:3 C
0 U
4
_ c
ca
!
cu -
CL
ch
O
N
.mac
E
U
N
U
W
W
Z
O
0
w
U)
J
U
w
N�
I.L
w
w
J
0
2
Q
W
w
0
0
Q
0
Z
w
Z
w
crw
LL
w
C�
Z
0
0w
w Q
H d
00
Ow
Ir Ir
d d
w
2 0
0
0
0
O 0C')L000U')
0
c')
N
04
(D
(O
N
N
= M'ct0(9C?CJ
O
Lo
1`
co
(()
N
M0
to
ct
NI�
-LONODM
�I
r
w N
N
'� �
N
1-
M
c0
r�
00
M
N
00
r•
N
Co
�
( h
00
0
N
M
(D
�:
(p
co
c•%�
(D
1�-
(p
ao
0
r�
c0
1�
(O
0
w
w
m
d
I— (D
oN
O
C3
acic
c
O
E
U
mYcs
.0
wHE'JyUm200
LN
Mo
o
Z v—
c
A)
5r
U
�
UO�U�m��
I—•in
m`
W
Q
m
Z
o
Z
o
t
Q
CL
O
in
t
U
-�
v
c
CC
c
o
L
U
p
8�
N
E
Fa• -Q
0 co
,t3
OU6)�U
m�
o
m
N
o
U�
F=
c
M
Z
W c
m
c
O
v
J
V
(D
W
E2
o
O
a
E y
,
0
m
cn
c
�— CO
�oE
c
t
2
N
(6
�U
O c
o
:.-.�i000
N
=.O
m'
(o
M
., v
X
C
0
cp
(9
c
w E_3
`m
mo
w`9
� L)
0
W 0
`o
o
W
Vi=m
0
cn
O
1
r
U
U
U
�
L
cu
a)
O
c
a) o
rn
LC
O O
L U
L
c o
rn N
Fn
CD
'o ca
c
L
c E
O U
� 3
c o
`u0 00
Z Z
-C3 ® C6
a) 7
�co :2
= w > w
47- >- }
cc
>,[:]cEl
m cu
Q.
EO
O C'. >%
U Q. c
L L cif
ocn a
>, c E
U O U
o (u L
C O
U •�
L �. Q
o 2 3. Z
a o c c
c 0 ca ca
O C NX
E .N CU L a)
c > 0
O E+
O (u '~ a)
o .c : a) o Q
3 O E L
c c
w C o
�
Dc� U)
w
>' > a rn
oCU
C N
O 3
c.E �Lm Lc
a) _ c
cu
Em c
U L
�O O >' >
c (c0 C
o m Q
>,c m E 0
U Q U
It
m
CL
M
0
N
c
-CU
Em
m a>
CUv
c a
�j
� O
N U
Q c
o
�U
cao m
U y
O aci
c
•N m
E
o a.
PART' 2 - CURRENTLY HELD CONTRACTS
LIST ALL PUBLIC AND PRIVATE BUILDING AND NON -BUILDING CONSTRUCTION
PROJECTS YOUR FIRM HAS UNDER CONTRACT ON THIS DATE REGARDLESS OF WHEN
OR WHETHER THE WORK COMMENCED.
1
2
3
4
5
6
7
8
9
PROJECT TITLE &
LOCATION
WORK
CATEGORY
START AND
END DATES
ON
SCHEDULE,
(yes / no)
CONTRACT
PRICE
. % NOT$'VALUE
COMPLETE`
OF
WORK NOT
COMPLETE
(col 5 X col 6)
NO. OF YEARS
REMAINING
(see note below)
ANNUALIZED
VALUE OF
INCOMPLETE
WORK
(col. 7 _ col. 8)
(divided by)
Alford St. Bridge
Civil/ Electrical
May -11 - Jun -14
Yes
3,762,125
15%
564,319
1.00
564,319
Newton Lighting & Traffic
Civil/ Electrical
Jun -11 - Jun -14
Yes
1,376,545
5%
68,827.
1.00
68,827
Boston Schools Maint.
Electrical
Jun -12 - Jul -15'
Yes
3,653,790
40%
1,461,516
1.53
956,853
MassDOT - N. Andover
Hwy. Systems
Feb -13 - Jun -14
Yes
640,833
10%
64,083
1.00
64,083
MassDOT - Salisbury
Hwy. Systems
Feb -13 - Dec -14
Yes
587,508
10%
58,751
1.00
58,751
Dist. 6 Emergency Lighting
Hwy. Systems
Jan -13 - Dec -14
Yes
1,280,400
40%
512,160
1.03
497,828
Muddy River - Boston
Hwy. Systems
Jun -13 - Nov -14
Yes
1,035,000
65%
672,750
1.00
672,750
Boston Traffic Signal Maint.
Hwy. Systems
Jul -13 - Jun -16
Yes
2,469,000
90%
2,222,100
2,53
879,197
Leverett - McKinlock
Bldg/ Electrical
May -13 - Jun -14
Yes
5,522,002
30%
1,656,601
1.00
1,656,601
Worcester East Splash Pad
Gen. Civil Const.
Jul -13 - Jul -14
Yes
2,252,500
30%
675,750
1.00
675,750
MWRA Electrical Upgrades
Civil/ Electrical
May -13 - Jun -16
Yes
10,861,700
90%
9,775,530
2.45
3,993,325
Belmont to Watertown
Hwy. Systems
Aug -13 - Dec -16
Yes
1,777,467
95%
1,688,594
3.00
562,603
West Stockbridge to Weston
Hwy. Systems
Sep -13 - Sep -14
Yes
1,577,468
90%
1,419,721
1.00
1,419,721
Springfield Intersections
Hwy. Systems
Oct -13 - Mar -15
Yes
799,700
100%
799,700
1.25
642,212
New Bedford Marine Terminal
Civil/ Electrical
Sep -13 - Apr -15
Yes
979,859
100%
979,859
1.32
744,313
Lowell - Gallagher Garage
Civil/ Electrical
Dec -13 - Feb -15
Yes
686,868
100%
686,868
1.16
593,377
Weeks Footbridge
Civil/ Electrical
Aug -13 - Mar -15
Yes
760,500
100%
760,500
1.27
597,584
District 6 Lighting
Civil/ Electrical
Aug -13 - Aug -15
Yes
788,708
80%
630,966
1.62
390,669
Boston LED Upgrade
Civil/ Electrical
Jul -13 - Dec -14
Yes
652,333
40%
260,933
1.00
260,933
Cormier Youth Center
Gen. Civil Const.
Dec -13 - Dec -14
Yes
4,643,655
95%
4,411,472
1.00
4,411,472
All Other Projects <500K
Various
Jan -12 - Jul -15
Yes
41,000,000
310%
12,710,000
1.56
8,145,888
ANNUALIZED VALUE OF ALL INCOMPLETE CONTRACT WORK (Total of Column 9)
Column 8 • If less than one year is left in the project schedule, write 1.
• If more than 12 months are left in the project schedule, divide the number of months left
in the project schedule by 12 (calculate to three decimal places).
Division of Capital Asset Management Pay e 15
Prime/General Contractor Update Statement Effective December, 2013
w
2
F—
z
O
0
w
U)
J
U
w
3
O
a
w
F -
w
J
a
O
U
z
U
W
OfO
LL
z
O
H
Q
O
LL
z
w
z
w
ofw
LL
w
a
Z
Zt
0
J
Ow
LJL
wQ
ma
wZ)
O
OW
as
cc
a
m
E
m
U
U
U
w
0o
0
w
(D
x
O
N
O
�
LO
oN
T"
M
O
O
M
N
r-_
ql
M
M
00
00
f)Ooc)
00
N
M
0
T-
OO
lC)
O
MD
In
O
M
mO�
M
r
MO
M
CD
OmMOMON
0
(n
O
CD
0)(0
00
qT
00
r
a
w
M
(D
0
N
co
(D
O
O
m
M
co
O
O
0p
(D
N
M
4
O
M
N
4
N
4
O
N
M
N
to
O
0
O
N'
4
O
Ln
co
O
(D
O
(D
qT
1\
1-
(D
N
M
O
0
O
O
In
qt
�
N
N
LO
CD
f`
r-
M
.-
(n
(n
F-
co
N
O
(D
z
CD
co
z
co
0o
N
w
w
O
CD
w
w
CD
M
z
CD
�-
(D
z
N
O
w
w
a
_
o
O
Co
cts
O
C
co
N
N
s
N
E
v°
N>,
>,
N
U
a)
E°
°
d
d
°
cu
d
o
u)
o
$
Q
5
U
rn
o
U)
75
5
p
cn
Z
�,
Z
v
(/i
(n
Z
a
O
C
m
N
O
(o
mc
C9
D_
Z
C)
O
a)
CO
o
Z
w
m
c
Q
O
U
L'
N
=
.•
C
Q
L
U
Q
t
U_
C
p
O
c
>
r'�-
p
C
C
U
Q
p
C
Q
N
00
U
Z
00
Z
00
U
U
o
U)
O
o
2
w
Z
U)
0
Z
Y
o.
a
0)
a
a
a
a
6-
U
U
C
U
L
U
U
L—
U
U
0
c
rn
o
c
rn
w
0
w
0
c
(n
co
w
5U
-U
m0
U
U
o
c
N
a)
cu
a
h
0
w
_0
(v
o
_UL(c0�
z
0
U)
06w
Q
'c
p
m
C
cu
m°c
Q
°
Q
}
i
2
3
Z
a_pi
z
aUi
vi
m
a°i
vi
>
N
Z
z
z
2
w
z
_°,
U
w
_°,
(.i
w
cu
w
(10�
U
w
U
w
aw;aW;CoW
0
O
MWZ�wZ�wZ�wz�Wz�
O
w
O
w
N
w
N
w
N
Mz
u)
z
o
z
o
z
L9
o
z�
o
z
z
o
O�
w
v
w
v
3
w
v
w
v
w
�i
z
3
w
v
3
w
U
U)
ci
O
O
o
CSI
O
o
(9
O
o
O�
O
O
(9
O
o
(9
O
o
(9I0
o
CSI
O
o
CSI
wc
>
U
cu
`
0
U
O
J
~
w
~
U
C
C
O
F-
1
06
p
o
C)
U
Q
(A
N
CY)
m
C
0)
c
c
cc C
z
E
O
U)
w
s
L
(D
U
mom°,
o
O
v
`
0U)c
o
2
`
U
cc
co
�
C
aQ
�
o
o
Z
m
cc
a
m
E
m
U
U
U
w
LO
N
O
O
'd'
�to
Tl-
O
O
N
N
O
Tl -O
N
O
O
M
•
't
,
It
t
O
O
01
ti
M
O
LO
M
N
N
CO
O
LO
tO
M
O
CO•
I\
-
00
I-
O
O
CO
N
r'
00
I-
O
M
O
M
It
�-
00
N
LO
M
O
CO
N
'
00
N
O
O
r
(O
�-
00
N
O
O
N
CO
00
M
O
Co
M
N
O
It
O
LO
I`
T' -t0
CO
00
M
O
M
0
M
�
oo
tO
O
M
C"')
M
N
r`
U)v--r
co
*M
N
O
M
tO
ti
CO
r
(O
M
Il-
M
r
M
M
N
M
T
d'
N
N
to
M
00
to
M
.-
qt
lO
tl)
M
LO
-
CO
I�
v
(O
lI)
N
o0
O
O
I�
r
(O
O
M
N
O
tO
I�
e-
(O
W
N
to
t
CO
N
O
O
N
I,-
M
O
,
M
N
CO
W
O
O
N
o0
O
to
d
Il-
O
CO
N
(O
h
T-
CO
(D
W
O
CO
O0
M
I�
T -CO
CO
N
r
r
(O
M
M
COO
a)
>+
a)
U
M
°
U
Ir
Ow0C0
O
m
CLj
o
E
F-
M
0
Q
a)
Y
co
CU
U
_
0
U
N
m
O
Q
N
Y
a)
C>
O
f
(D
U
m?
�
o
m
o
a`)
m
C
j
ami
Y
_
>.
Fes-
O
U)
Y
U
Q
0
U
U
Co
cc
(D
U>
'O
Q
C
U)
Z
c�a
CU
m
°
Z
C
0
a.
J
L
m
CL
CC
0a
O
m
d
m
N
'O
F°-
co
t
a
�
a)
L
c
O.
O
C_
>
Y
U
�
-0
of
>,
C
o
Z
2
W
Z
O
a)
CU
E
C
c�
O
Y
W
z
('
W
0
O
(D
_E
U
U
of
a
0
w
m
2
O
O
>%
U
W
Z
O
0
CU
CL
X
N
m
°
(U
-J
W
Z
()
W
D
a
O
U
c
o
U
cu
.L
U
a)
W
0
U
(�I
2
W
Z-
O
W
Q
w
W
Z
W
D
a
O
U
c
o
U
cp
U
()
W
O
U
U�
CSI
F-
O
m
W
Z
O
o
)
c
�j
O
a
O
z
d
W
z
W
o
a
O
U
U)
o
U
cU
.L
U
a)
W
a)
0)
Co
0
U�
CSI
F -
Oca
m
W
Z
O
O
c
°
U
C
N
Y
d
W
Z
(�
W
D
a
O
U
N
o
U
?
U
a)
W
N
0)
CU
U
U�
CSI
a)
o)
C
c
cn
O
>,
U
W
Z
O
.`
(C
o
`=
U
d
W
Z
U'
W
D
o
U
N
C
U
3
O
a
O
�
U
(7I
U
W
2
IY
W
Z>
>
O
cc
t
(U
U
d
W
z
(
W
D
a
O
U
N
o
U
j
a)
W-
N
CM
cc
0
U
CSI
a
F-
W
Z
O
rn
C
m
rn
c
W
a)
(U
m
d
W
z
U
W
D
•g
0
c
CU
o
U
U
CSI
af
o
�
W
Z
O
rn
r
N
c
W
c
O
N
E
O
L
W'
W
Z
0
W
OR
C
O
co
O
_O
U
U
�c
°
C
Y
U
a)
^m
LL
s
c�U
U
U)
W
w,
N
OL
0
U
U
LL
3
°
>coo
>
O
c
O
0
a)
rn
U
O
..
m
c
O
N
U)
m
g
L)
a)
L
N
C
v
o
a)
L
cc
a
O
)
m
m
C
E
a)
F-
rn
cc
f°
O
�
N
cv
0
°)
.-.
10
�
a)
J
U
o
3:m
E
cn
c
3
Z
3
0
a)
3
c
O
E
E
a)
o) m
m-0
C: a
co
2-
0 L0
H U
ac
c
Fao
U
Uco
o c
m
•NO N
E
oa
N
O
N
O
G�0
O)
CO
m
0�0
OMD
N
t�
N
c0
C�
In
00
w
C�
In
CO
0
&
r
co
ch
cCb
r
co
Z
ct
�-
c�
co
rn
O
co
m
rn
co
O
w
fo
7
C
0
co
7
_�
C
0
d
CO
U
a)
O
O
U
c
_N
0
Q
Z
O
0)
Z
•EL �t
0
c
L
N
n
`
U
C
O
U
m
V
a
U
a
U
a
U
O
o
ca
Z
0OC�IOD0IODC�I
O
D
wa)
U)
U
C)
w
C,Z
o
O
mQ
°,
U
Z
W
c
'Fu
N
a)
p
>
c
Q
O
3
~
Z
Q
+cu
m
w
0
U
U
L
a
a)
N
a)
N
L
�c
a)
0
U
L
w
co
�.
U
a)
E
>
LO
a
E
a
Z
J
c
O
L
w
0
m
E
U)
m
U
0
_ L
c
a) O
L C
O O
L V
L
O
a) rn
"O (0
c
L co
C E
O
C
3
0
`c0 00
Z z
�® �®
(1) D
CUco
= W W
cu c
❑ >,R
c c
Q fo
E O
U Q. c
7 t Q
>% cO
cn 2 00
O � L
O >+
Q
E
O �- Z
cn coo 3 s
cn
co 0m ° u) cu «.
U) — c6 a.
a) tt= X
E.c ca L a)
U) a)
c a o' o
0 c° c m
L
t = 0 0
L
cn a)
C C w
L U)
N c 7
C 0 i)
N w
>' > Q �-
OMCU L N
-p O.. N
(o E a) L c
cu
Ec �� a)
_ a)
U 0 0 �' N
N c
O
E O
N U Q 0
00
J
v1
M
r
0
N
.. PART 3 - PROJECT PERFORMANCE
For Parts 3 and. 4, if you answer YES. to any question, please provide on a separate page a .
complete. explanation. Information you'provide herein must supplement the Application for
your most recently issued (not extended or amended) DCAM Certificate of Eligibility. You must
report all requested information not previously reported on that DCAM Application for
Prime/General Certificate of Eligibility. Include all details [project name(s) and location(s),
names of all parties involved, relevant dates, etc.].
vFc Nn
1.
Has your firm been terminated on any contract prior to completing a project or has
❑
any officer, partner or principal of your firm been an officer, partner or principal of
another firm that was terminated or failed to complete aproject?
2.
Has your firm failed or refused either to perform or complete any of its work under
❑
any contract prior to substantial completion?
3.
Has your firm failed or refused to complete any punch list work under any contract?
❑
4.
Has your firm filed for bankruptcy, or has any officer, principal or individual with a
❑
financial interest in your current firm been an officer, principal or individual with a
financial interest in another firm that filed for bankruptcy?
5.
Has your surety taken over or been asked to complete any of your work under any
❑
contract?
6.
Has a payment or performance bond been invoked against your current firm, or has
❑
any officer, principal or individual with a financial interest in your current firm been
an officer, principal or individual with a financial interest in another firm that had a
payment or performance bond invoked?
7.
Has your surety made payment to a materials supplier or other party under your
❑
payment bond on any contract?
8.
Has any subcontractor filed a demand for direct payment with an awarding authority
❑
fora public project on any of your contracts?
9.
Have any of your subcontractors or suppliers filed litigation to enforce a mechanic's
❑
lien against property in connection with work performed or materials supplied
under any of your contracts?
10.
Have there been any deaths of an employee or others occurring in connection with
❑
any of yourprojects?
11.
Has any employee or other person suffered an injury in connection with any of your
❑
projects resulting in their inability to return to work for a period in excess of one
ear?
Division of Capital Asset Management , 9
Prime/General Contractor Update Statement Effective December, 2013
PART 4'.- Legal or Administrative Proceedings;. compliance with Laws
Please answer the following questions. Information must supplement all judicial and
administrative proceedings involving bidder's firm, which were instituted or concluded
(adversely or otherwise) since your firm's Application for your most recently issued (not
extended or amended) Certificate of Eligibility. You must report all requested information
not previously reported on that DCAM Application for Prime/General Certificate of
Eligibility.
The term "administrative proceeding" as used in this Prime/General Contractor
Update Statement includes (i) any action taken or proceeding brought by a
governmental agency, department or officer to enforce any law, regulation, code,
legal, or contractual requirement, except for those brought in state or federal courts, or
(ii) any action taken by a governmental agency, department or officer imposing
penalties, fines or other sanctions for failure to comply with any such legal or
contractual requirement.
The term "anyone with a financial interest in your firm" as used in this Section "I",
shall mean any person and/or entity with a 5% or greater ownership interest in the
applicant's firm.
If you answer YES to any question, on a separate page provide a complete
explanation of each proceeding or action and any judgment, decision, fine or
other sanction or result. Include all details (name of court or administrative
agency, title of case or proceeding, case number, date action was commenced,
date judgment or decision was entered, fines or penalties imposed, etc.).
vV c Xrn
1. Have any civil, judicial or administrative proceedings involving your firm or a
X 1�V
❑
principal or officer or anyone with a financial interest in your firm been brought,
concluded, or settled relating to the procurement or performance of any construction
contract, including but not limited to actions to obtain payment brought by
subcontractors, suppliers or others?
2. Have any criminal proceedings involving your firm or a principal or officer or
❑
anyone with a financial interest in your firm been brought, concluded, or settled
relating to the procurement or performance of any construction contract including,
but not limited to, any of the following offenses: fraud, graft, embezzlement,
forgery, bribery, falsification or destruction of records, or receipt of stolen property?
3. Have any judicial or administrative proceedings involving your firm or a principal
❑
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state's or federal procurement laws arising
out of the submission of bids or roposals?
4. Have any judicial or administrative proceedings involving your firm or a principal
❑
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of M.G.L. Chapter 268A, the State Ethics Law?
Division of Capital Asset Management Nage 110
Prime/General Contractor Update Statement Effective December, 2013
PART 4 - Legal,or Administrative Proceedings; Compliance with Laws (continued)
5. Have any judicial or administrative proceedings involving your firm or a principal
❑
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state or federal law regulating hours of labor,
unemployment compensation, minimum wages, prevailing wages, overtime pay,
equal pay, child labor or worker's compensation?
6. Have any judicial or administrative proceedings involving your firm or a principal
❑
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a violation of any state or federal law prohibiting
discrimination in employment?
7. Have any judicial or administrative proceedings involving your firm or a principal
❑
or officer or anyone with a financial interest in your firm been brought, concluded,
or settled relating to a claim of repeated or aggravated violation of any state or
federal law regulating labor relations?
8. Have any proceedings by a municipal, state, or federal agency been brought,
❑
concluded, or settled relating to decertification, debarment, or suspension of your
firm or any principal or officer or anyone with a financial interest in your firm from
public contracting?
9. Have any judicial or administrative proceedings involving your firm or a principal or
❑
officer or anyone with a financial interest in your firm been brought, concluded, or
settled relating to a violation of state or federal law regulating the environment?
10. Has your firm been fined by OSHA or any other state or federal agency for
❑
violations of any laws or regulations related to occupational health or safety? Note:
this information may be obtained from OSHA's Web Site at www.osha.gov
11. Has your firm been sanctioned for failure to achieve DBE/MBE/WBE goals,
❑
workforce goals, or failure to file certified payrolls on any publicprojects?
12. Other than previously reported in the above paragraphs of this Section I, have any
❑
administrative proceedings or investigations involving your firm or a principal or
officer or anyone with a financial interest in your firm been brought, concluded, or
settled by any local, state or federal agency relating to the procurement or
performance of any construction contract?
13. Are there any other issues that you are aware which may affect your firm's
❑
responsibility and integrity as a building contractor?
Division of Capital Asset Management P a g e
Prime/General Contractor Update Statement Effective December, 2013
PART 5 - SUPERVISORY PERSONNEL
List all supervisory personnel, such as project managers and superintendents, who will be assigned
to the project if your firm is awarded the contract. Attach the resume of each person listed below.
NAME
TITLE OR FUNCTION
James Dagle
Vice President
Robert Narbonne
Chief Estimator
Richard Kaiser
Project Manager
Michael Cronin
Project Manager
PART 6 - CHANGES IN BUSINESS ORGANIZATION OR FINANCIAL CONDITION
Have there been any changes in your firm's business organization, financial condition or bonding
capacity since the date your current Certificate of Eligibility was issued? ❑ Yes ® No
If YES, attach a separate page providing complete details.
PART 7 — LIST OF COMPLETED CONSTRUCTION PROJECTS SUBMITTED TO
THE DIVISION OF CAPITAL ASSET MANAGEMENT.
Attach here a copy of the list of completed construction projects which was
submitted with your firm's DCAM Application for your most recently issued
(not extended or amended) DCAM Certificate of Eligibility. The Attachment
must include a complete copy of the entire Section G — "Completed Projects"
and the final page — "Certification" (Section J) containing the signature and
date that the Completed Projects list (Section G) was submitted to the
Division of Capital Asset Management.
Division of Capital Asset Management P a g e 112
Prime/General Contractor Update Statement Effective December, 2013
J. Certification (notarization required)
The undersigned, Maureen P. Dagle hereby certifies: .
(type name)
That I am an owner or, principal of Dale Electrical Construction Corp.,
(company name)
and that all answers and all statements contained in the attached application (including Sections F
and G) for certificate of eligibility are complete, true and correct. Providing false or misleading
information or failure to provide all required information will be considered grounds for denial,
decertification and/or debarment. I attest to the accuracy of all information contained in this
application and verify that the information submitted is in fact complete, accurate and true,. under
oath.
Signed and Sworn under the Pains and Penalties of Perjury.
Dated at Woburn. MA
This 22nd day of January, 2014.
By (signature):
Type name: Maureen P. DaQle
Title or position: President
Middlesex ss. Massachusetts.
(county) (state)
Before me, Scott Niss , personally appeared and
(notary public)
known to me to be Maureen P. Daele ,based
(name of officer)
on satisfactory evidence which was his/her driver's license and acknowledged that he/she is
authorized to execute the foregoing and that its execution is his/her free act and deed and the free
act an d of the firm. -
�g!Kpp,�expires: 9/22/2017
(notary public signature) oMMlssipN• �ss
Scott Niss
(print name)
AJ LU o� Z `
"Upon completion of this Application and the two coi'y' �i" xcek-spreadsheets, save and
email them to CertificationApplication.�V�:i�ua.us **
Page 16 of 16
Prime/General Revised March 2011
Computer
38 WEST HILL A1'i?Nl0i MI:LILUSL, MA 02176
PHONE 781-662-7706 FAX 781-937-7678 I -MAIL MAUREEN®DECCO,RP.com-
MAUREEN ]EAGLE
BUSINESS Dagle Electrical Construction, Corp., Melrose, MA 1997 -present
EXPERIENCE President/Owner
Quality Graphics, Inc., Cambridge, MA 1985-1998
Office Manager
Aerial Electric, Inc. Somerville, MA 1985-1991
Reviewed. bid documents, blueprints and specification manuals.
Patriot Bank, NA Boston, MA 1981-1985
Head Teller/ Customer Service Representative
EDUCATION Peterson School
Master Electrician Course 2005
.Journeyman Electrician Course 2003
International Municipal Signal Association 2003
Traffic Signal Technician Level I & H
Work Zone Safety
Greater Boston C6de Consultant's '2001
Construction Supervisor Course
Bunker Hill Community College, Charlestown, MA 1997
ASI University, Waterloo, IA 1991
Course in ASI, Profit Plus software
Smith, McLaughlin and Hart Real Estate 1984
Salesperson real-estate course
PERSONAL Master Electrician license, MA #A20103
Journeyman Electrician License, MA #E51887
Journey Electrician, RI #B012836
MA Certification #ZZ -75812 & AA -75812 & BE -75812
Construction Supervisor License MA#CS 079230
Hoisting Engineer license #HE110674
National Electrical Contractors Association #0961158
Licensed Real Estate Salesperson License MA#030518
Notary Public Commonwealth of Massachusetts
Firearms License State of Massachusetts
Melrose, MA 021.76
(781) 662-7706
EXPERIENCE:
1999 -present Eagle Klectricaj CopspMetlon Corp. Melrose, MA
Vice President, Project Manager, Electrician: Work with all phases of
electrical construction and installation: commercial and residential
rehabilitation; generators, motors, HVAC, traffic signal installation,
security, high voltage, Fire Alarm Systems, CATV Systems, Marine
Construction and Rehabilitation
1997-1999 ftle Electptc Coutnalue Medford, MA
Electrician: Worked with all phases of electrical
construction and installation: commercial and residential
rehabilitation; generators, motors, HVAC, security and high voltage
1992-1997
1985-1991
James Daale Electrician Medford, MA
Electrician: Worked with all phases of electrical
construction and installation: commercial and residential
rehabilitation; generators, motors, HVAC, security and high voltage
Aerial Electric, Incorporated Somerville, MA
Project Manager, Electrician: Worked extensively on highway
power distribution, lighting, high voltage and line voltage;
Draw bridge power and controls; Sports facRy's lighting, power,
security, motor and controls; Electrical construction, rehabilitation,
upgrade and maintenance.
1980-1985 92riello Electric, Incorporated Medford, MA
Field Supervisor, Electrician: Responsibilities were
coordinating and working the company's major commercial and
residential projects. Overseen field personnel, equipment
purchasing, tool maintenance and inventory.
1978-1980 North American Industries Everett, MA
Electrician's Apprentice, wired and tested motors.
Page 1
EDUCATION:
International Municipal Signal Associates, NY
Work Zone Safety Certification
Traffic Signal CertiScation mac-•
Wentworth Institute ofTechnology, Boston MA
Mash Blactrician Course ,
Journeyman Electrician Course .,i.
Welding Course t
Bunker Hill Community College, Charlestown, MA
Master Electrician Reviaw � ' -.5
PERSONAL Massachusetts Mager Ebetrician License #17087A
Massachusetts Joumeyam Electrician License #28051E
New Hampshire Master Electrician License #11035M
Maine Master Electrician Lioe m #MS60018360
Rhode Island Joumey Electrician #B-012837
Massachusetts Construction Supervisor License #CS074897
Massachusetts Hoisting Engineer Liogm #HE082633
IMSA Certification Work Zone #Z7,74223
IMSA Ceatification Traffic Signal Technician Level I #AA -74223
Page 2
Key Proiect Personnel
Name: Peter M. Grela
Title: Project Excecutive
Work Experience: 2006 - Present: Dagle Electrical Construction, Corp.
1988 - 2005: Modern Continental Construction Co., Inc.
1984 -1988: Darmody, Merlino & Co.,
Major Proiects
Value: $168,000,000
Title: Las Vegas Cogeneration II
Owner: Black Hills Energy Corporation
Description: Construction of 224 Megawatt cogeneration electrical power plant featuring
carbon monoxide catalyst and No, catalytic reduction units.
Value: $145,000,000
Title: Shoreham & Edgewood Peaking Plant Construction
Owner: PPL Electric Utility Corporation
Description: Construction of two 79.9 MW Natural Gas peaking plants featuring 4
GE, LM 6000 gas turbine generators, SCR Units, Completed turnkey within
Eight Month Schedule
Value: $242,000,000
Title: Terminal E, International Gateway Construction
Owner: Massachusetts Port Authority
Description: Construction of new International (E) Terminal at Logan Airport encompassing
800,000 S.F. Terminal Addition and 350,000 S.F. reconstruction, including all
security, baggage handling, roadway and parking lot systems.
Value: $72,000,000
Title: West Parking Garage
Owner: Massachusetts Port Authority
Description: Construction of West Parking Garage at Logan Airport
including concrete construction, poured in place, precast, electrical systems
and related infrastructure improvements
Value: $146,000,000, $110,000,000, $84,000,000 & $72,000,000
Title: Metrowest water supply tunnel system
Interisland Tunnel (Quincy to Deer Island)
Braintree/ Weymouth Effluent Tunnel
Nut Island Headworks
Owner: Massachusetts Water Resources Authority
Description: Construction of various underground tunnel systems and above ground
monitoring and flow facilities for the Boston Harbor cleanup project.
Complete tunnel excavation, lining, shaft construction, substation
construction, site construction, headworks construction, and site restoration
Value: $384,000,000
Title: MHD Rt. 3 North Widening - Design/ Build/ Finance
Owner: Commonwealth of Massachusetts - MHD
Description: Design/ Build/ Finance of 21 miles of reconstruction and widening of Rt. 3 North
from Rt. 128 to New Hampshire border, including all new lighting, ITS systems,
sound wall and Smart Route Systems.
Name:
Title:
Kev Proiect Personnel
Robert Narbonne
Chief Estimator/ Project Manager - Electrical
Work Experience: 2005 -Present: Dagle Electrical Construction, Corp.
1999-2005: O'Mahoney & Sons Electric
1986-1999: Croce Electric
Maior Proiects
Value: $20,044,301
Title: Natick Mall Expansion
Owner: General Growth Properties, Inc.
Description: Complete electrical construction and installation of all electrical components
including power distribution, branch distribution, life/safety systems, security,
Tel/Data, Lighting and retail fit -out for a new 870,000 sq. ft. retail mall.
Value: $5,000,000
Title: United Airlines at Logan
Owner: Massachusetts Port Authority
Description: Fitout of Terminal "C"
Value: $9,300,000
Title: Avenir
Owner: Trinity Capital Partners
Description: Ground up construction of 241 luxury apartments, retail area, and MBTA
Superstation Improvements encompassing over 700,000 S.F.
Title: Salem Harbor Power Plant
Owner: New England Power and Service
Description: Removed and Replaced 115kV transformers, switches, conductors,
and service switches
Title: Tewksbury Sub Station Switchyard
Owner: New England Power and Service
Description: Replace oil switches with gas switches. Replaced 230kV and 115kV
disconnects, switches, installator operators, and replace all 230
and 115 conductors, installed all new control and relay cabinet
wiring.
Key Project Personnel
Name: Rich Kaiser
Title: Senior Project Manager
Work Experience: 2007-2010: Power Line Contractors, Inc
2006 -Present: Dagle Electrical Construction, Corp.
2005-2006: Roads Construction Corp.
1997-2005: Modern Continental Construction Corp.
1996-1997: Irrigation Consulting and Engineering Corp.
Maior Proiects
Value: $6,200,000
Title: South Shore Plaza Expansion
Owner: Simon Mall Group
Description: Complete electrical construction of all the electrical systems of a 320,000
square foot addition of the South Shore Plaza. Work includes power
distribution, branch distribution, life/safety systems, security, tel /data,
HVAC Controls, and Site Lighting.
Value: $130,000,000
Title: MBTA Superstation
Owner: Massachusetts Bay Transportation Authority
Description: Construction of a new underground light rail train station for the MBTA's
Green Line Service, and the remodeling of the existing Orange Line North
Station. Project included, 950 linear feet of top down tunnel construction,
erection of a steel frame viaduct for light rail train service, construction
a new highway ramp. Electrician substation, signaling, and communication
Value: $242,000,000
Title: Terminal E, International Gateway Construction
Owner: Massachusetts Port Authority
Description: Construction of new International (E) Terminal at Logan Airport encompassing
800,000 S.F. Terminal Addition and 350,000 S.F. reconstruction, including all
security, baggage handling, roadway and parking lot systems.
Value: $4,200,000
Title: Economy Parking Garage
Owner: Massachusetts Port Authority
Description: Construction of new electrical service, fire alarm system, security system,
installation of parking controls equipment and photovoltaic system
Value: $1,200,000
Title: Wind Technology Testing Center
Owner: Massachusetts Port Authority
Description: Construction of high rise building project for Massachusetts Clean Energy Center,
LED lighting, power distribution system, fire alarm & power feed to testing equipment
Value: $9,300,000
Title: Avenir
Owner: Trinity Capital Partners
Description: Ground up construction of 241 luxury apartments, retail area, and MBTA
Superstation Improvements encompassing over 700,000 S.F.
Value: $20,044,301
Title: Natick Mall Expansion
Owner: General Growth Properties, Inc.
Description: Complete Electrical Construction including Power Distribution, Branch Distribution,
Life / Safety Systems, Tel/Data, Lighting and Retail Fit -out for 870,000 sq ft retail mall.
Key Protect Personnel
Name: Michael Cronin
Title: Senior Project Manager
Work
Experience: 23 years experience in high-rise construction, excavation, deep foundations,
structural steel & concrete.
Major Proiects
Value: $12,500,000
Title: 41 Phillips Street, Beacon Hill, MA
Owner: Modern Continental Construction, Corp.
Description: High-rise renovations, elevator, underpinning
Value: $33,000,000
Title: 470 Atlantic Ave., Boston, MA
Owner: Modern Continental Construction, Corp.
Description: High-rise renovation of 14 stories, elevator bank, transformer room to supply
National Grid, masonry curtain wall finishes & parking garage
Value: $6,000,000
Title: Natick Armory Castle Condominiums
Owner: Natick Armory, LLC
Description: 23 condominiums, 46 underground parking spots & historical renovations
Value: $10,800,000
Title: Three Campus Security
Owner: MBTA
Security, Vertical Lift Gates, Access Control to Campus, Camera
Description: Surveillance with VIDSIS
Value: $4,200,000
Title: Downtown Crossing & Park Street
Owner: MBTA
Description: Security, Access Control, Camera Surveillance
!
.� 0
`
X22\LU�
\IL$\�°
» «
... �,
�
k
a
a
a
-
Q
-
2
/
|■
a
a
a
2c)
�
>/2\\)®
E \
\
67
}
�
.
2
\
k
2
CL
I
»°2
c
a
a
a
\
10
8
§
)
\
0
_
k
03
«
\\dmi
\2\\
im.
.
.
.,
!
K
!
2�
.
°
§
��
�
■
.!
§
k
-/
k�
,
k
■
t
$
�
®
2
2
\§
k
� ■
`
�
!
■
. �
-
OW
!�
w
A
Y
O
8O
8O
8S
�y
r
�
a
z
�
�
0
o
9
a
�
U»
o
rU
z
m
O
O
0
N
4
� U
W
R
a
W
�a
4
E
g
25
25
v
z
R
UR
w
c�
o
—y
m
y U
=
4
W
W
LL
" e m
iE
E.
Y
IT
o^
n
^
c
o>°
u
v
sz
0
U
Z" a. _
`
E
'c
'c
c o
m
`m
E
i
€�
o
m
a
E
m
m
c
-
LL
U
C
v' C
06..E
U
i
i
m=m2
m
2
dOwi
ma
0
m
�mmi
E
w
1
'
s
ac
o=S c
V
Ise-
Um'
U
U
z
2
U
1
U
m
o
p
Q LL
U
>
E
v
O
W
M
U
'a
Z6a
a
a
L
m
N
O
O
r
U
CO
O
a
G
W
O
O
ao
e
s
o
o$
o
g$s
o
0
o0
s
s
o
s
s
0
s
0
s
0
o
a
0
a
s
a
s
s
o
€
c;
�
a
o
U
O�
m�
e
o.
8
S
S
8
E
o
s
s
S
o
S
o
S
U uj
,
O
J
Uma
o
o
5
0
o
0
c
i
`-
-
E�
E-
E-
b
m
E-
W2
,mcE
w`
m
o
=
m
E„
Em
m
o
a
3
w
ORW°rSoo
s
s
U40
e$
e
4=1
s
s
s
0
s
o
s
s
s
Q
V
o
ZU
wE
E.
W
uEEE
-�`e
RNHNN
w
Eo
p
Wm
m
y
q
0m
W
W
W
a
W
m
WmN
2
U R
F
W
W
a
W
a
a
W
W
O
p
o
o
p
O
O
s
O
O
O
O
O
�l
CL
ms
pg
o
pO
O _$
o
O
o
ci
U
e
c
ec
_
.o.
ao
q
w
a
m2€o
fmm
2,�
2.2
��r
mm'2
m
w
�o
w
w`u
�
m
�0o
o
A
m
`�
m
gm
w
wSo
U
W
W
uo
0
f'
w
m E
o
u,
m q
V
:Tu
w 3
@
c
m
m
?
B
m
w E
.' p
O, W
=
O
=
m
ul
a
o
01
Eo
d'
`o
z
'
m
_
m
m
y
U
ti
'
d
m
r
o
a
w
=
F
w'
E' z
U w
m
1
f
o
$
Eva
E
� � o
w A m am N E .g ay5 N m
w cN o» m m U c
o
fqU oI I E
3 N LLI N ¢
8
8
O
N
fD
O
a
O
N
<
O
n
n
O
n
O
n
O
_
E
o
y
$
E
N
_
°
EE
D
o
<
o
a
om
E
U
c
m
m
= _co
m
0
moi °
o g
�`o°
`o
j =
`o
`o32
z
c
c
m
a
-y
:
vt2
y
_
m
O
ooiL
_Z
N
v
3
_
i
�<
E
m
E
m
o
a
v
O1
E
a
r
Y
E
A
'j
m`
a
o
mFS
m
3
m
m
w
-
•
8
O
N
fD
O
a
O
N
<
O
n
n
O
n
O
n
O
_
E
o
y
$
E
w
_
°
EE
2
E.
e
JE
3
zv
w
-
t
-
3
-
•
8
O
N
fD
O
a
O
N
<
O
n
n
O
n
O
n
O
y
y
•
2
E.
e
z
3
w
t
LL•
a z
i
ry
`
a
m
m
3
0
m
3
Z
m
m
m
=�
9
a
m
z
m
3
o°
W
-0001
°
U p0
$
z
O
=o
°
-
°
y
3
x
a
°
y
V
v
Y
c
Z
m
`
z
w
0
-
m
`
m
5
z
Y
_
a
o
m
Q
m
m
S
m
w
0
>
V
0
a
^
o
N
O
- s
z
'
1.
m
Z5
m
N
r
❑
zo
i3
i3
�°
;
oa
g
t
V1
o'
A
y
w
m
=
U
m
Q
q
m
c
O
S
N
3
N
Q
° ° E
° a E - 8
L< EI E E E o - E c E m E v �E E a E __ c E E v a
00
--
wI E -
sA�
a
Me
c0
o
0
o
g
o
0
;0
}
Z
o
E
p
y
<
n
o
m
x
o
,
Ccc-
7 U
2
y
x
a
y
a
V
L
$
c
C O
ccmS
o
o
a
0
ili
atia
�
C
in
O
V
N
�r
W
w
Vl
p
-
LL
W
�
•
p
g
o
g
o
L
E�
acid
N
ge
8